Part 1 Preliminary

1 Short title

This Act may be cited as the Residential Building Work Contracts and Dispute Resolution Act 2016 .

2 Commencement

This Act commences on a day to be proclaimed.

3 Act binds Crown

This Act binds the Crown in right of Tasmania and, so far as the legislative power of Parliament permits, in all its other capacities.

Part 2 Interpretation

4 Definitions

(1)  In this Act, unless the contrary intention appears –

appropriate variation document means a variation document that complies with the formal requirements specified in section 18(2) ;

building includes a proposed building or part of a building and a building that is able to be relocated;

building contractor means a person who performs, has performed, or intends to perform, residential building work;

building site means a place where residential building work has been, is being, or is to be, performed;

business day means a day that is not a Saturday, a Sunday, a statutory holiday as defined in the Statutory Holidays Act 2000 or a public holiday throughout the State;

contract price, in relation to a residential building work contract, means the total amount payable under the contract for the performance of residential building work under the contract and includes –

(a) an amount in relation to labour and materials; and

(b) an amount the building contractor is entitled to receive and keep under the contract; and

(c) an amount the building contractor is entitled to receive under the contract for payment to another person;

cost-plus contract means a residential building work contract under which the amount the building contractor is to receive under the contract cannot be calculated when the contract is entered into;

date of practical completion, in relation to a residential building work contract, means the day by which –

(a) the residential building work to be performed under the contract is completed in compliance with the contract, including all plans and specifications for the work and all statutory requirements applying to the work; and

(b) the residential building work to be performed under the contract is completed without any defects or omissions, other than minor defects, or minor omissions, that will not unreasonably affect occupation; and

(c) if the owner claims there are minor defects or minor omissions – the building contractor has given the owner a defects document for the minor defects or minor omissions;

defects document, for a residential building work contract, means a document that –

(a) lists the minor defects, and minor omissions, in the residential building work performed under the contract, that the building contractor and the owner agree exist; and

(b) states when the building contractor is to remedy the minor defects and minor omissions referred to in paragraph (a) ; and

(c) lists the minor defects, and minor omissions, in the residential building work performed under the contract, that the owner claims exist and the building contractor does not agree exist; and

(d) is signed by the building contractor;

deposit, in relation to a residential building work contract, includes any payment for residential building work demanded or received by the building contractor before the residential building work begins to be performed under the contract;

[Section 4 Subsection (1) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017]

[Section 4 Subsection (1) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] Director means the Director of Building Control appointed under section 15 of the Building Act 2016 ;

fixed-price contract means a residential building work contract that is not a cost-plus contract;

Guide to Standards and Tolerances means a guide approved under section 82(1) ;

materials, in relation to residential building work, includes goods to be supplied and fitted or installed in the course of the residential building work;

member of a panel means –

(a) a member of a mediation panel who is appointed under section 49(2) ; and

(b) [Section 4 Subsection (1) amended by No. 9 of 2023, s. 50, Applied:01 Jul 2024]

NCC means the National Construction Code series, published by the Australian Building Codes Board, as varied or replaced from time to time;

owner means a person for whom residential building work is being, is to be, or has been, performed;

perform, in relation to residential building work, includes –

(a) cause residential building work to be carried out; and

(b) manage, or arrange, the carrying out of residential building work;

prime cost item, in relation to a residential building work contract, means an item, (including, but not limited to, a fixture or fitting) –

(a) that has not been selected, or the price of which is not known, when the contract is entered into; and

(b) for the cost of supply and delivery of which a reasonable allowance is, or is to be, made in the contract by the building contractor;

progress payment, in relation to a residential building work contract, means a payment of an amount that is a part of the contract price for the contract, but does not include a payment of an amount that is, or is in the nature of, a deposit under the contract;

provisional sum has the meaning it has in section 7 ;

residential building has the meaning it has in section 5 ;

residential building consumer guide means a residential building consumer guide approved under section 81(1) ;

residential building work has the meaning it has in section 6 ;

residential building work contract means a contract between a building contractor and an owner for the performance by the building contractor of residential building work, but does not include –

