Queensland regulation

Building Industry Fairness (Security of Payment) Regulation 2018

In ForceQLD

Jurisdiction

Queensland

Act Number

16 of 2018

Collection

regulation

Plain English Summary

6/10 complexity

This regulation fills in detailed rules for the Building Industry Fairness (Security of Payment) framework. It prescribes which construction activities are covered or excluded from trust protections, what trustees and financial institutions must report and keep, how adjudicators are qualified, graded and maintained, and the fees and timeframes that apply. It mainly affects contracting parties, subcontractors, trustees, adjudicators, financial institutions and the commissioner/registrar by setting specific compliance, reporting and record‑keeping duties that affect how and when payments are held and released.

JSON API

Deep Dive

6,668 words · generated 21/06/2026

What it does

This regulation implements detailed operational, recordkeeping, notice, grading, professional development and procedural rules that give practical effect to the Building Industry Fairness (Security of Payment) Act framework. It commenced 1 March 2018 (sec. 2) and prescribes specific categories of work that are to be treated as project trust work and project trust subcontracts (secs 4, 5A), which construction activities are residential construction work (secs 6-7), the types of information trustees and others must give when opening, changing or closing project and retention trust accounts (secs 8-10E and schedule 1AA), and the ledger, reconciliation and documentary record requirements trustees must keep for project trusts and retention trusts (secs 10F-10G). The regulation also prescribes oversight notice content for directions to trustees and financial institutions (secs 10H, 10J), the types of information to be included in agreements between the commission and financial institutions (sec. 10I), and the form and content of notices associated with withdrawals and deposits from project and retention trust accounts (schedule 1AA parts 4 and 8).

On adjudication and tribunal-side processes, the regulation approves the registrar’s policies and an adjudicator code of conduct (secs 11-12), prescribes what constitutes conflicts of interest for adjudicators (sec. 13), sets maximum adjudication fees for small claims (sec. 14), fixes lodgement cut-off practice (sec. 15), and sets the registrar’s referral procedure for assigning applications to grade 1 or grade 2 adjudicators (sec. 16). It sets limits on the length and supporting documents for small-value adjudications (sec. 17). The regulation prescribes the adjudication qualification (Certificate in Adjudication, sec. 18), the grading rules and review cycle for adjudicators (secs 19-25), and a continuing professional development (CPD) regime including points, recording and administrative processes (secs 26-37).

Current sections

Direct links to the current provisions in Building Industry Fairness (Security of Payment) Regulation 2018.

118

pt.1

Introduction

sec.1

Short title

sec.1 Short title

This regulation may be cited as the Building Industry Fairness (Security of Payment) Regulation 2018 .

sec.2

Commencement

sec.2 Commencement

This regulation commences on 1 March 2018.

sec.3

Definitions

sec.3 Definitions

The dictionary in schedule 3 defines particular words used in this regulation. s 3 (prev s 2A) ins 2018 SL No. 177 s 4 renum 2018 SL No. 177 s 5

pt.2

Trusts

pt.2-div.1

General

sec.4

Work included as project trust work— Act , s 8A

sec.4 Work included as project trust work— Act , s 8A

For section 8A (2) of the Act , the following work is prescribed to be project trust work— the management and removal of scaffolding if the scaffolding is used for carrying out other project trust work; the construction, installation, alteration or repair of a swimming pool, whether associated with a building or not. In this section— swimming pool see the Building Act 1975 , schedule 2 . s 4 (prev s 3) renum 2018 SL No. 177 s 5 sub 2020 SL No. 241 s 15 (sec.4-ssec.1) For section 8A (2) of the Act , the following work is prescribed to be project trust work— the management and removal of scaffolding if the scaffolding is used for carrying out other project trust work; the construction, installation, alteration or repair of a swimming pool, whether associated with a building or not. (sec.4-ssec.2) In this section— swimming pool see the Building Act 1975 , schedule 2 .

(a) the management and removal of scaffolding if the scaffolding is used for carrying out other project trust work;
(b) the construction, installation, alteration or repair of a swimming pool, whether associated with a building or not.

sec.5

Work that is not project trust work— Act , s 8A

sec.5 Work that is not project trust work— Act , s 8A

For section 8A (3) of the Act , the following work is prescribed not to be project trust work— the construction, maintenance or repair of a busway, road or railway; the construction, maintenance or repair of a tunnel for a busway, road or railway; an authorised activity for a resource authority. In this section— authorised activity , for a resource authority, see the Mineral and Energy Resources (Common Provisions) Act 2014 , schedule 2 . busway — means a route especially designed and constructed for, and dedicated to, the priority movement of buses for passenger transport; and includes— places for the taking on and letting off of passengers of buses using the busway; and a causeway or culvert in, on, or under a busway that is associated with the busway; and another structure that supports a busway or has the purpose of ensuring the safe or efficient use of a busway. bridge, fence, gate, pedestrian overpass, pillar, sign driveway means— a surface constructed— on private property; and for the purpose of driving or riding of motor vehicles to or from the property and a road; and for which the right to use the surface is restricted to persons with an interest in the property and their invitees; or a surface constructed— between the boundary of a private property and that part of a road used for the driving or riding of motor vehicles; and for the purpose of driving or riding of motor vehicles to or from the property and the road. private property includes a separate or distinct parcel of land for which an interest is recorded in a register under the Land Act 1994 . railway — means a guided system designed for the movement of rolling stock having the capability of transporting passengers, livestock or freight on a track with a gauge of 600mm or more; and includes a railway station or platform. resource authority see the Mineral and Energy Resources (Common Provisions) Act 2014 , section 10 . road — means an area of land— whether surveyed or unsurveyed, dedicated, notified or declared to be a road for public use; or whether surveyed or unsurveyed, taken under an Act, for the purpose of a road for public use; or developed, or to be developed, for the public use of driving or riding of motor vehicles; and includes— a street, esplanade, highway, pathway, thoroughfare, toll road, track or stock route; and a causeway or culvert in, on, or under a road that is associated with the road; and a structure in, on, or under a road that is associated with the road; and does not include a driveway. rolling stock means a vehicle that operates on or uses rails, including, for example, a carriage, locomotive, rail car, tram or trolley. s 5 (prev s 4) renum 2018 SL No. 177 s 5 sub 2020 SL No. 241 s 15 (sec.5-ssec.1) For section 8A (3) of the Act , the following work is prescribed not to be project trust work— the construction, maintenance or repair of a busway, road or railway; the construction, maintenance or repair of a tunnel for a busway, road or railway; an authorised activity for a resource authority. (sec.5-ssec.2) In this section— authorised activity , for a resource authority, see the Mineral and Energy Resources (Common Provisions) Act 2014 , schedule 2 . busway — means a route especially designed and constructed for, and dedicated to, the priority movement of buses for passenger transport; and includes— places for the taking on and letting off of passengers of buses using the busway; and a causeway or culvert in, on, or under a busway that is associated with the busway; and another structure that supports a busway or has the purpose of ensuring the safe or efficient use of a busway. bridge, fence, gate, pedestrian overpass, pillar, sign driveway means— a surface constructed— on private property; and for the purpose of driving or riding of motor vehicles to or from the property and a road; and for which the right to use the surface is restricted to persons with an interest in the property and their invitees; or a surface constructed— between the boundary of a private property and that part of a road used for the driving or riding of motor vehicles; and for the purpose of driving or riding of motor vehicles to or from the property and the road. private property includes a separate or distinct parcel of land for which an interest is recorded in a register under the Land Act 1994 . railway — means a guided system designed for the movement of rolling stock having the capability of transporting passengers, livestock or freight on a track with a gauge of 600mm or more; and includes a railway station or platform. resource authority see the Mineral and Energy Resources (Common Provisions) Act 2014 , section 10 . road — means an area of land— whether surveyed or unsurveyed, dedicated, notified or declared to be a road for public use; or whether surveyed or unsurveyed, taken under an Act, for the purpose of a road for public use; or developed, or to be developed, for the public use of driving or riding of motor vehicles; and includes— a street, esplanade, highway, pathway, thoroughfare, toll road, track or stock route; and a causeway or culvert in, on, or under a road that is associated with the road; and a structure in, on, or under a road that is associated with the road; and does not include a driveway. rolling stock means a vehicle that operates on or uses rails, including, for example, a carriage, locomotive, rail car, tram or trolley.

(a) the construction, maintenance or repair of a busway, road or railway;
(b) the construction, maintenance or repair of a tunnel for a busway, road or railway;
(c) an authorised activity for a resource authority.
(a) means a route especially designed and constructed for, and dedicated to, the priority movement of buses for passenger transport; and
(b) includes— (i) places for the taking on and letting off of passengers of buses using the busway; and (ii) a causeway or culvert in, on, or under a busway that is associated with the busway; and (iii) another structure that supports a busway or has the purpose of ensuring the safe or efficient use of a busway. Example for subparagraph (iii) — bridge, fence, gate, pedestrian overpass, pillar, sign
(i) places for the taking on and letting off of passengers of buses using the busway; and
(ii) a causeway or culvert in, on, or under a busway that is associated with the busway; and
(iii) another structure that supports a busway or has the purpose of ensuring the safe or efficient use of a busway. Example for subparagraph (iii) — bridge, fence, gate, pedestrian overpass, pillar, sign
(i) places for the taking on and letting off of passengers of buses using the busway; and
(ii) a causeway or culvert in, on, or under a busway that is associated with the busway; and
(iii) another structure that supports a busway or has the purpose of ensuring the safe or efficient use of a busway. Example for subparagraph (iii) — bridge, fence, gate, pedestrian overpass, pillar, sign
(a) a surface constructed— (i) on private property; and (ii) for the purpose of driving or riding of motor vehicles to or from the property and a road; and (iii) for which the right to use the surface is restricted to persons with an interest in the property and their invitees; or
(i) on private property; and
(ii) for the purpose of driving or riding of motor vehicles to or from the property and a road; and
(iii) for which the right to use the surface is restricted to persons with an interest in the property and their invitees; or
(b) a surface constructed— (i) between the boundary of a private property and that part of a road used for the driving or riding of motor vehicles; and (ii) for the purpose of driving or riding of motor vehicles to or from the property and the road.
(i) between the boundary of a private property and that part of a road used for the driving or riding of motor vehicles; and
(ii) for the purpose of driving or riding of motor vehicles to or from the property and the road.
(i) on private property; and
(ii) for the purpose of driving or riding of motor vehicles to or from the property and a road; and
(iii) for which the right to use the surface is restricted to persons with an interest in the property and their invitees; or
(i) between the boundary of a private property and that part of a road used for the driving or riding of motor vehicles; and
(ii) for the purpose of driving or riding of motor vehicles to or from the property and the road.
(a) means a guided system designed for the movement of rolling stock having the capability of transporting passengers, livestock or freight on a track with a gauge of 600mm or more; and
(b) includes a railway station or platform.
(a) means an area of land— (i) whether surveyed or unsurveyed, dedicated, notified or declared to be a road for public use; or (ii) whether surveyed or unsurveyed, taken under an Act, for the purpose of a road for public use; or (iii) developed, or to be developed, for the public use of driving or riding of motor vehicles; and
(i) whether surveyed or unsurveyed, dedicated, notified or declared to be a road for public use; or
(ii) whether surveyed or unsurveyed, taken under an Act, for the purpose of a road for public use; or
(iii) developed, or to be developed, for the public use of driving or riding of motor vehicles; and
(b) includes— (i) a street, esplanade, highway, pathway, thoroughfare, toll road, track or stock route; and (ii) a causeway or culvert in, on, or under a road that is associated with the road; and (iii) a structure in, on, or under a road that is associated with the road; and
(i) a street, esplanade, highway, pathway, thoroughfare, toll road, track or stock route; and
(ii) a causeway or culvert in, on, or under a road that is associated with the road; and
(iii) a structure in, on, or under a road that is associated with the road; and
(c) does not include a driveway.
(i) whether surveyed or unsurveyed, dedicated, notified or declared to be a road for public use; or
(ii) whether surveyed or unsurveyed, taken under an Act, for the purpose of a road for public use; or
(iii) developed, or to be developed, for the public use of driving or riding of motor vehicles; and
(i) a street, esplanade, highway, pathway, thoroughfare, toll road, track or stock route; and
(ii) a causeway or culvert in, on, or under a road that is associated with the road; and
(iii) a structure in, on, or under a road that is associated with the road; and

sec.5A

Meaning of project trust subcontract — Act , s 9A

sec.5A Meaning of project trust subcontract — Act , s 9A

Each of the following services or work is, when associated with the construction, alteration, repair, restoration, maintenance or extension of a building, prescribed for section 9A (1) (b) (iv) of the Act — earthmoving and excavating; if the building is prefabricated—installing the building; constructing a structure, or installing a prefabricated structure, associated with the building; installing a prefabricated component of the building or a structure associated with the building; cleaning the inside or outside of the building or a structure associated with the building; landscaping or restoring the site; other project trust work. For section 9A (1) (c) of the Act , a subcontract is excluded from being a project trust subcontract if the only subcontracted work under the subcontract is 1 or more of the following— drilling for or extracting oil or gas; tunnelling or boring for or extracting minerals; supplying or transporting a prefabricated building or structure or a prefabricated component of a building or structure. s 5A ins 2024 SL No. 85 s 4 (sec.5A-ssec.1) Each of the following services or work is, when associated with the construction, alteration, repair, restoration, maintenance or extension of a building, prescribed for section 9A (1) (b) (iv) of the Act — earthmoving and excavating; if the building is prefabricated—installing the building; constructing a structure, or installing a prefabricated structure, associated with the building; installing a prefabricated component of the building or a structure associated with the building; cleaning the inside or outside of the building or a structure associated with the building; landscaping or restoring the site; other project trust work. (sec.5A-ssec.2) For section 9A (1) (c) of the Act , a subcontract is excluded from being a project trust subcontract if the only subcontracted work under the subcontract is 1 or more of the following— drilling for or extracting oil or gas; tunnelling or boring for or extracting minerals; supplying or transporting a prefabricated building or structure or a prefabricated component of a building or structure.