(a) a contract between a building contractor and a subcontractor or supplier; or

(b) [Section 4 Subsection (1) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] a contract between a building contractor and an owner builder within the meaning of the Building Act 2016 ;

statutory warranty means a warranty arising under Part 6 ;

structure includes a proposed structure, a part of a structure and a temporary structure;

subcontract, in relation to residential building work, means a contract for the performance of residential building work for a building contractor who is obliged, under a residential building work contract, to perform residential building work;

subcontractor means a person who contracts to perform residential building work for a building contractor who is obliged, under a residential building work contract, to perform residential building work;

supplier means a person who supplies goods or services related to the performance of residential building work;

temporary structure includes any –

(a) structure that does not form part of the land and is temporary; and

(b) structure of a prescribed type;

variation, in relation to a residential building work contract, means –

(a) an addition of residential building work to the residential building work to be performed under the contract; or

(b) an omission of residential building work from the residential building work to be performed under the contract  –

but, for a cost-plus contract, an addition or omission is a variation only if the addition or omission is not reasonably contemplated by the contract;

variation document means a document setting out a variation to a residential building work contract.

(2)  In this Act –

(a) a reference to the building contractor, in relation to a residential building work contract, is a reference to the building contractor referred to in the contract; and

(b) a reference to the owner, in relation to a residential building work contract, is a reference to the owner referred to in the contract; and

(c) a reference to performing residential building work, or residential building work performed, under a residential building work contract includes a reference to residential building work that a building contractor arranges, or manages the carrying out of, under a subcontract in order to comply with the building contractor's obligations under the residential building work contract.

5 Meaning of residential building

(1)  In this Act, a residential building is a building, or structure, that is classified under Volume One of the NCC as –

(a) a class 1a building; or

(b) a class 2 building; or

(c) a class 10 building, if that building is associated with a class 1a building or class 2 building.

(2)  Despite subsection (1) , the following are not residential buildings for the purposes of this Act:

(a) a caravan or any motor vehicle, trailer, aeroplane, or boat, used as a residence;

(b) a boarding house, guest house, hostel or lodging house;

(c) a motel, residential club, residential hotel or residential part of licensed premises, within the meaning of the Liquor Licensing Act 1990 , or any other building or structure, or part of a building or structure, used or intended to be used as tourist, holiday or overnight accommodation;

(d) a residential part of an educational institution;

(e) a hospital or care institution;

(f) if a building or structure contains only one residence and that residence is used, or is intended to be used, by a caretaker for the building or structure – that part of the building comprising the residence;

(g) a prison within the meaning of the Corrections Act 1997 , a detention centre within the meaning of the Youth Justice Act 1997 , or premises, or part of premises, where offenders on remand are held or it is intended that such offenders are to be held;

(h) Government House;

(i) a building, structure or other thing that is prescribed by the regulations not to be a residential building.

(3)  In subsection (2)  –

care institution means an institution where accommodation and personal, nursing or medical care are provided to elderly, sick or rehabilitating persons, but does not include an institution for persons otherwise living independently even though the provision of accommodation may include domestic services such as the preparation of meals, cleaning and laundry services.

(4)  If a building or structure, or part of a building or structure, constitutes a residential building, the following structures, fixtures and fittings are taken to be part of the residential building:

(a) all structures, fixtures and fittings that form part of the residential building or are used for, or partly for, the purposes of the residential building;

(b) any thing that is prescribed by the regulations to be such a structure, fixture or fitting.

(5)  For the purposes of subsection (4) , the structures, fixtures and fittings that form part of the residential building or are used for, or partly for, the purposes of the residential building include, but are not limited to, passageways, retaining structures, driveways, paths, fencing, paving, garages, carports, workshops, storage sheds, swimming pools and spas.

(6)  Despite subsection (4) , a structure, fixture or fitting that forms part of a residential building or is used for or partly for the purposes of a residential building is not taken to be part of the residential building under that subsection if the regulations prescribe that it is not to be so taken.