(a) earthmoving and excavating;
(b) if the building is prefabricated—installing the building;
(c) constructing a structure, or installing a prefabricated structure, associated with the building;
(d) installing a prefabricated component of the building or a structure associated with the building;
(e) cleaning the inside or outside of the building or a structure associated with the building;
(f) landscaping or restoring the site;
(g) other project trust work.
(a) drilling for or extracting oil or gas;
(b) tunnelling or boring for or extracting minerals;
(c) supplying or transporting a prefabricated building or structure or a prefabricated component of a building or structure.

pt.2-div.2

Project trusts

sec.6

Meaning of residence

sec.6 Meaning of residence

For section 7 , each of the following structures is a residence if fixed to land and designed to be used for residential purposes— a single detached dwelling; 1 or more attached dwellings that are separated by a common wall; duplex, row house, terrace house, townhouse, villa unit a building, of not more than 3 storeys, containing 2 or more separate residential units. Part of a structure mentioned in subsection (1) is also a residence if the part is designed to be used for residential purposes. A manufactured home fixed, or intended to be fixed, to land in a residential park is also a residence. However, the following things are not a residence— a boat, caravan, motor vehicle, tent, trailer or train; a building designed as a temporary or movable building, other than a manufactured home mentioned in subsection (3) . For subsection (1) (c) , the number of storeys of a building is calculated by excluding 1 storey of the building if more than 50% of the floor area of at least 1 storey of the building is designed to accommodate motor vehicles. If a building has 3 storeys containing residential units and another storey where more than 50% of the floor area of the storey is designed to accommodate motor vehicles, the number of storeys of the building is 3. In this section— manufactured home see the Manufactured Homes (Residential Parks) Act 2003 , section 10 . residential park see the Manufactured Homes (Residential Parks) Act 2003 , section 12 . residential unit means a part of a building designed for separate occupation as a residence. storey — means a space within a building which is situated between one floor level and the next floor level, or if there is no floor above, the ceiling or roof above; but does not include a mezzanine or space that contains only— a lift, shaft, stairway or meter room; or a bathroom, shower room, laundry, water closet or other sanitary compartment; or accommodation intended for not more than 3 vehicles; or any combination of a thing mentioned in any of subparagraphs (i) to (iii) . s 6 prev s 6 om 2018 SL No. 177 s 6 pres s 6 (prev s 5) renum 2018 SL No. 177 s 5 sub 2020 SL No. 241 s 15 (sec.6-ssec.1) For section 7 , each of the following structures is a residence if fixed to land and designed to be used for residential purposes— a single detached dwelling; 1 or more attached dwellings that are separated by a common wall; duplex, row house, terrace house, townhouse, villa unit a building, of not more than 3 storeys, containing 2 or more separate residential units. (sec.6-ssec.2) Part of a structure mentioned in subsection (1) is also a residence if the part is designed to be used for residential purposes. (sec.6-ssec.3) A manufactured home fixed, or intended to be fixed, to land in a residential park is also a residence. (sec.6-ssec.4) However, the following things are not a residence— a boat, caravan, motor vehicle, tent, trailer or train; a building designed as a temporary or movable building, other than a manufactured home mentioned in subsection (3) . (sec.6-ssec.5) For subsection (1) (c) , the number of storeys of a building is calculated by excluding 1 storey of the building if more than 50% of the floor area of at least 1 storey of the building is designed to accommodate motor vehicles. If a building has 3 storeys containing residential units and another storey where more than 50% of the floor area of the storey is designed to accommodate motor vehicles, the number of storeys of the building is 3. (sec.6-ssec.6) In this section— manufactured home see the Manufactured Homes (Residential Parks) Act 2003 , section 10 . residential park see the Manufactured Homes (Residential Parks) Act 2003 , section 12 . residential unit means a part of a building designed for separate occupation as a residence. storey — means a space within a building which is situated between one floor level and the next floor level, or if there is no floor above, the ceiling or roof above; but does not include a mezzanine or space that contains only— a lift, shaft, stairway or meter room; or a bathroom, shower room, laundry, water closet or other sanitary compartment; or accommodation intended for not more than 3 vehicles; or any combination of a thing mentioned in any of subparagraphs (i) to (iii) .

(a) a single detached dwelling;
(b) 1 or more attached dwellings that are separated by a common wall; Examples— duplex, row house, terrace house, townhouse, villa unit
(c) a building, of not more than 3 storeys, containing 2 or more separate residential units.
(a) a boat, caravan, motor vehicle, tent, trailer or train;
(b) a building designed as a temporary or movable building, other than a manufactured home mentioned in subsection (3) .
(a) means a space within a building which is situated between one floor level and the next floor level, or if there is no floor above, the ceiling or roof above; but
(b) does not include a mezzanine or space that contains only— (i) a lift, shaft, stairway or meter room; or (ii) a bathroom, shower room, laundry, water closet or other sanitary compartment; or (iii) accommodation intended for not more than 3 vehicles; or (iv) any combination of a thing mentioned in any of subparagraphs (i) to (iii) .
(i) a lift, shaft, stairway or meter room; or
(ii) a bathroom, shower room, laundry, water closet or other sanitary compartment; or
(iii) accommodation intended for not more than 3 vehicles; or
(iv) any combination of a thing mentioned in any of subparagraphs (i) to (iii) .
(i) a lift, shaft, stairway or meter room; or
(ii) a bathroom, shower room, laundry, water closet or other sanitary compartment; or
(iii) accommodation intended for not more than 3 vehicles; or
(iv) any combination of a thing mentioned in any of subparagraphs (i) to (iii) .

sec.7

Residential construction work— Act , s 15C

sec.7 Residential construction work— Act , s 15C

This section prescribes the type of work that is residential construction work for section 15C (3) of the Act , definition residential construction work . All of the following work is residential construction work if carried out by a licensed contractor and the insurable value of the work is more than $3,300— the construction of a residence or related roofed building; building work within the building envelope of a residence or related roofed building; building work, on a thing connected to a residence or related roofed building, that requires a building development approval under the Building Act 1975 or a permit under the Plumbing and Drainage Act 2018 ; the construction, installation, alteration or repair of a swimming pool for a— residence or proposed residence; or related roofed building or proposed related roofed building. Also, the following work is residential construction work if carried out for work mentioned in subsection (2) — for work relating to a residence—work carried out on the site of the residence or proposed residence; for work relating to a related roofed building—work carried out on the site of the building or proposed building; other work necessary for the proper construction, installation, alteration or repair of a residence or related roofed building, including, for example— work performed by an architect under the Architects Act 2002 in the architect’s professional practice; and work performed by a registered professional engineer under the Professional Engineers Act 2002 in the engineer’s professional practice; and work performed by a surveyor under the Surveyors Act 2003 in the surveyor’s professional practice. In this section— building envelope , for a residence or related roofed building, means the outermost sides of the aggregation of the components of a building that have the primary function of separating the internal part of the residence or related roofed building from the external environment. the slab and footings system, an external wall and a roof building work see the Queensland Building and Construction Commission Act 1991 , schedule 2 . licensed contractor means a person who holds a contractor’s licence under the Queensland Building and Construction Commission Act 1991 . related roofed building — means a building that— has a roof designed to be part of the building and is impervious to water or wind; and is, or is proposed to be, on the site of a residence or proposed residence; and is used, or proposed to be used, for a purpose related to the use of a residence or proposed residence; but does not include— a residence; or a building if the roof is a sail, umbrella or similar thing. residence see section 6 . swimming pool see the Building Act 1975 , schedule 2 . s 7 prev s 7 om 2018 SL No. 177 s 6 pres s 7 ins 2018 SL No. 177 s 7 sub 2020 SL No. 241 s 15 (sec.7-ssec.1) This section prescribes the type of work that is residential construction work for section 15C (3) of the Act , definition residential construction work . (sec.7-ssec.2) All of the following work is residential construction work if carried out by a licensed contractor and the insurable value of the work is more than $3,300— the construction of a residence or related roofed building; building work within the building envelope of a residence or related roofed building; building work, on a thing connected to a residence or related roofed building, that requires a building development approval under the Building Act 1975 or a permit under the Plumbing and Drainage Act 2018 ; the construction, installation, alteration or repair of a swimming pool for a— residence or proposed residence; or related roofed building or proposed related roofed building. (sec.7-ssec.3) Also, the following work is residential construction work if carried out for work mentioned in subsection (2) — for work relating to a residence—work carried out on the site of the residence or proposed residence; for work relating to a related roofed building—work carried out on the site of the building or proposed building; other work necessary for the proper construction, installation, alteration or repair of a residence or related roofed building, including, for example— work performed by an architect under the Architects Act 2002 in the architect’s professional practice; and work performed by a registered professional engineer under the Professional Engineers Act 2002 in the engineer’s professional practice; and work performed by a surveyor under the Surveyors Act 2003 in the surveyor’s professional practice. (sec.7-ssec.4) In this section— building envelope , for a residence or related roofed building, means the outermost sides of the aggregation of the components of a building that have the primary function of separating the internal part of the residence or related roofed building from the external environment. the slab and footings system, an external wall and a roof building work see the Queensland Building and Construction Commission Act 1991 , schedule 2 . licensed contractor means a person who holds a contractor’s licence under the Queensland Building and Construction Commission Act 1991 . related roofed building — means a building that— has a roof designed to be part of the building and is impervious to water or wind; and is, or is proposed to be, on the site of a residence or proposed residence; and is used, or proposed to be used, for a purpose related to the use of a residence or proposed residence; but does not include— a residence; or a building if the roof is a sail, umbrella or similar thing. residence see section 6 . swimming pool see the Building Act 1975 , schedule 2 .

(a) the construction of a residence or related roofed building;
(b) building work within the building envelope of a residence or related roofed building;
(c) building work, on a thing connected to a residence or related roofed building, that requires a building development approval under the Building Act 1975 or a permit under the Plumbing and Drainage Act 2018 ;
(d) the construction, installation, alteration or repair of a swimming pool for a— (i) residence or proposed residence; or (ii) related roofed building or proposed related roofed building.
(i) residence or proposed residence; or
(ii) related roofed building or proposed related roofed building.
(i) residence or proposed residence; or
(ii) related roofed building or proposed related roofed building.
(a) for work relating to a residence—work carried out on the site of the residence or proposed residence;
(b) for work relating to a related roofed building—work carried out on the site of the building or proposed building;
(c) other work necessary for the proper construction, installation, alteration or repair of a residence or related roofed building, including, for example— (i) work performed by an architect under the Architects Act 2002 in the architect’s professional practice; and (ii) work performed by a registered professional engineer under the Professional Engineers Act 2002 in the engineer’s professional practice; and (iii) work performed by a surveyor under the Surveyors Act 2003 in the surveyor’s professional practice.
(i) work performed by an architect under the Architects Act 2002 in the architect’s professional practice; and
(ii) work performed by a registered professional engineer under the Professional Engineers Act 2002 in the engineer’s professional practice; and
(iii) work performed by a surveyor under the Surveyors Act 2003 in the surveyor’s professional practice.
(i) work performed by an architect under the Architects Act 2002 in the architect’s professional practice; and
(ii) work performed by a registered professional engineer under the Professional Engineers Act 2002 in the engineer’s professional practice; and
(iii) work performed by a surveyor under the Surveyors Act 2003 in the surveyor’s professional practice.
(a) means a building that— (i) has a roof designed to be part of the building and is impervious to water or wind; and (ii) is, or is proposed to be, on the site of a residence or proposed residence; and (iii) is used, or proposed to be used, for a purpose related to the use of a residence or proposed residence; but
(i) has a roof designed to be part of the building and is impervious to water or wind; and
(ii) is, or is proposed to be, on the site of a residence or proposed residence; and
(iii) is used, or proposed to be used, for a purpose related to the use of a residence or proposed residence; but
(b) does not include— (i) a residence; or (ii) a building if the roof is a sail, umbrella or similar thing.
(i) a residence; or
(ii) a building if the roof is a sail, umbrella or similar thing.
(i) has a roof designed to be part of the building and is impervious to water or wind; and
(ii) is, or is proposed to be, on the site of a residence or proposed residence; and
(iii) is used, or proposed to be used, for a purpose related to the use of a residence or proposed residence; but
(i) a residence; or
(ii) a building if the roof is a sail, umbrella or similar thing.

sec.8

Information for notice about opening, closing, transferring or changing the name of project trust account— Act , s 18B

sec.8 Information for notice about opening, closing, transferring or changing the name of project trust account— Act , s 18B

For section 18B (2) (b) of the Act , the information stated in schedule 1AA , part 1 for the notice is prescribed. s 8 prev s 8 om 2018 SL No. 177 s 6 pres s 8 (prev s 9) renum 2018 SL No. 177 s 8 sub 2020 SL No. 241 s 15

sec.9

Information for notice about change of financial institution— Act , s 18C

sec.9 Information for notice about change of financial institution— Act , s 18C

For section 18C (1) (c) of the Act , the trustee must inform the contracting party, the commissioner and subcontractor beneficiaries about a transfer of a project trust account to an alternative financial institution by giving them a written notice stating the information stated in schedule 1AA , part 2 . s 9 (prev s 10) renum 2018 SL No. 177 s 8 sub 2020 SL No. 241 s 15

sec.10

Information for notice of project trust— Act , s 23

sec.10 Information for notice of project trust— Act , s 23

For section 23 (2) (c) of the Act , the information stated in schedule 1AA , part 3 is prescribed. s 10 (prev s 11) renum 2018 SL No. 177 s 8 sub 2020 SL No. 241 s 15

sec.10A

Information for notice about particular withdrawals from project trust account— Act , s 23A

sec.10A Information for notice about particular withdrawals from project trust account— Act , s 23A

For section 23A (2) of the Act , the information stated in schedule 1AA , part 4 for the notice is prescribed. s 10A ins 2020 SL No. 241 s 15

pt.2-div.3

Retention trust account

sec.10B

Information for notice about opening, closing, transferring or changing the name of retention trust account— Act , s 34B

sec.10B Information for notice about opening, closing, transferring or changing the name of retention trust account— Act , s 34B

For section 34B (2) (b) of the Act , the information stated in schedule 1AA , part 5 for the notice is prescribed. s 10B ins 2020 SL No. 241 s 15

sec.10C

Information for notice about change of financial institution— Act , s 34C

sec.10C Information for notice about change of financial institution— Act , s 34C

For section 34C (1) (c) of the Act , the trustee must inform a contracted party about the transfer of a retention trust account to an alternative financial institution by giving the contracted party a written notice stating the information stated in schedule 1AA , part 6 about the account. s 10C ins 2020 SL No. 241 s 15

sec.10D

Information for notice of retention trust— Act , s 40

sec.10D Information for notice of retention trust— Act , s 40

For section 40 (2) (c) of the Act , the information stated in schedule 1AA , part 7 is prescribed. s 10D ins 2020 SL No. 241 s 15

sec.10E

Information for notice about deposits to or withdrawals from retention trust account— Act , s 40A

sec.10E Information for notice about deposits to or withdrawals from retention trust account— Act , s 40A

For section 40A (2) of the Act , the information stated in schedule 1AA , part 8 for the notice is prescribed. s 10E ins 2020 SL No. 241 s 15

sec.10EA

Section sec.10EA

s 10EA ins 2021 SL No. 181 s 4 om 2024 SL No. 85 s 5

pt.2-div.4

Trust records

sec.10F

Ledger accounts and reconciliation statements— Act , s 52

sec.10F Ledger accounts and reconciliation statements— Act , s 52

For section 52 (a) of the Act , the following records are prescribed for each project trust and retention trust— ledger accounts kept in accordance with subsection (2) ; and monthly reconciliation statements prepared in accordance with subsection (3) showing that the ledger accounts correctly record relevant transactions for the trust. The ledger accounts for a project trust or retention trust must be kept as follows— the ledger accounts for the trust must be kept separately from the ledger accounts for any other trust and from any other accounting record; each relevant transaction for the trust must be recorded in the ledger accounts within 3 business days after the transaction occurs; there must be separate ledger accounts for the following— each beneficiary other than the trustee; the trustee; the trust account; before an electronic system used to keep the ledger accounts is changed or records are archived or deleted from the system, steps must be taken to ensure that the records remain accessible in a readable form. A monthly reconciliation statement— must be prepared within 5 business days after the end of each month; and must show a trial balance of the ledger accounts at the end of the month confirming that the total of debit balances equals the total of credit balances; and must show that the balance in the trust account ledger account at the end of the month is the same as the balance shown in the financial institution statement for the trust account at the end of the month. In this section— relevant transaction , for a project trust or retention trust— means an activity or event that affects the financial position and value of interests in the trust; and includes— for a project trust— a claimant giving a payment claim under section 75 of the Act ; and a respondent giving a claimant a payment schedule under section 76 of the Act ; and any other activity or event that affects a claimant’s entitlement to a progress payment; and for a retention trust— withholding an amount from payment to a beneficiary; and an activity or event that affects the beneficiary’s entitlement to the amount withheld. s 10F ins 2020 SL No. 241 s 15 sub 2024 SL No. 85 s 6 (sec.10F-ssec.1) For section 52 (a) of the Act , the following records are prescribed for each project trust and retention trust— ledger accounts kept in accordance with subsection (2) ; and monthly reconciliation statements prepared in accordance with subsection (3) showing that the ledger accounts correctly record relevant transactions for the trust. (sec.10F-ssec.2) The ledger accounts for a project trust or retention trust must be kept as follows— the ledger accounts for the trust must be kept separately from the ledger accounts for any other trust and from any other accounting record; each relevant transaction for the trust must be recorded in the ledger accounts within 3 business days after the transaction occurs; there must be separate ledger accounts for the following— each beneficiary other than the trustee; the trustee; the trust account; before an electronic system used to keep the ledger accounts is changed or records are archived or deleted from the system, steps must be taken to ensure that the records remain accessible in a readable form. (sec.10F-ssec.3) A monthly reconciliation statement— must be prepared within 5 business days after the end of each month; and must show a trial balance of the ledger accounts at the end of the month confirming that the total of debit balances equals the total of credit balances; and must show that the balance in the trust account ledger account at the end of the month is the same as the balance shown in the financial institution statement for the trust account at the end of the month. (sec.10F-ssec.4) In this section— relevant transaction , for a project trust or retention trust— means an activity or event that affects the financial position and value of interests in the trust; and includes— for a project trust— a claimant giving a payment claim under section 75 of the Act ; and a respondent giving a claimant a payment schedule under section 76 of the Act ; and any other activity or event that affects a claimant’s entitlement to a progress payment; and for a retention trust— withholding an amount from payment to a beneficiary; and an activity or event that affects the beneficiary’s entitlement to the amount withheld.

(a) ledger accounts kept in accordance with subsection (2) ; and
(b) monthly reconciliation statements prepared in accordance with subsection (3) showing that the ledger accounts correctly record relevant transactions for the trust.
(a) the ledger accounts for the trust must be kept separately from the ledger accounts for any other trust and from any other accounting record;
(b) each relevant transaction for the trust must be recorded in the ledger accounts within 3 business days after the transaction occurs;
(c) there must be separate ledger accounts for the following— (i) each beneficiary other than the trustee; (ii) the trustee; (iii) the trust account;
(i) each beneficiary other than the trustee;
(ii) the trustee;
(iii) the trust account;
(d) before an electronic system used to keep the ledger accounts is changed or records are archived or deleted from the system, steps must be taken to ensure that the records remain accessible in a readable form.
(i) each beneficiary other than the trustee;
(ii) the trustee;
(iii) the trust account;
(a) must be prepared within 5 business days after the end of each month; and
(b) must show a trial balance of the ledger accounts at the end of the month confirming that the total of debit balances equals the total of credit balances; and
(c) must show that the balance in the trust account ledger account at the end of the month is the same as the balance shown in the financial institution statement for the trust account at the end of the month.
(a) means an activity or event that affects the financial position and value of interests in the trust; and
(b) includes— (i) for a project trust— (A) a claimant giving a payment claim under section 75 of the Act ; and (B) a respondent giving a claimant a payment schedule under section 76 of the Act ; and (C) any other activity or event that affects a claimant’s entitlement to a progress payment; and (ii) for a retention trust— (A) withholding an amount from payment to a beneficiary; and (B) an activity or event that affects the beneficiary’s entitlement to the amount withheld.
(i) for a project trust— (A) a claimant giving a payment claim under section 75 of the Act ; and (B) a respondent giving a claimant a payment schedule under section 76 of the Act ; and (C) any other activity or event that affects a claimant’s entitlement to a progress payment; and
(A) a claimant giving a payment claim under section 75 of the Act ; and
(B) a respondent giving a claimant a payment schedule under section 76 of the Act ; and
(C) any other activity or event that affects a claimant’s entitlement to a progress payment; and
(ii) for a retention trust— (A) withholding an amount from payment to a beneficiary; and (B) an activity or event that affects the beneficiary’s entitlement to the amount withheld.
(A) withholding an amount from payment to a beneficiary; and
(B) an activity or event that affects the beneficiary’s entitlement to the amount withheld.
(i) for a project trust— (A) a claimant giving a payment claim under section 75 of the Act ; and (B) a respondent giving a claimant a payment schedule under section 76 of the Act ; and (C) any other activity or event that affects a claimant’s entitlement to a progress payment; and
(A) a claimant giving a payment claim under section 75 of the Act ; and
(B) a respondent giving a claimant a payment schedule under section 76 of the Act ; and
(C) any other activity or event that affects a claimant’s entitlement to a progress payment; and
(ii) for a retention trust— (A) withholding an amount from payment to a beneficiary; and (B) an activity or event that affects the beneficiary’s entitlement to the amount withheld.
(A) withholding an amount from payment to a beneficiary; and
(B) an activity or event that affects the beneficiary’s entitlement to the amount withheld.
(A) a claimant giving a payment claim under section 75 of the Act ; and
(B) a respondent giving a claimant a payment schedule under section 76 of the Act ; and
(C) any other activity or event that affects a claimant’s entitlement to a progress payment; and
(A) withholding an amount from payment to a beneficiary; and
(B) an activity or event that affects the beneficiary’s entitlement to the amount withheld.

sec.10G

Other trust records— Act , s 52

sec.10G Other trust records— Act , s 52

For section 52 (a) of the Act , the following records are also prescribed for a project trust or retention trust— each financial institution statement for the trust account relied on for a reconciliation; each payment instruction directing payment from the trust account; each notice received or given under the Act by the trustee; for a project trust— documents comprising or evidencing each of the following— the project trust contract; each project trust subcontract for the project trust contract; each amendment of the project trust contract or a project trust subcontract for the project trust contract; and each payment claim for a payment under a contract mentioned in subparagraph (i) ; and each payment schedule responding to a payment claim mentioned in subparagraph (ii) . s 10G ins 2020 SL No. 241 s 15 sub 2024 SL No. 85 s 6

(a) each financial institution statement for the trust account relied on for a reconciliation;
(b) each payment instruction directing payment from the trust account;
(c) each notice received or given under the Act by the trustee;
(d) for a project trust— (i) documents comprising or evidencing each of the following— (A) the project trust contract; (B) each project trust subcontract for the project trust contract; (C) each amendment of the project trust contract or a project trust subcontract for the project trust contract; and (ii) each payment claim for a payment under a contract mentioned in subparagraph (i) ; and (iii) each payment schedule responding to a payment claim mentioned in subparagraph (ii) .
(i) documents comprising or evidencing each of the following— (A) the project trust contract; (B) each project trust subcontract for the project trust contract; (C) each amendment of the project trust contract or a project trust subcontract for the project trust contract; and
(A) the project trust contract;
(B) each project trust subcontract for the project trust contract;
(C) each amendment of the project trust contract or a project trust subcontract for the project trust contract; and
(ii) each payment claim for a payment under a contract mentioned in subparagraph (i) ; and
(iii) each payment schedule responding to a payment claim mentioned in subparagraph (ii) .
(i) documents comprising or evidencing each of the following— (A) the project trust contract; (B) each project trust subcontract for the project trust contract; (C) each amendment of the project trust contract or a project trust subcontract for the project trust contract; and
(A) the project trust contract;
(B) each project trust subcontract for the project trust contract;
(C) each amendment of the project trust contract or a project trust subcontract for the project trust contract; and
(ii) each payment claim for a payment under a contract mentioned in subparagraph (i) ; and
(iii) each payment schedule responding to a payment claim mentioned in subparagraph (ii) .
(A) the project trust contract;
(B) each project trust subcontract for the project trust contract;
(C) each amendment of the project trust contract or a project trust subcontract for the project trust contract; and

pt.2-div.5

Oversight powers

sec.10H

Information for direction to trustee— Act , s 53B

sec.10H Information for direction to trustee— Act , s 53B

For section 53B (3) of the Act , the following information is prescribed— that the direction is given under section 53B of the Act ; the following details of the trust account to which the direction relates— the name of the account; the name of the financial institution where the account is kept; the identifying number of the financial institution (BSB) where the account is kept; the account number for the account; the period within which the direction must be complied with ; the reason for giving the direction . s 10H ins 2020 SL No. 241 s 15

(a) that the direction is given under section 53B of the Act ;
(b) the following details of the trust account to which the direction relates— (i) the name of the account; (ii) the name of the financial institution where the account is kept; (iii) the identifying number of the financial institution (BSB) where the account is kept; (iv) the account number for the account;
(i) the name of the account;
(ii) the name of the financial institution where the account is kept;
(iii) the identifying number of the financial institution (BSB) where the account is kept;
(iv) the account number for the account;
(c) the period within which the direction must be complied with ;
(d) the reason for giving the direction .
(i) the name of the account;
(ii) the name of the financial institution where the account is kept;
(iii) the identifying number of the financial institution (BSB) where the account is kept;
(iv) the account number for the account;

pt.2-div.6

Financial institutions

sec.10I

Agreements between commission and financial institutions— Act , s 55

sec.10I Agreements between commission and financial institutions— Act , s 55

For section 55 (3) (c) of the Act , the following information is prescribed— arrangements for giving information to the commissioner about account details; arrangements for giving information to the commissioner when a trust account has been opened, closed, transferred or had it’s name changed; how information to which the agreement applies is to be given to the commissioner; the frequency with which information to which the agreement applies must be given to the commissioner. s 10I ins 2020 SL No. 241 s 15

(a) arrangements for giving information to the commissioner about account details;
(b) arrangements for giving information to the commissioner when a trust account has been opened, closed, transferred or had it’s name changed;
(c) how information to which the agreement applies is to be given to the commissioner;
(d) the frequency with which information to which the agreement applies must be given to the commissioner.

sec.10J

Information for direction to financial institution— Act , s 55C

sec.10J Information for direction to financial institution— Act , s 55C

For section 55C (2) of the Act , the following information is prescribed— that the direction is given under section 55C of the Act ; the following details of the trust account to which the direction relates— the name of the account; the identifying number of the financial institution (BSB) where the account is kept; the account number for the account; the period for which the direction applies . s 10J ins 2020 SL No. 241 s 15