6 Meaning of residential building work

(1)  In this section –

fire safety system includes –

(a) a booster assembly; and

(b) fire mains, hydrants and hose reels; and

(c) sprinklers; and

(d) fire and smoke alarms; and

(e) fire control centres; and

(f) [Section 6 Subsection (1) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] structures or devices to mitigate the fire hazard in respect of special fire hazard buildings, within the meaning of the Building Regulations; and

(g) stairwell pressurisation; and

(h) air-handling systems; and

(i) smoke and heat vents;

plumbing system means –

(a) a water supply system; or

(b) a system of sewage, or of sullage, drainage or removal; or

(c) a system of storm water drainage or roof drainage; or

(d) an on-site waste water management system;

relevant system means any of the following:

(a) a system for lighting, heating, ventilation, air conditioning or cooling;

(b) a power supply system;

(c) a sewerage, water supply, or drainage, system;

(d) a communications system;

(e) a fire safety system;

(f) a security system;

(g) a plumbing system;

(h) a gas supply system.

(2)  For the purposes of this Act, the following work is residential building work:

(a) erecting, re-erecting, constructing, altering, repairing, underpinning, demolishing or removing a residential building;

(b) adding to, or removing a part of, a residential building;

(c) the restoration, maintenance, renovation, alteration, extension, improvement or repair of a residential building;

(d) work, on the land on which building work referred to in paragraph (a) , (b) or (c) is being, or is to be, carried out, that is work in preparation for the use of that land for residential purposes or in preparation for that or other residential building work, including, but not limited to –

(i) work required to gain access, or to remove impediments to access, to that land, part of that land or other land related to any other residential building work, including the construction of a road to enable access to the residential building or to that land or part of that land; and

(ii) site clearance, earth moving, excavation, tunnelling, boring and filling; and

(iii) the preparation of foundations; and

(iv) the erection, maintenance or dismantling of plant and equipment; and

(v) work required in preparation for the erection of a prefabricated dwelling;

(e) all associated work carried out in conjunction with work referred to in paragraph (a) , (b) or (c) including, but not limited to –

(i) the provision, installation, alteration, repair or removal, of all, or a part of, a relevant system in relation to the residential building or the land on which the residential building is, or is to be, situated; and

(ii) the erection, re-erection, construction, alteration, repair or removal of buildings, structures and fixtures associated with a residential building; and

(iii) the cleaning, painting and decorating of the inside and outside surfaces of the residential building; and

(iv) paving; and

(v) landscaping and site restoration;

(f) the prefabrication of any component that is to form part of a residential building, including the manufacture of a prefabricated dwelling, regardless of where that prefabrication is carried out;

(g) any work carried out on any part of a prefabricated dwelling, or on any prefabricated component of a dwelling, in preparation for the erection of the prefabricated dwelling or component, regardless of where that work is carried out;

(h) any other work that is prescribed by the regulations to be residential building work.

(3)  Although a caravan, motor vehicle, trailer, aeroplane or boat is not a residential building, if the caravan, motor vehicle, trailer, aeroplane or boat is, or is to be, used as a residence on any land, the following work is residential building work:

(a) all work done in relation to the use of the land for residential purposes, including, but not limited to, landscaping, paving and the erection, construction or removal of any building or fixture associated with the caravan, motor vehicle, trailer, aeroplane or boat;

(b) the provision of water supply, sewerage or drainage to the land on which the caravan, motor vehicle, trailer, aeroplane or boat is, or is to be, situated;

(c) loading, unloading or transporting a building or structure that, if fixed to land, could be a residential building, regardless of whether the loading, unloading or transportation is solely on the land on which the building or structure was or is to be located;

(d) loading, unloading or transporting a prefabricated building or structure that, if fixed to land, could be a residential building, regardless of whether –

(i) the building or structure is whole or in parts; and

(ii) the loading, unloading or transportation is solely on the land on which the building or structure was or is to be located;

(e) any other work that is prescribed by the regulations to be residential building work in relation to the land on which the caravan, motor vehicle, trailer, aeroplane or boat is, or is to be, situated.

(4)  For the purposes of subsections (2) and (3) , buildings and fixtures associated with a residential building or a caravan, motor vehicle, trailer, aeroplane or boat include, but are not limited to, passageways, retaining structures, driveways, paths, fencing, paving, garages, carports, workshops, storage sheds, swimming pools and spas.

(5)  Despite subsections (2) and (3) , the following work is not residential building work for the purposes of this Act:

(a) any delivery of materials;

(b) any work that is exempted from the application of this Act in accordance with section 10 ;

(c) work for the purposes of the subdivision of land;

(d) work in relation to a building, caravan, motor vehicle, trailer, aeroplane, or boat, intended to be used only for business purposes;

(e) work in relation to a building, caravan, motor vehicle, trailer, aeroplane, or boat, intended to be used only for the accommodation of animals;

(f) other work that is prescribed by the regulations not to be residential building work.

7 Meaning of provisional sum

(1)  In this Act, a provisional sum, in relation to a residential building work contract, is an amount that is an estimate, of the cost of performing a part of the residential building work to be performed under the contract (including the cost of supplying any materials needed for the residential building work), that is made by the building contractor.

(2)  Without limiting the generality of subsection (1) , a building contractor may estimate an amount under that subsection in relation to residential building work on the basis of –

(a) written advice, in relation to the work, provided by the designer or the owner; or

(b) an amount, in relation to all or part of the work, that is specified in a schedule to a design, or to a tender, that relates to the work.

(3)  However, subsection (1) only applies to a part of residential building work to which the relevant residential building work contract relates if the building contractor, after making all reasonable enquiries, cannot state a definite amount in relation to the part of the contract work when the contract is entered into.

8 Certain contracts taken to be one contract

(1)  This section applies if a building contractor and an owner enter into 2 or more separate contracts that –

(a) could be the subject of a single contract that relates to the performance of residential building work by the building contractor; and

(b) if they were a single contract, would be a residential building work contract.

(2)  The separate contracts are taken to be a single contract for which the contract price is the sum of the contract prices for the separate contracts.

Part 3 Application

9 Application of Act

This Act does not apply to, or in relation to, residential building work that –

(a) is performed, or is to be performed, for a contract price that is less than $20 000 or another greater amount, if any, that is prescribed by the regulations; or

(b) is begun before the commencement of this Act, or performed, in pursuance of a residential building work contract entered into before the commencement of this Act; or

(c) consists solely of demolition work; or

(d) is exempted from this Act in accordance with section 10 .

10 Exemptions from application of Act

The regulations may provide for the exemption of any specified residential building work, or class of residential building work, from the application of this Act or a specified provision of this Act, either unconditionally or subject to any conditions specified in the regulations.

Part 4 Functions and Powers of Director

11 Functions and powers of Director

(1)  In addition to his or her functions under any other Act, the Director has the following functions:

(a) to investigate and research matters relevant to residential building work contracts;

(b) to publish reports and information relevant to residential building work contracts;

(c) to inform the public about the provisions of this Act;

(d) to report to the Minister in relation to –

(i) the Director's functions; and

(ii) matters, referred to the Director by the Minister, in relation to residential building work contracts;

(da) [Section 11 Subsection (1) amended by No. 9 of 2023, s. 51, Applied:01 Jul 2024] to advise, and make recommendations to, the Minister in respect of matters relating to residential building work disputes generally;

(e) to assist in the administration of the provision of mediation and adjudication under this Act.

(2)  The Director has the powers necessary to perform his or her functions under this Act.

11A Director may make determination in certain circumstances

[Section 11A Inserted by No. 9 of 2023, s. 52, Applied:01 Jul 2024]

(1)  In this section –

mediation panel has the same meaning as in Part 9 ;

notice of dispute has the same meaning as in Part 9 .

(2)  The Director may make a determination in respect of the following matters:

(a) the provisions that must be included in a residential building work contract;

(b) details of the information to be provided as part of a notice of dispute;

(c) the timing of processes relating to a notice of dispute, or a mediation panel, not otherwise specified in this Act;

(d) the qualifications required to be held by a person for the person to be appointed to a mediation panel;

(e) any other matter relating to a notice of dispute, or mediation panel, not otherwise specified in this Act.