(a) that the direction is given under section 55C of the Act ;
(b) the following details of the trust account to which the direction relates— (i) the name of the account; (ii) the identifying number of the financial institution (BSB) where the account is kept; (iii) the account number for the account;
(i) the name of the account;
(ii) the identifying number of the financial institution (BSB) where the account is kept;
(iii) the account number for the account;
(c) the period for which the direction applies .
(i) the name of the account;
(ii) the identifying number of the financial institution (BSB) where the account is kept;
(iii) the account number for the account;

pt.2-div.7

sec.10K

Section sec.10K

s 10K ins 2020 SL No. 241 s 15 amd 2022 Act No. 11 s 68 sch 1 om 2024 SL No. 85 s 7

sec.10L

Section sec.10L

s 10L ins 2020 SL No. 241 s 15 amd 2022 Act No. 11 s 68 sch 1 om 2024 SL No. 85 s 7

pt.3

Registrar’s policies and code of conduct for adjudicators

sec.11

Approval of registrar’s policies— Act , s 155

sec.11 Approval of registrar’s policies— Act , s 155

For section 155 (2) of the Act — version 1 of the document called ‘Adjudicator referral policy’ and published on the commission’s website is approved as a policy about administering chapter 3 of the Act ; and version 1 of the document called ‘Continuing professional development for adjudicators policy’ and published on the commission’s website is approved as a policy about administering chapter 5 of the Act . s 11 ins 2018 SL No. 177 s 10 sub 2018 SL No. 177 s 16

(a) version 1 of the document called ‘Adjudicator referral policy’ and published on the commission’s website is approved as a policy about administering chapter 3 of the Act ; and
(b) version 1 of the document called ‘Continuing professional development for adjudicators policy’ and published on the commission’s website is approved as a policy about administering chapter 5 of the Act .

sec.12

Approval of code of conduct— Act , s 181

sec.12 Approval of code of conduct— Act , s 181

For section 181 (2) of the Act , version 1 of the document called ‘Code of conduct for adjudicators’ and published on the commission’s website is approved. s 12 ins 2018 SL No. 177 s 10

pt.4

Adjudication applications

sec.13

Conflicts of interest— Act , s 80

sec.13 Conflicts of interest— Act , s 80

For section 80 (b) of the Act , an adjudicator has a conflict of interest if— the adjudicator or a family member of the adjudicator— is, or is contracted to be, employed or otherwise engaged by the claimant or respondent for the adjudication application; or is an owner of a building, structure or land in relation to which construction work or the supply of related goods and services to which the adjudication application relates is being carried out; or is carrying out construction work or the supply of related goods and services in relation to a building, structure or land to which the adjudication application relates; or has a direct or indirect pecuniary or other interest in a matter to be considered during the adjudication that could conflict with the proper performance of the adjudicator in adjudicating the adjudication application; or the claimant or respondent for the adjudication application is a family member of the adjudicator. For subsection (1) , a person is a family member of the adjudicator if the person is— the adjudicator’s spouse; or a grandparent, parent, uncle, aunt, brother, sister, cousin, child, nephew, niece or grandchild of— the adjudicator; or the adjudicator’s spouse; or a spouse of a person mentioned in paragraph (b) . In this section— freehold land see the Land Act 1994 , schedule 6 . owner — of a building or structure, means the owner of the building or structure under the Building Act 1975 ; or of land, means the following— if the land is freehold land—the registered owner of the land; if the land is the subject of a lease registered under the Land Title Act 1994 —the lessee of the land; if the land is the subject of a lease registered under the Land Act 1994 —the lessee of the land; if the land is a reserve—the trustee of the reserve; if a person has occupation rights in relation to the land under a licence or permit—the licensee or permittee. reserve see the Land Act 1994 , schedule 6 . s 13 ins 2018 SL No. 177 s 10 (sec.13-ssec.1) For section 80 (b) of the Act , an adjudicator has a conflict of interest if— the adjudicator or a family member of the adjudicator— is, or is contracted to be, employed or otherwise engaged by the claimant or respondent for the adjudication application; or is an owner of a building, structure or land in relation to which construction work or the supply of related goods and services to which the adjudication application relates is being carried out; or is carrying out construction work or the supply of related goods and services in relation to a building, structure or land to which the adjudication application relates; or has a direct or indirect pecuniary or other interest in a matter to be considered during the adjudication that could conflict with the proper performance of the adjudicator in adjudicating the adjudication application; or the claimant or respondent for the adjudication application is a family member of the adjudicator. (sec.13-ssec.2) For subsection (1) , a person is a family member of the adjudicator if the person is— the adjudicator’s spouse; or a grandparent, parent, uncle, aunt, brother, sister, cousin, child, nephew, niece or grandchild of— the adjudicator; or the adjudicator’s spouse; or a spouse of a person mentioned in paragraph (b) . (sec.13-ssec.3) In this section— freehold land see the Land Act 1994 , schedule 6 . owner — of a building or structure, means the owner of the building or structure under the Building Act 1975 ; or of land, means the following— if the land is freehold land—the registered owner of the land; if the land is the subject of a lease registered under the Land Title Act 1994 —the lessee of the land; if the land is the subject of a lease registered under the Land Act 1994 —the lessee of the land; if the land is a reserve—the trustee of the reserve; if a person has occupation rights in relation to the land under a licence or permit—the licensee or permittee. reserve see the Land Act 1994 , schedule 6 .

(a) the adjudicator or a family member of the adjudicator— (i) is, or is contracted to be, employed or otherwise engaged by the claimant or respondent for the adjudication application; or (ii) is an owner of a building, structure or land in relation to which construction work or the supply of related goods and services to which the adjudication application relates is being carried out; or (iii) is carrying out construction work or the supply of related goods and services in relation to a building, structure or land to which the adjudication application relates; or (iv) has a direct or indirect pecuniary or other interest in a matter to be considered during the adjudication that could conflict with the proper performance of the adjudicator in adjudicating the adjudication application; or
(i) is, or is contracted to be, employed or otherwise engaged by the claimant or respondent for the adjudication application; or
(ii) is an owner of a building, structure or land in relation to which construction work or the supply of related goods and services to which the adjudication application relates is being carried out; or
(iii) is carrying out construction work or the supply of related goods and services in relation to a building, structure or land to which the adjudication application relates; or
(iv) has a direct or indirect pecuniary or other interest in a matter to be considered during the adjudication that could conflict with the proper performance of the adjudicator in adjudicating the adjudication application; or
(b) the claimant or respondent for the adjudication application is a family member of the adjudicator.
(i) is, or is contracted to be, employed or otherwise engaged by the claimant or respondent for the adjudication application; or
(ii) is an owner of a building, structure or land in relation to which construction work or the supply of related goods and services to which the adjudication application relates is being carried out; or
(iii) is carrying out construction work or the supply of related goods and services in relation to a building, structure or land to which the adjudication application relates; or
(iv) has a direct or indirect pecuniary or other interest in a matter to be considered during the adjudication that could conflict with the proper performance of the adjudicator in adjudicating the adjudication application; or
(a) the adjudicator’s spouse; or
(b) a grandparent, parent, uncle, aunt, brother, sister, cousin, child, nephew, niece or grandchild of— (i) the adjudicator; or (ii) the adjudicator’s spouse; or
(i) the adjudicator; or
(ii) the adjudicator’s spouse; or
(c) a spouse of a person mentioned in paragraph (b) .
(i) the adjudicator; or
(ii) the adjudicator’s spouse; or
(a) of a building or structure, means the owner of the building or structure under the Building Act 1975 ; or
(b) of land, means the following— (i) if the land is freehold land—the registered owner of the land; (ii) if the land is the subject of a lease registered under the Land Title Act 1994 —the lessee of the land; (iii) if the land is the subject of a lease registered under the Land Act 1994 —the lessee of the land; (iv) if the land is a reserve—the trustee of the reserve; (v) if a person has occupation rights in relation to the land under a licence or permit—the licensee or permittee.
(i) if the land is freehold land—the registered owner of the land;
(ii) if the land is the subject of a lease registered under the Land Title Act 1994 —the lessee of the land;
(iii) if the land is the subject of a lease registered under the Land Act 1994 —the lessee of the land;
(iv) if the land is a reserve—the trustee of the reserve;
(v) if a person has occupation rights in relation to the land under a licence or permit—the licensee or permittee.
(i) if the land is freehold land—the registered owner of the land;
(ii) if the land is the subject of a lease registered under the Land Title Act 1994 —the lessee of the land;
(iii) if the land is the subject of a lease registered under the Land Act 1994 —the lessee of the land;
(iv) if the land is a reserve—the trustee of the reserve;
(v) if a person has occupation rights in relation to the land under a licence or permit—the licensee or permittee.

sec.14

Maximum fees and expenses for particular adjudication applications— Act , s 95

sec.14 Maximum fees and expenses for particular adjudication applications— Act , s 95

This section prescribes, for section 95 (2) of the Act , the maximum amount for fees and expenses an adjudicator is entitled to be paid for adjudicating an adjudication application relating to a payment claim for a progress payment of not more than $25,000. The maximum amount is— if the progress payment is not more than $5,000—$620; or if the progress payment is more than $5,000 but not more than $15,000—$930; or if the progress payment is more than $15,000 but not more than $20,000—$1,860; or if the progress payment is more than $20,000 but not more than $25,000—$2,070. To remove any doubt, it is declared that a maximum amount mentioned in subsection (2) includes both fees and expenses. s 14 ins 2018 SL No. 177 s 10 (sec.14-ssec.1) This section prescribes, for section 95 (2) of the Act , the maximum amount for fees and expenses an adjudicator is entitled to be paid for adjudicating an adjudication application relating to a payment claim for a progress payment of not more than $25,000. (sec.14-ssec.2) The maximum amount is— if the progress payment is not more than $5,000—$620; or if the progress payment is more than $5,000 but not more than $15,000—$930; or if the progress payment is more than $15,000 but not more than $20,000—$1,860; or if the progress payment is more than $20,000 but not more than $25,000—$2,070. (sec.14-ssec.3) To remove any doubt, it is declared that a maximum amount mentioned in subsection (2) includes both fees and expenses.

(a) if the progress payment is not more than $5,000—$620; or
(b) if the progress payment is more than $5,000 but not more than $15,000—$930; or
(c) if the progress payment is more than $15,000 but not more than $20,000—$1,860; or
(d) if the progress payment is more than $20,000 but not more than $25,000—$2,070.

sec.15

Time for lodgement— Act , s 201

sec.15 Time for lodgement— Act , s 201

For section 201 (2) (f) (i) of the Act , an adjudication application must be lodged with the registrar no later than 5p.m. on a business day. An application lodged after 5p.m. is taken to be lodged on the next business day. s 15 ins 2018 SL No. 177 s 10 (sec.15-ssec.1) For section 201 (2) (f) (i) of the Act , an adjudication application must be lodged with the registrar no later than 5p.m. on a business day. (sec.15-ssec.2) An application lodged after 5p.m. is taken to be lodged on the next business day.

sec.16

Procedures for processing adjudication applications— Act , s 201

sec.16 Procedures for processing adjudication applications— Act , s 201

This section prescribes, for section 201 (2) (f) (ii) of the Act , the procedure for the processing of adjudication applications by the registrar. The registrar must refer an adjudication application to a grade 2 adjudicator for decision if— the payment claim to be adjudicated is for a progress payment of more than $150,000; or the registrar considers the complexity of the application requires that it be decided by a grade 2 adjudicator. The registrar must refer an adjudication application relating to a payment claim for a progress payment of more than $25,000 but not more than $150,000 to— a grade 2 adjudicator; or a grade 1 adjudicator who has decided at least 3 adjudication applications relating to payment claims for progress payments of not more than $25,000. The registrar must refer an adjudication application relating to a payment claim for a progress payment of not more than $25,000 to a grade 1 adjudicator or a grade 2 adjudicator. s 16 ins 2018 SL No. 177 s 10 (sec.16-ssec.1) This section prescribes, for section 201 (2) (f) (ii) of the Act , the procedure for the processing of adjudication applications by the registrar. (sec.16-ssec.2) The registrar must refer an adjudication application to a grade 2 adjudicator for decision if— the payment claim to be adjudicated is for a progress payment of more than $150,000; or the registrar considers the complexity of the application requires that it be decided by a grade 2 adjudicator. (sec.16-ssec.3) The registrar must refer an adjudication application relating to a payment claim for a progress payment of more than $25,000 but not more than $150,000 to— a grade 2 adjudicator; or a grade 1 adjudicator who has decided at least 3 adjudication applications relating to payment claims for progress payments of not more than $25,000. (sec.16-ssec.4) The registrar must refer an adjudication application relating to a payment claim for a progress payment of not more than $25,000 to a grade 1 adjudicator or a grade 2 adjudicator.