(3)  A determination made under subsection (2)  –

(a) must be published before it comes into effect; and

(b) is to specify the date on which it takes effect; and

(c) must remain so published while the determination remains in effect.

(4)  For the purposes of subsection (3) , a determination is published if –

(a) the determination is made available for viewing by members of the public on a website that is freely accessible by the public; or

(b) the determination is made available for viewing by, or accessible to, members of the public by any other means that the Director considers appropriate.

(5)  A determination made under subsection (2) does not apply in respect of a notice of dispute, or a mediation panel, if –

(a) in the case of a notice of dispute, the notice is lodged under Part 9 before the determination takes effect; and

(b) in the case of a mediation panel, the panel is established under Part 9 before the determination takes effect.

(6)  A notice made by the Director under section 14 (2) that is in force immediately before the commencement of section 52 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 is taken, on and after the commencement of that section, to be a determination made under this section until it ceases to be in force, according to its terms, or is revoked.

12 Delegation

The Director may delegate to a person any of the Director's functions or powers under this Act, other than this power of delegation.

Part 5 Contracts

Division 1 Contracts generally

13 Contracts must be in writing

A building contractor who enters into a residential building work contract must ensure the contract –

(a) is in written form when it is entered into; or

(b) is put into written form –

(i) as soon as practicable (but in any case within 5 business days) after it is entered into; and

(ii) before residential building work begins to be performed under the contract.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

14 General contents of contracts

(1)  A building contractor who enters into a residential building work contract must ensure the contract –

(a) is in English and is readily legible; and

(b) sets out in full all the terms of the contract; and

(c) specifies the names of the parties to the contract; and

(d) if the building contractor holds a licence under the Occupational Licensing Act 2005 , specifies the number of the licence; and

(e) includes a description of, and any plans or specifications in relation to, the residential building work to be performed under the contract; and

(f) specifies either –

(i) the contract price; or

(ii) a method for calculating the contract price and an estimate of the contract price, as determined in accordance with the method of calculation, that is fair and reasonable; and

(g) specifies the date of practical completion or the method for estimating the date of practical completion; and

(h) sets out the warranties that are part of the contract under Part 6 ; and

(i) [Section 14 Subsection (1) amended by No. 9 of 2023, s. 53, Applied:01 Jul 2024] sets out provisions in relation to the matters, if any, specified in a determination, made under section 11A , for the purposes of this section; and

(j) includes the required checklist in relation to the contract; and

(k) has attached to it a copy of a residential building consumer guide that is in effect under section 81(3) , unless the building contractor has already given to the owner a copy of the guide.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

(2)  [Section 14 Subsection (2) omitted by No. 9 of 2023, s. 53, Applied:01 Jul 2024] .  .  .  .  .  .  .  .  

(3)  For the purposes of subsection (1)(j) , a required checklist is a document containing, in language that is readily comprehensible, a summary of the provisions of the residential building work contract to which the checklist relates.

15 Contracts must be signed

A residential building work contract has effect only if it is signed by the building contractor and the owner (or their authorised agents).

16 Copy of contract for owner

As soon as practicable (but in any case within 5 business days) after entering into a residential building work contract, the building contractor must give the owner a readily legible signed copy of the contract, to which is attached the residential building consumer guide required under section 14(1)(k) to be attached to the contract, unless the building contractor has already given to the owner under section 39(1) a copy of the guide.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

Division 2 Variations of contracts

17 Variations must be in writing

(1)  A building contractor must ensure any variation of the residential building work contract agreed to between the building contractor and the owner is put into written form –

(a) within the shortest practicable time; and

(b) for a variation consisting of an addition to the residential building work to be performed under the contract – before any residential building work to which the variation relates begins to be performed.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(2)  Subsection (1) does not apply to a building contractor for a variation of a residential building work contract if –

(a) the variation is in relation to residential building work that is required to be performed urgently; and

(b) it is not reasonably practicable, in the particular circumstances, to produce a variation document before the residential building work to which the variation relates begins to be performed.

(3)  For the purposes of subsection (2) , the circumstances in which residential building work may be required to be performed urgently include, but are not limited to, where the condition of the building site on which the residential building work is to be performed requires an alteration to the work and the condition could not have been discovered, before the work begins to be performed, by reasonably diligent investigation.

(4)  Subsection (5) applies if –

(a) a proposed variation of a residential building work contract has not yet been agreed to between the building contractor under the contract and the owner, but is proposed to come into existence on the signing of a variation document by the owner and the building contractor; and

(b) the variation document is to be the first and only agreement between the building contractor and the owner for the particular variation.

(5)  A building contractor must ensure that no residential building work to which a proposed variation of a residential building work contract relates is performed until the variation document has been signed by the building contractor and the owner, if the proposed variation consists of –

(a) an addition to the residential building work that is to be performed under the contract; or

(b) a variation sought by the owner.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

18 General contents of variation document

(1)  The building contractor under a residential building work contract must ensure a variation document in respect of the contract complies with the formal requirements for a variation document.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(2)  A variation document in respect of a residential building work contract complies with the formal requirements for a variation document if the document –

(a) is in English and is readily legible; and

(b) describes the variation; and

(c) where the variation was sought by the building contractor – states the reason for the variation; and

(d) where the variation will result in a delay affecting the residential building work to be performed under the contract – states the building contractor's reasonable estimate for the period of delay; and

(e) for a fixed-price contract – states the change of the contract price because of the variation, or how the change of the contract price is to be determined; and

(f) for a cost-plus contract – states a fair and reasonable estimate of the costs associated with the addition or omission the subject of the variation; and

(g) if the contract provides for progress payments – makes appropriate provision for payments under the contract to reflect any change, to the contract price, caused by the variation.

19 Variation document must be signed

As soon as practicable after an appropriate variation document is made, the building contractor must –

(a) sign the document; and

(b) take all reasonable steps to ensure the document is signed by the owner.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

20 Copy of variation document for owner

(1)  As soon as practicable (but in any case within 5 business days) after a variation of a residential building work contract is agreed to between the building contractor and the owner, the building contractor must give the owner –

(a) a readily legible copy of an appropriate variation document for the variation signed by the building contractor and the owner; or

(b) if acceptable circumstances apply to the building contractor – a readily legible copy of an appropriate variation document for the variation, signed by the building contractor.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(2)  For the purposes of subsection (1)(b) , acceptable circumstances apply to the building contractor if the building contractor has taken all reasonable steps to ensure an appropriate variation document for the variation is signed by the owner, but the owner has not signed the document.

21 Where variation requires consent by building surveyor or authorisation to be obtained

(1)  In this section –

[Section 21 Subsection (1) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] certificate of likely compliance means a certificate of likely compliance issued under the Building Act 2016 .

(2)  [Section 21 Subsection (2) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] If a variation of a residential building work contract is such that residential building work, if performed in accordance with the variation, would require the consent, under the Building Act 2016 , of a building surveyor because it varies from the residential building work to which a certificate of likely compliance relates, the building contractor must ensure that –

(a) the copy of the variation document provided to the owner has attached to it the written consent of a building surveyor to the residential building work to be performed in accordance with the variation; and

(b) residential building work in accordance with the variation is not performed until paragraph (a) has been complied with.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(3)  [Section 21 Subsection (3) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] If a variation to a residential building work contract relates to residential building work in relation to which a permit, or other authorisation, under the Land Use Planning and Approvals Act 1993 or the Building Act 2016 is required, the building contractor must ensure that –

(a) the residential building work to which the variation relates is authorised by the permit or other authorisation, or if the permit or authorisation required amendment in order for the work to be authorised, has been so amended; and

(b) the copy of the variation document provided to the owner has attached to it a copy of the permit or other authorisation, as so amended, if at all; and

(c) residential building work in accordance with the variation is not performed until paragraph (b) has been complied with.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

Part 6 Statutory Warranties in Contracts

22 Implied warranties

The warranties on the part of the building contractor that are contained in this Division are implied in a residential building work contract.