(a) the payment claim to be adjudicated is for a progress payment of more than $150,000; or
(b) the registrar considers the complexity of the application requires that it be decided by a grade 2 adjudicator.
(a) a grade 2 adjudicator; or
(b) a grade 1 adjudicator who has decided at least 3 adjudication applications relating to payment claims for progress payments of not more than $25,000.

sec.17

Limitations on submissions and accompanying documents for particular adjudication applications— Act , s 201

sec.17 Limitations on submissions and accompanying documents for particular adjudication applications— Act , s 201

This section prescribes, for section 201 (2) (g) of the Act , limitations on submissions and accompanying documents for— adjudication applications relating to payment claims for progress payments of not more than $25,000; and adjudication responses to adjudication applications mentioned in paragraph (a) . The submissions— must not exceed 10 pages in total; and if typed— must be set out in a document the margins of which are at least 2.54cm; and must be written in a font size of at least 10 point; and may only be accompanied by the following documents or copies of the documents— the payment claim to which the adjudication application relates; the construction contract to which the payment claim relates; a payment schedule given in response to the payment claim; if a party to the application gave the other party a document in support of the payment claim or the payment schedule at the time the claim or schedule was given to the other party—the supporting document; if a party to the application gave the other party a document relating to the construction contract—the related document; correspondence agreeing to a variation of a construction contract or an extension of time a program of work an expert report about a matter to which the payment claim relates; a statutory declaration about a matter to which the payment claim relates. In this section— expert report means a report made by a person dealing entirely or mainly with the issues the person is qualified to give expert evidence about. s 17 ins 2018 SL No. 177 s 10 (sec.17-ssec.1) This section prescribes, for section 201 (2) (g) of the Act , limitations on submissions and accompanying documents for— adjudication applications relating to payment claims for progress payments of not more than $25,000; and adjudication responses to adjudication applications mentioned in paragraph (a) . (sec.17-ssec.2) The submissions— must not exceed 10 pages in total; and if typed— must be set out in a document the margins of which are at least 2.54cm; and must be written in a font size of at least 10 point; and may only be accompanied by the following documents or copies of the documents— the payment claim to which the adjudication application relates; the construction contract to which the payment claim relates; a payment schedule given in response to the payment claim; if a party to the application gave the other party a document in support of the payment claim or the payment schedule at the time the claim or schedule was given to the other party—the supporting document; if a party to the application gave the other party a document relating to the construction contract—the related document; correspondence agreeing to a variation of a construction contract or an extension of time a program of work an expert report about a matter to which the payment claim relates; a statutory declaration about a matter to which the payment claim relates. (sec.17-ssec.3) In this section— expert report means a report made by a person dealing entirely or mainly with the issues the person is qualified to give expert evidence about.

(a) adjudication applications relating to payment claims for progress payments of not more than $25,000; and
(b) adjudication responses to adjudication applications mentioned in paragraph (a) .
(a) must not exceed 10 pages in total; and
(b) if typed— (i) must be set out in a document the margins of which are at least 2.54cm; and (ii) must be written in a font size of at least 10 point; and
(i) must be set out in a document the margins of which are at least 2.54cm; and
(ii) must be written in a font size of at least 10 point; and
(c) may only be accompanied by the following documents or copies of the documents— (i) the payment claim to which the adjudication application relates; (ii) the construction contract to which the payment claim relates; (iii) a payment schedule given in response to the payment claim; (iv) if a party to the application gave the other party a document in support of the payment claim or the payment schedule at the time the claim or schedule was given to the other party—the supporting document; (v) if a party to the application gave the other party a document relating to the construction contract—the related document; Examples— • correspondence agreeing to a variation of a construction contract or an extension of time • a program of work (vi) an expert report about a matter to which the payment claim relates; (vii) a statutory declaration about a matter to which the payment claim relates.
(i) the payment claim to which the adjudication application relates;
(ii) the construction contract to which the payment claim relates;
(iii) a payment schedule given in response to the payment claim;
(iv) if a party to the application gave the other party a document in support of the payment claim or the payment schedule at the time the claim or schedule was given to the other party—the supporting document;
(v) if a party to the application gave the other party a document relating to the construction contract—the related document; Examples— • correspondence agreeing to a variation of a construction contract or an extension of time • a program of work
• correspondence agreeing to a variation of a construction contract or an extension of time
• a program of work
(vi) an expert report about a matter to which the payment claim relates;
(vii) a statutory declaration about a matter to which the payment claim relates.
(i) must be set out in a document the margins of which are at least 2.54cm; and
(ii) must be written in a font size of at least 10 point; and
(i) the payment claim to which the adjudication application relates;
(ii) the construction contract to which the payment claim relates;
(iii) a payment schedule given in response to the payment claim;
(iv) if a party to the application gave the other party a document in support of the payment claim or the payment schedule at the time the claim or schedule was given to the other party—the supporting document;
(v) if a party to the application gave the other party a document relating to the construction contract—the related document; Examples— • correspondence agreeing to a variation of a construction contract or an extension of time • a program of work
• correspondence agreeing to a variation of a construction contract or an extension of time
• a program of work
(vi) an expert report about a matter to which the payment claim relates;
(vii) a statutory declaration about a matter to which the payment claim relates.
• correspondence agreeing to a variation of a construction contract or an extension of time
• a program of work

pt.5

Adjudicators

pt.5-div.1

Adjudication qualification

sec.18

Adjudication qualification— Act , s 201

sec.18 Adjudication qualification— Act , s 201

The following matters are prescribed, for section 201 (2) (b) of the Act , for an adjudication qualification— the name of the qualification is Certificate in Adjudication; a body mentioned in schedule 1 , part 1 may issue the qualification; the adjudication competency to be achieved is completion of the course called ‘Building Industry Fairness (Security of Payment) Adjudication’; the elements that must be successfully completed are the elements mentioned in schedule 1 , part 2 . s 18 ins 2018 SL No. 177 s 10

(a) the name of the qualification is Certificate in Adjudication;
(b) a body mentioned in schedule 1 , part 1 may issue the qualification;
(c) the adjudication competency to be achieved is completion of the course called ‘Building Industry Fairness (Security of Payment) Adjudication’;
(d) the elements that must be successfully completed are the elements mentioned in schedule 1 , part 2 .

pt.5-div.2

Grading

sec.19

Application of division— Act , s 201

sec.19 Application of division— Act , s 201

This division prescribes the grading of adjudicators for section 201 (2) (c) of the Act . s 19 ins 2018 SL No. 177 s 10

sec.20

Eligibility to be grade 2 adjudicator

sec.20 Eligibility to be grade 2 adjudicator

A person is eligible to be a grade 2 adjudicator if— both of the following apply— the person has, as an adjudicator, decided at least 10 adjudication applications; at least 5 of the applications related to a payment claim for a progress payment of more than $25,000; or the registrar considers the person’s experience is equivalent to meeting the requirements of paragraph (a) . s 20 ins 2018 SL No. 177 s 10

(a) both of the following apply— (i) the person has, as an adjudicator, decided at least 10 adjudication applications; (ii) at least 5 of the applications related to a payment claim for a progress payment of more than $25,000; or
(i) the person has, as an adjudicator, decided at least 10 adjudication applications;
(ii) at least 5 of the applications related to a payment claim for a progress payment of more than $25,000; or
(b) the registrar considers the person’s experience is equivalent to meeting the requirements of paragraph (a) .
(i) the person has, as an adjudicator, decided at least 10 adjudication applications;
(ii) at least 5 of the applications related to a payment claim for a progress payment of more than $25,000; or

sec.21

Grade of adjudicator on initial registration

sec.21 Grade of adjudicator on initial registration

On the day an adjudicator’s registration first becomes effective, the adjudicator is a grade 1 adjudicator. However, if the adjudicator is eligible to be a grade 2 adjudicator under section 20 , the registrar must give the adjudicator written notice stating the registrar proposes to grade the adjudicator as a grade 2 adjudicator. s 21 ins 2018 SL No. 177 s 10 (sec.21-ssec.1) On the day an adjudicator’s registration first becomes effective, the adjudicator is a grade 1 adjudicator. (sec.21-ssec.2) However, if the adjudicator is eligible to be a grade 2 adjudicator under section 20 , the registrar must give the adjudicator written notice stating the registrar proposes to grade the adjudicator as a grade 2 adjudicator.

sec.22

Review of grade 1 adjudicators

sec.22 Review of grade 1 adjudicators

The registrar must review the grade of each grade 1 adjudicator at least once every 12 months. The registrar must, after conducting the review, give the adjudicator written notice stating— if the adjudicator is eligible to be a grade 2 adjudicator under section 20 —the registrar proposes to grade the adjudicator as a grade 2 adjudicator; or otherwise—the adjudicator continues to be a grade 1 adjudicator. s 22 ins 2018 SL No. 177 s 10 (sec.22-ssec.1) The registrar must review the grade of each grade 1 adjudicator at least once every 12 months. (sec.22-ssec.2) The registrar must, after conducting the review, give the adjudicator written notice stating— if the adjudicator is eligible to be a grade 2 adjudicator under section 20 —the registrar proposes to grade the adjudicator as a grade 2 adjudicator; or otherwise—the adjudicator continues to be a grade 1 adjudicator.

(a) if the adjudicator is eligible to be a grade 2 adjudicator under section 20 —the registrar proposes to grade the adjudicator as a grade 2 adjudicator; or
(b) otherwise—the adjudicator continues to be a grade 1 adjudicator.

sec.23

Adjudicator may decline proposed grading

sec.23 Adjudicator may decline proposed grading

An adjudicator may, within 14 days after being given a written notice under section 21 (2) or 22 (2) (a) , decline the proposed grading by written notice to the registrar. s 23 ins 2018 SL No. 177 s 10

sec.24

Grading

sec.24 Grading

The registrar must grade a grade 1 adjudicator as a grade 2 adjudicator if— the registrar has given the adjudicator a written notice under section 21 (2) or 22 (2) (a) ; and the adjudicator does not decline the proposed grading mentioned in the notice under section 23 . The registrar must confirm the grading of a grade 1 adjudicator remains unchanged if— the registrar gives the adjudicator a written notice under section 22 (2) (b) ; or the adjudicator declines a proposed grading under section 23 . The registrar must give the adjudicator written notice of the grading or confirmation. s 24 ins 2018 SL No. 177 s 10 (sec.24-ssec.1) The registrar must grade a grade 1 adjudicator as a grade 2 adjudicator if— the registrar has given the adjudicator a written notice under section 21 (2) or 22 (2) (a) ; and the adjudicator does not decline the proposed grading mentioned in the notice under section 23 . (sec.24-ssec.2) The registrar must confirm the grading of a grade 1 adjudicator remains unchanged if— the registrar gives the adjudicator a written notice under section 22 (2) (b) ; or the adjudicator declines a proposed grading under section 23 . (sec.24-ssec.3) The registrar must give the adjudicator written notice of the grading or confirmation.

(a) the registrar has given the adjudicator a written notice under section 21 (2) or 22 (2) (a) ; and
(b) the adjudicator does not decline the proposed grading mentioned in the notice under section 23 .
(a) the registrar gives the adjudicator a written notice under section 22 (2) (b) ; or
(b) the adjudicator declines a proposed grading under section 23 .

sec.25

Change of grade by agreement

sec.25 Change of grade by agreement

The registrar may, with a grade 2 adjudicator’s agreement, grade the adjudicator as a grade 1 adjudicator at any time. s 25 ins 2018 SL No. 177 s 10

pt.5-div.3

Continuing professional development

sec.26

Application of division— Act , ss 165 and 201

sec.26 Application of division— Act , ss 165 and 201

This division prescribes, for sections 165 (1) (b) and 201 (2) (d) of the Act , continuing professional development for adjudicators. s 26 ins 2018 SL No. 177 s 17

sec.27

Requirement to accumulate CPD points

sec.27 Requirement to accumulate CPD points

An adjudicator must accumulate 10 CPD points in each CPD year. CPD points are points an adjudicator accumulates by completing CPD activities. Of the 10 CPD points required to be accumulated for a CPD year, at least 3 of the CPD points must be accumulated by completing core CPD activities. This section is subject to section 30 and subdivision 3 . s 27 ins 2018 SL No. 177 s 17 (sec.27-ssec.1) An adjudicator must accumulate 10 CPD points in each CPD year. (sec.27-ssec.2) CPD points are points an adjudicator accumulates by completing CPD activities. (sec.27-ssec.3) Of the 10 CPD points required to be accumulated for a CPD year, at least 3 of the CPD points must be accumulated by completing core CPD activities. (sec.27-ssec.4) This section is subject to section 30 and subdivision 3 .

sec.28

CPD activities and CPD points

sec.28 CPD activities and CPD points

Each of the following is a CPD activity — an activity identified as a CPD activity in the CPD policy; another activity the registrar considers to be equivalent to an activity mentioned in paragraph (a) . A core CPD activity is a CPD activity that is identified as a core CPD activity in the CPD policy. The CPD policy must state the number of CPD points accumulated for completing each CPD activity mentioned in subsection (1) (a) . The completion of an activity mentioned in subsection (1) (b) accumulates the same number of CPD points as are accumulated for the CPD activity mentioned in subsection (1) (a) to which the activity is considered equivalent. s 28 ins 2018 SL No. 177 s 17 (sec.28-ssec.1) Each of the following is a CPD activity — an activity identified as a CPD activity in the CPD policy; another activity the registrar considers to be equivalent to an activity mentioned in paragraph (a) . (sec.28-ssec.2) A core CPD activity is a CPD activity that is identified as a core CPD activity in the CPD policy. (sec.28-ssec.3) The CPD policy must state the number of CPD points accumulated for completing each CPD activity mentioned in subsection (1) (a) . (sec.28-ssec.4) The completion of an activity mentioned in subsection (1) (b) accumulates the same number of CPD points as are accumulated for the CPD activity mentioned in subsection (1) (a) to which the activity is considered equivalent.

(a) an activity identified as a CPD activity in the CPD policy;
(b) another activity the registrar considers to be equivalent to an activity mentioned in paragraph (a) .

sec.29

CPD points accumulated in last quarter of CPD year

sec.29 CPD points accumulated in last quarter of CPD year

This section applies if, in the last quarter of a CPD year, an adjudicator accumulates a CPD point (an excess CPD point ) that brings the total number of CPD points accumulated by the adjudicator for the year to more than 10. The excess CPD point is taken to be accumulated for completing a CPD activity of the same type in the following CPD year. In this section— last quarter , of a CPD year, means the 3-month period starting on 1 January in that year. s 29 ins 2018 SL No. 177 s 17 (sec.29-ssec.1) This section applies if, in the last quarter of a CPD year, an adjudicator accumulates a CPD point (an excess CPD point ) that brings the total number of CPD points accumulated by the adjudicator for the year to more than 10. (sec.29-ssec.2) The excess CPD point is taken to be accumulated for completing a CPD activity of the same type in the following CPD year. (sec.29-ssec.3) In this section— last quarter , of a CPD year, means the 3-month period starting on 1 January in that year.

sec.30

Registration of adjudicator during CPD year

sec.30 Registration of adjudicator during CPD year

This section applies to an adjudicator whose registration becomes effective in a month mentioned in column 1 of the table below. The adjudicator must, for the remainder of the CPD year in which the month occurs— accumulate a total number of CPD points equal to the number mentioned opposite the month in column 2; and of the total number of CPD points, accumulate at least the number of CPD points mentioned opposite the month in column 3 by completing core CPD activities. Column 1 Column 2 Column 3 Month Total CPD points CPD points for core CPD activities May 9 3 June 8 3 July 7 3 August 6 3 September 5 2 October 4 2 November 3 2 December 2 2 January 1 1 s 30 ins 2018 SL No. 177 s 17 (sec.30-ssec.1) This section applies to an adjudicator whose registration becomes effective in a month mentioned in column 1 of the table below. (sec.30-ssec.2) The adjudicator must, for the remainder of the CPD year in which the month occurs— accumulate a total number of CPD points equal to the number mentioned opposite the month in column 2; and of the total number of CPD points, accumulate at least the number of CPD points mentioned opposite the month in column 3 by completing core CPD activities. Column 1 Column 2 Column 3 Month Total CPD points CPD points for core CPD activities May 9 3 June 8 3 July 7 3 August 6 3 September 5 2 October 4 2 November 3 2 December 2 2 January 1 1

(a) accumulate a total number of CPD points equal to the number mentioned opposite the month in column 2; and
(b) of the total number of CPD points, accumulate at least the number of CPD points mentioned opposite the month in column 3 by completing core CPD activities.

sec.31

Grounds for application

sec.31 Grounds for application

An adjudicator may apply to the registrar for an extension of time to comply with, or an exemption from compliance with, section 27 (1) or (3) or section 30 on the ground that compliance is impracticable. the applicant has been unable to decide adjudication applications for a period because of extended parental leave, illness or employment obligations places offered for completing CPD activities in the relevant area are unavailable or fully booked s 31 ins 2018 SL No. 177 s 17

• the applicant has been unable to decide adjudication applications for a period because of extended parental leave, illness or employment obligations
• places offered for completing CPD activities in the relevant area are unavailable or fully booked

sec.32

Making application

sec.32 Making application

The application must— be in writing; and state whether the application is for— an extension of time; or an exemption; and be accompanied by sufficient information to establish the ground on which the application is made. s 32 ins 2018 SL No. 177 s 17

(a) be in writing; and
(b) state whether the application is for— (i) an extension of time; or (ii) an exemption; and
(i) an extension of time; or
(ii) an exemption; and
(c) be accompanied by sufficient information to establish the ground on which the application is made.
(i) an extension of time; or
(ii) an exemption; and

sec.33

Requirement for further information

sec.33 Requirement for further information

The registrar may, by written notice, require the applicant to give the registrar further information to establish the ground on which the application is made. The notice— must state— the information required; and the day, at least 14 days after the notice is given, by which the information must be given; and may state the way the information must be given. If the notice does not state the way the information must be given, the applicant must give the information in writing. If the adjudicator does not give the registrar the further information by the end of the day stated in the notice, the application is taken to be withdrawn. s 33 ins 2018 SL No. 177 s 17 (sec.33-ssec.1) The registrar may, by written notice, require the applicant to give the registrar further information to establish the ground on which the application is made. (sec.33-ssec.2) The notice— must state— the information required; and the day, at least 14 days after the notice is given, by which the information must be given; and may state the way the information must be given. (sec.33-ssec.3) If the notice does not state the way the information must be given, the applicant must give the information in writing. (sec.33-ssec.4) If the adjudicator does not give the registrar the further information by the end of the day stated in the notice, the application is taken to be withdrawn.

(a) must state— (i) the information required; and (ii) the day, at least 14 days after the notice is given, by which the information must be given; and
(i) the information required; and
(ii) the day, at least 14 days after the notice is given, by which the information must be given; and
(b) may state the way the information must be given.
(i) the information required; and
(ii) the day, at least 14 days after the notice is given, by which the information must be given; and

sec.34

Decision on application

sec.34 Decision on application

The registrar must consider the application and decide to— for an application for an extension of time—grant, or refuse to grant, the extension; or for an application for an exemption—grant, or refuse to grant, the exemption. In deciding the application, the registrar— must consider any information given to the registrar under section 32 (c) or 33 ; and may consider anything else the registrar considers relevant. The registrar may grant an extension of time or an exemption only to the extent necessary on the basis of the ground on which the application was made. s 34 ins 2018 SL No. 177 s 17 (sec.34-ssec.1) The registrar must consider the application and decide to— for an application for an extension of time—grant, or refuse to grant, the extension; or for an application for an exemption—grant, or refuse to grant, the exemption. (sec.34-ssec.2) In deciding the application, the registrar— must consider any information given to the registrar under section 32 (c) or 33 ; and may consider anything else the registrar considers relevant. (sec.34-ssec.3) The registrar may grant an extension of time or an exemption only to the extent necessary on the basis of the ground on which the application was made.

(a) for an application for an extension of time—grant, or refuse to grant, the extension; or
(b) for an application for an exemption—grant, or refuse to grant, the exemption.
(a) must consider any information given to the registrar under section 32 (c) or 33 ; and
(b) may consider anything else the registrar considers relevant.

sec.35

Registrar may grant exemption on condition

sec.35 Registrar may grant exemption on condition

This section applies if the registrar grants an exemption because the applicant has been unable to decide adjudication applications for a period. The registrar may grant the exemption on the condition the adjudicator complete a stated number and type of CPD activities within a stated period after the adjudicator resumes deciding adjudication applications. s 35 ins 2018 SL No. 177 s 17 (sec.35-ssec.1) This section applies if the registrar grants an exemption because the applicant has been unable to decide adjudication applications for a period. (sec.35-ssec.2) The registrar may grant the exemption on the condition the adjudicator complete a stated number and type of CPD activities within a stated period after the adjudicator resumes deciding adjudication applications.

sec.36

Notice of decision

sec.36 Notice of decision

After deciding the application, the registrar must give the applicant written notice of— the decision; and for a decision to grant an exemption under section 35 (2) —the condition on which the exemption is granted. s 36 ins 2018 SL No. 177 s 17

(a) the decision; and
(b) for a decision to grant an exemption under section 35 (2) —the condition on which the exemption is granted.

sec.37

Record of CPD activities

sec.37 Record of CPD activities

An adjudicator must keep a record of each CPD activity completed by the adjudicator in a CPD year. The record must be in the approved form. The adjudicator must give the registrar a written copy of the record within 14 days after the CPD year ends. The registrar may, by written notice, require the adjudicator to give the registrar further information about the CPD activities. A notice given under subsection (4) — must state— the information required; and the time, not earlier than 14 days after the notice is given, by which the information must be given; and that, if the adjudicator does not comply with the notice, the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points; and may state the way the information must be given. If the notice does not state the way the information must be given, the adjudicator must give the information in writing. If the adjudicator does not comply with the notice— the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points under section 27 ; and the registrar must give the adjudicator written notice of the failure. s 37 ins 2018 SL No. 177 s 17 (sec.37-ssec.1) An adjudicator must keep a record of each CPD activity completed by the adjudicator in a CPD year. (sec.37-ssec.2) The record must be in the approved form. (sec.37-ssec.3) The adjudicator must give the registrar a written copy of the record within 14 days after the CPD year ends. (sec.37-ssec.4) The registrar may, by written notice, require the adjudicator to give the registrar further information about the CPD activities. (sec.37-ssec.5) A notice given under subsection (4) — must state— the information required; and the time, not earlier than 14 days after the notice is given, by which the information must be given; and that, if the adjudicator does not comply with the notice, the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points; and may state the way the information must be given. (sec.37-ssec.6) If the notice does not state the way the information must be given, the adjudicator must give the information in writing. (sec.37-ssec.7) If the adjudicator does not comply with the notice— the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points under section 27 ; and the registrar must give the adjudicator written notice of the failure.

(a) must state— (i) the information required; and (ii) the time, not earlier than 14 days after the notice is given, by which the information must be given; and (iii) that, if the adjudicator does not comply with the notice, the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points; and
(i) the information required; and
(ii) the time, not earlier than 14 days after the notice is given, by which the information must be given; and
(iii) that, if the adjudicator does not comply with the notice, the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points; and
(b) may state the way the information must be given.
(i) the information required; and
(ii) the time, not earlier than 14 days after the notice is given, by which the information must be given; and
(iii) that, if the adjudicator does not comply with the notice, the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points; and
(a) the adjudicator is taken to have failed to comply with the requirement to accumulate CPD points under section 27 ; and
(b) the registrar must give the adjudicator written notice of the failure.

pt.6

Miscellaneous

sec.38

Review of Act— Act , s 200A

sec.38 Review of Act— Act , s 200A

The Building and Construction Legislation (Non-conforming Building Products—Chain of Responsibility and Other Matters) Amendment Act 2017 is prescribed for the Act , section 200A (6) , definition 2017 suite of building and construction reforms , paragraph (c) . s 38 (prev s 12) reloc and renum 2018 SL No. 177 s 9

sec.39

Fees

sec.39 Fees

The fees payable under the Act are stated in schedule 2 . s 39 ins 2018 SL No. 177 s 12 sub 2022 SL No. 78 s 6

pt.7

Transitional provisions

pt.7-div.1

Transitional provisions for Building Industry Fairness (Security of Payment) and Other Legislation Amendment Regulation 2018

sec.40

Definition for division

sec.40 Definition for division

In this division— previous , in relation to a section, means as in force immediately before the commencement. s 40 ins 2018 SL No. 177 s 13 amd 2019 SL No. 252 s 5 (retro)

sec.41

Existing prescribed payments for deposits to project bank accounts for Act , s 28

sec.41 Existing prescribed payments for deposits to project bank accounts for Act , s 28

This section applies if, immediately before the commencement, a payment— was to be made because of an adjudication of a payment claim mentioned in previous section 6(1); and had not been made. The payment is prescribed as a payment for section 28 (e) of the Act . s 41 ins 2018 SL No. 177 s 13 (sec.41-ssec.1) This section applies if, immediately before the commencement, a payment— was to be made because of an adjudication of a payment claim mentioned in previous section 6(1); and had not been made. (sec.41-ssec.2) The payment is prescribed as a payment for section 28 (e) of the Act .

(a) was to be made because of an adjudication of a payment claim mentioned in previous section 6(1); and
(b) had not been made.

sec.42

Existing prescribed payments for withdrawals from project bank accounts for Act , s 31

sec.42 Existing prescribed payments for withdrawals from project bank accounts for Act , s 31

This section applies if, immediately before the commencement, a payment— was to be made because of an adjudication of a payment claim mentioned in previous section 7(1); and had not been made. The payment is prescribed as a payment for section 31 (1) (e) of the Act . s 42 ins 2018 SL No. 177 s 13 (sec.42-ssec.1) This section applies if, immediately before the commencement, a payment— was to be made because of an adjudication of a payment claim mentioned in previous section 7(1); and had not been made. (sec.42-ssec.2) The payment is prescribed as a payment for section 31 (1) (e) of the Act .

(a) was to be made because of an adjudication of a payment claim mentioned in previous section 7(1); and
(b) had not been made.

sec.43

Existing prescribed dispute resolution process for Act , s 34B

sec.43 Existing prescribed dispute resolution process for Act , s 34B

This section applies if, immediately before the commencement, an application for adjudication of a payment claim under the Building and Construction Industry Payments Act 2004 had been made but not decided. The adjudication is prescribed as a dispute resolution process for the Act , section 34B , definition dispute resolution process . s 43 ins 2018 SL No. 177 s 13 (sec.43-ssec.1) This section applies if, immediately before the commencement, an application for adjudication of a payment claim under the Building and Construction Industry Payments Act 2004 had been made but not decided. (sec.43-ssec.2) The adjudication is prescribed as a dispute resolution process for the Act , section 34B , definition dispute resolution process .

sec.44

Grading of existing adjudicators

sec.44 Grading of existing adjudicators

This section applies to a person whose registration as an adjudicator is continued under section 204 of the Act . The person is taken to be— if section 20(a) or (b) applies in relation to the adjudicator—a grade 2 adjudicator; or otherwise—a grade 1 adjudicator. s 44 ins 2018 SL No. 177 s 13 (sec.44-ssec.1) This section applies to a person whose registration as an adjudicator is continued under section 204 of the Act . (sec.44-ssec.2) The person is taken to be— if section 20(a) or (b) applies in relation to the adjudicator—a grade 2 adjudicator; or otherwise—a grade 1 adjudicator.