23 Suitability of materials

(1)  In this section –

relevant criteria, for materials, means –

(a) generally accepted practices, or standards, applied in the building industry for the materials; or

(b) specifications, instructions or recommendations of manufacturers or suppliers of the materials;

responsible person, in relation to a residential building work contract, means the person who carries out residential building work required to be performed under the contract.

(2)  The building contractor warrants that all materials to be supplied for use in the residential building work to which the relevant residential building work contract relates –

(a) will be good and, having regard to the relevant criteria, suitable for the purpose for which they are used; and

(b) unless otherwise stated in the contract, will be new.

(3)  Subsection (2) applies to the building contractor in relation to materials only if the materials are supplied by the responsible person in relation to the residential building work contract.

(4)  Despite subsection (3) , if the residential building work contract is being administered by –

(a) an agent of the owner; or

(b) an architect, engineer, or building designer, who is engaged by the building owner –

subsection (2) does not apply to the owner in relation to materials if the responsible person is subject to the direction of the agent, architect, engineer or building designer for supplying the materials.

(5)  Also, despite subsection (3) , subsection (2) does not apply to the building contractor for materials if –

(a) the owner is responsible for nominating the materials for use in the residential building work to which the relevant residential building work contract relates; and

(b) either –

(i) there are no reasonable grounds for not using the materials; or

(ii) if there are reasonable grounds for not using the materials – the owner insists on the materials being used despite written advice to the contrary given to the owner by the building contractor.

24 Compliance with legal requirements

The building contractor warrants the residential building work to be performed under the relevant residential building work contract will be performed in accordance with all relevant laws and legal requirements.

25 Standard of work and exercise of care and skill

The building contractor warrants the residential building work to be performed under the relevant residential building work contract will be performed –

(a) in an appropriate and skilful way; and

(b) with reasonable care and skill.

26 Implied warranties

The warranties on the part of the building contractor that are contained in a provision in this Division are implied in a residential building work contract to which the provision applies.

27 Adherence to plans and specifications

(1)  This section applies to a residential building work contract if plans and specifications form part of the contract.

(2)  The building contractor warrants the residential building work to be performed under the relevant residential building work contract will be performed in accordance with the plans and specifications.

28 Suitability of residential building for occupation

(1)  This section applies to a residential building work contract if the residential building work to be performed under the contract –

(a) consists of the erection or construction of a residential building to a stage suitable for occupation; or

(b) is work intended to renovate, alter, extend, improve or repair a residential building to a stage suitable for occupation.

(2)  The building contractor warrants the residential building will be suitable for occupation when the residential building work is completed.

29 Carrying out work with reasonable diligence

The building contractor warrants that the residential building work to be performed under the relevant residential building work contract will be performed with reasonable diligence.

30 Calculation of provisional sums and prime cost items

(1)  This section applies to a residential building work contract if the contract provides for a provisional sum or a prime cost item.

(2)  The building contractor warrants the provisional sum or prime cost item has been calculated with reasonable care and skill, having regard to all the information reasonably available when the residential building work contract is entered into, including information about the nature and location of the building site.

(3)  Without limiting the circumstances in which a provisional sum may be taken to have been calculated with reasonable care and skill, a provisional sum is to be taken to have been calculated with reasonable care and skill if it has been, in relation to residential building work, calculated by the building contractor on the basis of –

(a) written advice, in relation to the work, provided by the designer or the owner; or

(b) an amount, in relation to all or part of the work, that is specified in a schedule to a design, or to a tender, that relates to the work.

Division 3 Effect of statutory warranties

31 Succession to statutory warranties

(1)  A person who purchases or otherwise acquires a residential building succeeds to the rights, in respect of statutory warranties, of his or her predecessor in title.

(2)  If a person purchases a residential building from a building contractor who has performed residential building work in relation to the residential building, the purchaser is entitled to the benefit of the statutory warranties as if the building contractor had performed the residential building work for the purchaser pursuant to a residential building work contract.