(a) if section 20(a) or (b) applies in relation to the adjudicator—a grade 2 adjudicator; or
(b) otherwise—a grade 1 adjudicator.

sec.45

Mandatory training for existing adjudicators— Act , s 165

sec.45 Mandatory training for existing adjudicators— Act , s 165

This section prescribes, for section 165 (1) (c) of the Act , the prescribed mandatory training for an adjudicator mentioned in section 44(1). The mandatory training is completion, by 1 April 2019, of the training course called ‘Transitionary training for registered adjudicators’, approved by the commission and published on the commission’s website. s 45 ins 2018 SL No. 177 s 13 (sec.45-ssec.1) This section prescribes, for section 165 (1) (c) of the Act , the prescribed mandatory training for an adjudicator mentioned in section 44(1). (sec.45-ssec.2) The mandatory training is completion, by 1 April 2019, of the training course called ‘Transitionary training for registered adjudicators’, approved by the commission and published on the commission’s website.

sec.46

Accumulation of CPD points for mandatory training under s 45

sec.46 Accumulation of CPD points for mandatory training under s 45

An adjudicator mentioned in section 44(1) who completes the mandatory training mentioned in section 45— accumulates 1 CPD point for the CPD year starting on 1 April 2019; and is taken to have accumulated the CPD point by completing a core CPD activity. However, the adjudicator can not accumulate further CPD points for completing the mandatory training more than once. s 46 ins 2018 SL No. 177 s 18 (sec.46-ssec.1) An adjudicator mentioned in section 44(1) who completes the mandatory training mentioned in section 45— accumulates 1 CPD point for the CPD year starting on 1 April 2019; and is taken to have accumulated the CPD point by completing a core CPD activity. (sec.46-ssec.2) However, the adjudicator can not accumulate further CPD points for completing the mandatory training more than once.

(a) accumulates 1 CPD point for the CPD year starting on 1 April 2019; and
(b) is taken to have accumulated the CPD point by completing a core CPD activity.

pt.7-div.2

Transitional provision for Queensland Building and Construction Commission and Other Legislation Amendment Regulation 2019

sec.47

Application fees for particular adjudication applications

sec.47 Application fees for particular adjudication applications

This section applies if— a claimant made an adjudication application during the relevant period; and the claimant paid the fee for the application stated in previous schedule 2, item 1; and the amending regulation increased the application fee for the application. The claimant is taken to have paid the increased application fee for the adjudication application. In this section— amending regulation means the Queensland Building and Construction Commission and Other Legislation Amendment Regulation 2019 . previous schedule 2, item 1 means schedule 2, item 1 as in force from time to time before its amendment by the amending regulation. relevant period means the period starting on 1 July 2019 and ending on the day the amending regulation is notified. s 47 ins 2019 SL No. 252 s 6 (retro) (sec.47-ssec.1) This section applies if— a claimant made an adjudication application during the relevant period; and the claimant paid the fee for the application stated in previous schedule 2, item 1; and the amending regulation increased the application fee for the application. (sec.47-ssec.2) The claimant is taken to have paid the increased application fee for the adjudication application. (sec.47-ssec.3) In this section— amending regulation means the Queensland Building and Construction Commission and Other Legislation Amendment Regulation 2019 . previous schedule 2, item 1 means schedule 2, item 1 as in force from time to time before its amendment by the amending regulation. relevant period means the period starting on 1 July 2019 and ending on the day the amending regulation is notified.

(a) a claimant made an adjudication application during the relevant period; and
(b) the claimant paid the fee for the application stated in previous schedule 2, item 1; and
(c) the amending regulation increased the application fee for the application.

pt.7-div.3

Transitional provision for Building Industry Fairness (Security of Payment) and Other Legislation Amendment Regulation 2020

sec.48

Transitioning to new scheme— Act , s 211C

sec.48 Transitioning to new scheme— Act , s 211C

For section 211C (5) of the Act , this section prescribes the information to be included in a notice given to a beneficiary affected by the trustee transitioning to the new scheme. The information to be included in the notice is an electronic or hard copy of the trust account framework guide. However, subsection (2) does not apply if the trustee has previously given the information to the beneficiary. In this section— new scheme see section 211C (9) of the Act . trust account framework guide means the document, made by the commission, that explains the requirements of chapter 2 of the Act . s 48 ins 2020 SL No. 241 s 16 (sec.48-ssec.1) For section 211C (5) of the Act , this section prescribes the information to be included in a notice given to a beneficiary affected by the trustee transitioning to the new scheme. (sec.48-ssec.2) The information to be included in the notice is an electronic or hard copy of the trust account framework guide. (sec.48-ssec.3) However, subsection (2) does not apply if the trustee has previously given the information to the beneficiary. (sec.48-ssec.4) In this section— new scheme see section 211C (9) of the Act . trust account framework guide means the document, made by the commission, that explains the requirements of chapter 2 of the Act .

pt.7-div.4

Transitional provisions for Building Industry Fairness (Security of Payment) and Other Legislation Amendment Regulation 2024

sec.49

Existing trust account records— Act , s 52

sec.49 Existing trust account records— Act , s 52

This section applies in relation to a record that, immediately before the commencement— was mentioned in section 10F or 10G; and was required to be kept by the trustee for a project trust or retention trust. The record continues to be prescribed for section 52 (a) of the Act . s 49 ins 2024 SL No. 85 s 8 (sec.49-ssec.1) This section applies in relation to a record that, immediately before the commencement— was mentioned in section 10F or 10G; and was required to be kept by the trustee for a project trust or retention trust. (sec.49-ssec.2) The record continues to be prescribed for section 52 (a) of the Act .

(a) was mentioned in section 10F or 10G; and
(b) was required to be kept by the trustee for a project trust or retention trust.

sec.50

Changes affecting review of trust account

sec.50 Changes affecting review of trust account

If section 215B of the Act applies in relation to a review of the trust account for a project trust or retention trust, sections 10K and 10L as in force immediately before the commencement continue to apply as if the Building Industry Fairness (Security of Payment) and Other Legislation Amendment Regulation 2024 had not been made. s 50 ins 2024 SL No. 85 s 8

sch.1AA-pt.1

Notice about opening, closing, transferring or changing the name of project trust account— Act , s 18B

Notice about opening, closing, transferring or changing the name of project trust account— Act , s 18B

sch.1AA-pt.1-div.1

Notices given to contracting party

sch.1AA-sec.1

Notice to contracting party about opening project trust account

sch.1AA-sec.1 Notice to contracting party about opening project trust account

(a) the name of the trustee;
(b) the name of the account;
(c) the name of the financial institution where the account is kept;
(d) the identifying number of the financial institution (BSB) where the account is kept;
(e) the account number at the financial institution.

sch.1AA-sec.2

Notice to contracting party about changing name of project trust account

sch.1AA-sec.2 Notice to contracting party about changing name of project trust account

The following information must be included in the notice— the name of the trustee; the name of the account before the change; the name of the account after the change; the name of the financial institution where the account is kept; the identifying number of the financial institution (BSB) where the account is kept; the account number at the financial institution; the date the name of the account was changed.

(a) the name of the trustee;
(b) the name of the account before the change;
(c) the name of the account after the change;
(d) the name of the financial institution where the account is kept;
(e) the identifying number of the financial institution (BSB) where the account is kept;
(f) the account number at the financial institution;
(g) the date the name of the account was changed.

sch.1AA-sec.3

Notice to contracting party about closing project trust account

sch.1AA-sec.3 Notice to contracting party about closing project trust account

The following information must be included in the notice— the name of the trustee; the name of the account; the name of the financial institution where the account was kept; the identifying number of the financial institution (BSB) where the account was kept; the account number at the financial institution; the date the account was closed.

(a) the name of the trustee;
(b) the name of the account;
(c) the name of the financial institution where the account was kept;
(d) the identifying number of the financial institution (BSB) where the account was kept;
(e) the account number at the financial institution;
(f) the date the account was closed.

sch.1AA-sec.4

Notice to contracting party about transferring project trust account

sch.1AA-sec.4 Notice to contracting party about transferring project trust account

The following information must be included in the notice— the name of the trustee; the name of the account before the transfer; the name of the account after the transfer; the name of the financial institution where the account was kept before the transfer; the name of the financial institution where the account will be kept after the transfer; the identifying number of each financial institution (BSB) mentioned in paragraphs (d) and (e); the account number at each financial institution mentioned in paragraphs (d) and (e); the date the account was transferred; the date from which the new account is intended to be used.

(a) the name of the trustee;
(b) the name of the account before the transfer;
(c) the name of the account after the transfer;
(d) the name of the financial institution where the account was kept before the transfer;
(e) the name of the financial institution where the account will be kept after the transfer;
(f) the identifying number of each financial institution (BSB) mentioned in paragraphs (d) and (e);
(g) the account number at each financial institution mentioned in paragraphs (d) and (e);
(h) the date the account was transferred;
(i) the date from which the new account is intended to be used.

sch.1AA-pt.1-div.2

Notices given to commissioner

sch.1AA-sec.5

Notice to commissioner about opening project trust account

sch.1AA-sec.5 Notice to commissioner about opening project trust account

The following information must be included in the notice— the name of the trustee; the name of the account; the name of the financial institution where the account is kept; the identifying number of the financial institution (BSB) where the account is kept; the account number at the financial institution; the value of the project trust contract; the date the first subcontract for the project trust contract was entered into; the name of the contracting party as it appears on the project trust contract; the site address for the contracted work; a brief description of the contracted work; the date of practical completion as provided for under the project trust contract; the date the account was opened.

(a) the name of the trustee;
(b) the name of the account;
(c) the name of the financial institution where the account is kept;
(d) the identifying number of the financial institution (BSB) where the account is kept;
(e) the account number at the financial institution;
(f) the value of the project trust contract;
(g) the date the first subcontract for the project trust contract was entered into;
(h) the name of the contracting party as it appears on the project trust contract;
(i) the site address for the contracted work;
(j) a brief description of the contracted work;
(k) the date of practical completion as provided for under the project trust contract;
(l) the date the account was opened.

sch.1AA-sec.6

Notice to commissioner about changing name of project trust account

sch.1AA-sec.6 Notice to commissioner about changing name of project trust account

(a) the name of the trustee;
(b) the name of the account before the change;
(c) the name of the account after the change;
(d) the name of the financial institution where the account is kept;
(e) the identifying number of the financial institution (BSB) where the account is kept;
(f) the account number at the financial institution;
(g) the date the name of the account was changed.

sch.1AA-sec.7

Notice to commissioner about closing project trust account

sch.1AA-sec.7 Notice to commissioner about closing project trust account

(a) the name of the trustee;
(b) the name of the account;
(c) the name of the financial institution where the account was kept;
(d) the identifying number of the financial institution (BSB) where the account was kept;
(e) the account number at the financial institution;
(f) the date the account was closed.

sch.1AA-sec.8

Notice to commissioner about transferring project trust account

sch.1AA-sec.8 Notice to commissioner about transferring project trust account

(a) the name of the trustee;
(b) the name of the account before the transfer;
(c) the name of the account after the transfer;
(d) the name of the financial institution where the account was kept before the transfer;
(e) the name of the financial institution where the account will be kept after the transfer;
(f) the identifying number of each financial institution (BSB) mentioned in paragraphs (d) and (e);
(g) the account number at each financial institution mentioned in paragraphs (d) and (e);
(h) the date the account was transferred;
(i) the date from which the new account is intended to be used.

sch.1AA-pt.2

Notice about change of financial institution— Act , s 18C

Notice about change of financial institution— Act , s 18C

sch.1AA-sec.1-oc.2

Information for notice about change of financial institution

sch.1AA-sec.1-oc.2 Information for notice about change of financial institution

(a) the name of the trustee;
(b) the name of the account before the transfer;
(c) the name of the account after the transfer;
(d) the name of the financial institution where the account was kept before the transfer;
(e) the name of the financial institution where the account will be kept after the transfer;
(f) the identifying number of each financial institution (BSB) mentioned in paragraphs (d) and (e);
(g) the account number at each financial institution mentioned in paragraphs (d) and (e);
(h) the date the account was transferred;
(i) the date from which the new account is intended to be used.

sch.1AA-pt.3

Notice of project trust— Act , s 23

Notice of project trust— Act , s 23

sch.1AA-sec.1-oc.3

Notice of project trust

sch.1AA-sec.1-oc.3 Notice of project trust

The following information must be included in the notice— the name of the project trust account; the name of the financial institution where the project trust account is kept; the identifying number of the financial institution (BSB) where the project trust account is kept; the project trust account number at the financial institution; information identifying the contract to which the project trust relates.

(a) the name of the project trust account;
(b) the name of the financial institution where the project trust account is kept;
(c) the identifying number of the financial institution (BSB) where the project trust account is kept;
(d) the project trust account number at the financial institution;
(e) information identifying the contract to which the project trust relates.

sch.1AA-pt.4

Notice about particular withdrawals from project trust account— Act , s 23A

Notice about particular withdrawals from project trust account— Act , s 23A

sch.1AA-sec.1-oc.4

Notice about withdrawal to make a payment to a subcontractor beneficiary

sch.1AA-sec.1-oc.4 Notice about withdrawal to make a payment to a subcontractor beneficiary

The following information must be included in the notice— the amount that was or is to be paid to the beneficiary; identification of the payment claim for the payment, if any; the name of the account (the payment account ) the payment was or is to be paid to; the identifying number of the financial institution (BSB) where the payment account is kept; the account number, at the financial institution, for the payment account; the date the payment was or is to be paid.

(a) the amount that was or is to be paid to the beneficiary;
(b) identification of the payment claim for the payment, if any;
(c) the name of the account (the payment account ) the payment was or is to be paid to;
(d) the identifying number of the financial institution (BSB) where the payment account is kept;
(e) the account number, at the financial institution, for the payment account;
(f) the date the payment was or is to be paid.

sch.1AA-sec.2-oc.2

Notice about withdrawal to deposit an amount in a retention trust account for the benefit of a subcontractor beneficiary

sch.1AA-sec.2-oc.2 Notice about withdrawal to deposit an amount in a retention trust account for the benefit of a subcontractor beneficiary

The following information must be included in the notice— the amount to be deposited in the account; identification of the payment claim for the deposit, if any; the name of the account (the deposit account ) into which the deposit is to be made; the name of the financial institution where the deposit account is kept; the identifying number of the financial institution (BSB) where the deposit account is kept; the account number, at the financial institution, for the deposit account; the date the amount was or is to be deposited into the deposit account; the total retention amounts held in the account, when the notice is given, for the beneficiary under the contract to which the withdrawal relates.

(a) the amount to be deposited in the account;
(b) identification of the payment claim for the deposit, if any;
(c) the name of the account (the deposit account ) into which the deposit is to be made;
(d) the name of the financial institution where the deposit account is kept;
(e) the identifying number of the financial institution (BSB) where the deposit account is kept;
(f) the account number, at the financial institution, for the deposit account;
(g) the date the amount was or is to be deposited into the deposit account;
(h) the total retention amounts held in the account, when the notice is given, for the beneficiary under the contract to which the withdrawal relates.

sch.1AA-pt.5

Notice about opening, closing, transferring or changing the name of retention trust account— Act , s 34B

Notice about opening, closing, transferring or changing the name of retention trust account— Act , s 34B

sch.1AA-sec.1-oc.5

Notice about opening retention trust account

sch.1AA-sec.1-oc.5 Notice about opening retention trust account

(a) the name of the trustee;
(b) the name of the account;
(c) the name of the financial institution where the account is kept;
(d) the identifying number of the financial institution (BSB) where the account is kept;
(e) the account number at the financial institution;
(f) the date the account was opened.

sch.1AA-sec.2-oc.3

Notice about changing name of retention trust account

sch.1AA-sec.2-oc.3 Notice about changing name of retention trust account

(a) the name of the trustee;
(b) the name of the account before the change;
(c) the name of the account after the change;
(d) the name of the financial institution where the account is kept;
(e) the identifying number of the financial institution (BSB) where the account is kept;
(f) the account number at the financial institution;
(g) the date the name of the account was changed.

sch.1AA-sec.3-oc.2

Notice about closing retention trust account

sch.1AA-sec.3-oc.2 Notice about closing retention trust account

(a) the name of the trustee;
(b) the name of the account;
(c) the name of the financial institution where the account was kept;
(d) the identifying number of the financial institution (BSB) where the account was kept;
(e) the account number at the financial institution;
(f) the date the account was closed.

sch.1AA-sec.4-oc.2

Notice about transferring retention trust account

sch.1AA-sec.4-oc.2 Notice about transferring retention trust account

(a) the name of the trustee;
(b) the name of the account before the transfer;
(c) the name of the account after the transfer;
(d) the name of the financial institution where the account was kept before the transfer;
(e) the name of the financial institution where the account will be kept after the transfer;
(f) the identifying number of each financial institution (BSB) mentioned in paragraphs (d) and (e);
(g) the account number at each financial institution mentioned in paragraphs (d) and (e);
(h) the date the account was transferred;
(i) the date from which the new account is intended to be used.

sch.1AA-pt.6

Notice about change of financial institution— Act , s 34C

Notice about change of financial institution— Act , s 34C

sch.1AA-sec.1-oc.6

Information for notice about change of financial institution

sch.1AA-sec.1-oc.6 Information for notice about change of financial institution

The following information must be included in the notice— the name of the trustee; the name of the account before the transfer; the name of the account after the transfer; the name of the financial institution where the account was kept before the transfer; the name of the financial institution where the account will be kept after the transfer; the identifying number of each financial institution (BSB) mentioned in paragraphs (d) or (e); the account number at each financial institution mentioned in paragraphs (d) or (e); the date the account was transferred; the date from which the new account is intended to be used.

(a) the name of the trustee;
(b) the name of the account before the transfer;
(c) the name of the account after the transfer;
(d) the name of the financial institution where the account was kept before the transfer;
(e) the name of the financial institution where the account will be kept after the transfer;
(f) the identifying number of each financial institution (BSB) mentioned in paragraphs (d) or (e);
(g) the account number at each financial institution mentioned in paragraphs (d) or (e);
(h) the date the account was transferred;
(i) the date from which the new account is intended to be used.

sch.1AA-pt.7

Notice of retention trust— Act , s 40

Notice of retention trust— Act , s 40

sch.1AA-sec.1-oc.7

Information about notice of retention trust

sch.1AA-sec.1-oc.7 Information about notice of retention trust

The following information must be included in the notice— the name of the retention trust account; the name of the financial institution where the retention trust account is kept; the identifying number of the financial institution (BSB) where the retention trust account is kept; the retention trust account number at the financial institution; information identifying the contract to which the retention trust relates.

(a) the name of the retention trust account;
(b) the name of the financial institution where the retention trust account is kept;
(c) the identifying number of the financial institution (BSB) where the retention trust account is kept;
(d) the retention trust account number at the financial institution;
(e) information identifying the contract to which the retention trust relates.

sch.1AA-pt.8

Notice about deposits into or withdrawals from retention trust account— Act , s 40A

Notice about deposits into or withdrawals from retention trust account— Act , s 40A

sch.1AA-sec.1-oc.8

Notice about deposit of retention amount into retention trust account

sch.1AA-sec.1-oc.8 Notice about deposit of retention amount into retention trust account

The following information must be included in the notice— the amount to be deposited in the account; identification of the payment claim for the deposit, if any; the name of the account; the name of the financial institution where the account is kept; the identifying number of the financial institution (BSB) where the account is kept; the account number at the financial institution for the deposit account; the total retention amounts held in the account, when the notice is given, for the contracted party under the contract to which the deposit relates; the date the amount is deposited in the account.

(a) the amount to be deposited in the account;
(b) identification of the payment claim for the deposit, if any;
(c) the name of the account;
(d) the name of the financial institution where the account is kept;
(e) the identifying number of the financial institution (BSB) where the account is kept;
(f) the account number at the financial institution for the deposit account;
(g) the total retention amounts held in the account, when the notice is given, for the contracted party under the contract to which the deposit relates;
(h) the date the amount is deposited in the account.

sch.1AA-sec.2-oc.4

Notice about withdrawal of retention amount from retention trust account to pay contracted party

sch.1AA-sec.2-oc.4 Notice about withdrawal of retention amount from retention trust account to pay contracted party

The following information must be included in the notice— the amount to be paid; identification of the payment claim to which the withdrawal relates, if any; the name of the account (the payment account ) the amount is to be paid to; the identifying number of the financial institution (BSB) where the payment account is kept; the account number, at the financial institution, for the payment account; the total retention amounts held in the retention trust account, after the withdrawal, for the contracted party under the contract to which the withdrawal relates; the date the amount is to be paid.

(a) the amount to be paid;
(b) identification of the payment claim to which the withdrawal relates, if any;
(c) the name of the account (the payment account ) the amount is to be paid to;
(d) the identifying number of the financial institution (BSB) where the payment account is kept;
(e) the account number, at the financial institution, for the payment account;
(f) the total retention amounts held in the retention trust account, after the withdrawal, for the contracted party under the contract to which the withdrawal relates;
(g) the date the amount is to be paid.

sch.1AA-sec.3-oc.3

Notice about withdrawal of retention amount from retention trust account to pay someone other than contracted party

sch.1AA-sec.3-oc.3 Notice about withdrawal of retention amount from retention trust account to pay someone other than contracted party

The following information must be included in the notice— the amount to be paid; the reason for the payment; payment made to correct defects in the contracted work the total retention amounts held in the account, after the withdrawal, for the contracted party under the contract to which the withdrawal relates; the date the amount is to be paid.

(a) the amount to be paid;
(b) the reason for the payment; Example— payment made to correct defects in the contracted work
(c) the total retention amounts held in the account, after the withdrawal, for the contracted party under the contract to which the withdrawal relates;
(d) the date the amount is to be paid.

sch.1-pt.1

Body that may issue qualification

sch.1-pt.2

Elements to be completed to achieve competency

Source text: opening excerpt

Sourced from Queensland Legislation (legislation.qld.gov.au), CC BY 4.0.

pt.1 Introduction

Introduction

sec.1 Short title

This regulation may be cited as the Building Industry Fairness (Security of Payment) Regulation 2018 .

sec.2 Commencement

This regulation commences on 1 March 2018.

sec.3 Definitions

The dictionary in schedule 3 defines particular words used in this regulation. s 3 (prev s 2A) ins 2018 SL No. 177 s 4 renum 2018 SL No. 177 s 5

pt.2 Trusts

Trusts

pt.2-div.1 General

General

sec.4 Work included as project trust work— Act , s 8A

(a) the management and removal of scaffolding if the scaffolding is used for carrying out other project trust work;
(b) the construction, installation, alteration or repair of a swimming pool, whether associated with a building or not.

Deep Dive

What it does

Current sections

Introduction

Introduction

Short title

sec.1 Short title

Commencement

sec.2 Commencement

Definitions

sec.3 Definitions

Trusts

Trusts

General

General

Work included as project trust work— Act , s&#160;8A

sec.4 Work included as project trust work— Act , s 8A

Work that is not project trust work— Act , s&#160;8A

sec.5 Work that is not project trust work— Act , s 8A

Meaning of project trust subcontract — Act , s&#160;9A

sec.5A Meaning of project trust subcontract — Act , s 9A

Project trusts

Project trusts

Meaning of residence

sec.6 Meaning of residence

Residential construction work— Act , s&#160;15C

sec.7 Residential construction work— Act , s 15C

Information for notice about opening, closing, transferring or changing the name of project trust account— Act , s&#160;18B

sec.8 Information for notice about opening, closing, transferring or changing the name of project trust account— Act , s 18B

Information for notice about change of financial institution— Act , s&#160;18C

sec.9 Information for notice about change of financial institution— Act , s 18C

Information for notice of project trust— Act , s&#160;23

sec.10 Information for notice of project trust— Act , s 23

Information for notice about particular withdrawals from project trust account— Act , s&#160;23A

sec.10A Information for notice about particular withdrawals from project trust account— Act , s 23A

Retention trust account

Retention trust account

Information for notice about opening, closing, transferring or changing the name of retention trust account— Act , s&#160;34B

sec.10B Information for notice about opening, closing, transferring or changing the name of retention trust account— Act , s 34B

Information for notice about change of financial institution— Act , s&#160;34C

sec.10C Information for notice about change of financial institution— Act , s 34C

Information for notice of retention trust— Act , s&#160;40

sec.10D Information for notice of retention trust— Act , s 40

Information for notice about deposits to or withdrawals from retention trust account— Act , s&#160;40A

sec.10E Information for notice about deposits to or withdrawals from retention trust account— Act , s 40A

Section sec.10EA

Trust records

Trust records

Ledger accounts and reconciliation statements— Act , s&#160;52

sec.10F Ledger accounts and reconciliation statements— Act , s 52

Other trust records— Act , s&#160;52

sec.10G Other trust records— Act , s 52

Oversight powers

Oversight powers

Information for direction to trustee— Act , s&#160;53B

sec.10H Information for direction to trustee— Act , s 53B

Financial institutions

Financial institutions

Agreements between commission and financial institutions— Act , s&#160;55

sec.10I Agreements between commission and financial institutions— Act , s 55

Information for direction to financial institution— Act , s&#160;55C

sec.10J Information for direction to financial institution— Act , s 55C

Section sec.10K

Section sec.10L

Registrar’s policies and code of conduct for adjudicators

Registrar’s policies and code of conduct for adjudicators

Approval of registrar’s policies— Act , s&#160;155

sec.11 Approval of registrar’s policies— Act , s 155

Approval of code of conduct— Act , s&#160;181

sec.12 Approval of code of conduct— Act , s 181

Adjudication applications

Adjudication applications

Conflicts of interest— Act , s&#160;80

sec.13 Conflicts of interest— Act , s 80

Maximum fees and expenses for particular adjudication applications— Act , s&#160;95

sec.14 Maximum fees and expenses for particular adjudication applications— Act , s 95

Time for lodgement— Act , s&#160;201

sec.15 Time for lodgement— Act , s 201

Procedures for processing adjudication applications— Act , s&#160;201

sec.16 Procedures for processing adjudication applications— Act , s 201

Work included as project trust work— Act , s 8A

Work that is not project trust work— Act , s 8A

Meaning of project trust subcontract — Act , s 9A

Residential construction work— Act , s 15C

Information for notice about opening, closing, transferring or changing the name of project trust account— Act , s 18B

Information for notice about change of financial institution— Act , s 18C

Information for notice of project trust— Act , s 23

Information for notice about particular withdrawals from project trust account— Act , s 23A

Information for notice about opening, closing, transferring or changing the name of retention trust account— Act , s 34B

Information for notice about change of financial institution— Act , s 34C

Information for notice of retention trust— Act , s 40

Information for notice about deposits to or withdrawals from retention trust account— Act , s 40A

Ledger accounts and reconciliation statements— Act , s 52

Other trust records— Act , s 52

Information for direction to trustee— Act , s 53B

Agreements between commission and financial institutions— Act , s 55

Information for direction to financial institution— Act , s 55C

Approval of registrar’s policies— Act , s 155

Approval of code of conduct— Act , s 181

Conflicts of interest— Act , s 80

Maximum fees and expenses for particular adjudication applications— Act , s 95

Time for lodgement— Act , s 201

Procedures for processing adjudication applications— Act , s 201

Limitations on submissions and accompanying documents for particular adjudication applications— Act , s 201

Adjudication qualification— Act , s 201

Application of division— Act , s 201

Application of division— Act , ss 165 and 201

Review of Act— Act , s 200A

Existing prescribed payments for deposits to project bank accounts for Act , s 28

Existing prescribed payments for withdrawals from project bank accounts for Act , s 31

Existing prescribed dispute resolution process for Act , s 34B