(3)  [Section 31 Subsection (3) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] A person who purchases or otherwise acquires a residential building in relation to which an owner builder, within the meaning of the Building Act 2016 , performed residential building work is entitled to the benefit of the statutory warranties in relation to the residential building as if the owner builder had performed the residential building work for the person pursuant to a residential building work contract.

32 Proceedings for breach of statutory warranty

(1)  Proceedings for a breach of a statutory warranty are to be commenced within 6 years after the date of practical completion of the residential building work to which the proceedings relate.

(2)  Subsection (3) applies in relation to residential building work if –

(a) proceedings, for a breach of a statutory warranty, are to be or have been commenced, in relation to the residential building work, by or on behalf of a person who is entitled under section 31(2) or (3) to the benefit of a statutory warranty in relation to the residential building work; and

(b) but for the application of subsection (3) , the person bringing the proceeding could not, by reasonable diligence, establish for the purposes of subsection (1) the date of practical completion of the work.

(3)  If this subsection applies in relation to residential building work, the date of practical completion of the residential building work is to be taken to be –

(a) [Section 32 Subsection (3) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] the date on which a certificate of completion (building work), within the meaning of the Building Act 2016 , is issued in relation to the residential building work; or

(b) if –

(i) paragraph (a) does not apply in relation to the residential building work; and

(ii) [Section 32 Subsection (3) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] an occupancy permit, within the meaning of the Building Act 2016 , is issued in relation to the residential building to which the work relates before the building is first occupied after the residential building work is carried out –

the date on which the occupancy permit is issued; or

(c) if –

(i) paragraphs (a) and (b) do not apply in relation to the residential building work; and

(ii) [Section 32 Subsection (3) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] a building permit was required under the Building Act 2016 for the carrying out of the residential building work –

the date that is 2 years after the date on which the building permit was issued; or

(d) if –

(i) paragraphs (a) , (b) and (c) do not apply in relation to the residential building work; and

(ii) [Section 32 Subsection (3) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] the authorisation of a building surveyor was required under the Building Act 2016 for the carrying out of the residential building work –

the date that is 2 years after the date on which the authorisation was given by a building surveyor.

(4)  In proceedings for breach of a statutory warranty it is a defence for the defendant to prove that the deficiencies of which the plaintiff complains arose from instructions given by the owner contrary to the advice in writing of the defendant.

Part 7 Cooling-off Period

33 Right of owner to withdraw from contract in cooling-off period

(1)  In this section –

receipt day, for a residential building work contract, means –

(a) the day on which the owner receives the following documents from the building contractor:

(i) a copy of the signed contract;

(ii) a copy of the residential building consumer guide that is in effect under section 81(3) ; or

(b) if the documents mentioned in paragraph (a) are received by the owner from the building contractor on different days – the later of the days.

(2)  The owner under a residential building work contract may withdraw from the contract under this section.

(3)  The owner may withdraw from the contract within 5 business days after the receipt day for the contract.

(4)  If 5 business days have elapsed since the contract was entered into and there is no receipt day for the contract, the owner may withdraw from the contract.

(5)  Nothing in subsection (4) affects the right of the owner to withdraw from the contract under subsection (3) if a receipt day subsequently applies to the contract.

34 Restrictions affecting right of withdrawal in cooling-off period

(1)  In this section –

formal legal advice means independent advice –

(a) given by a practising legal practitioner; and

(b) for the giving of which an amount is paid, or is payable, to the legal practitioner by the person to whom the advice is given;

practising legal practitioner means an Australian legal practitioner authorised under a law of the State to practise as a lawyer for purposes including the giving, for reward, of advice, including, for example, advice about residential building work contracts.

(2)  This section applies despite section 33 .

(3)  An owner may not withdraw from a residential building work contract (the current contract) under section 33 if –

(a) the owner and building contractor previously entered into a residential building work contract (the previous contract); and

(b) the terms of the previous contract and current contract are substantially the same; and

(c) the contracted services for the previous contract and current contract –

(i) are substantially the same; and

(ii) relate to the same residential building or land.

(4)  Also, an owner may not withdraw from a residential building work contract under section 33 if –

(a) before entering into the contract, the owner received formal legal advice about the contract; or

(b) when, or after, the contract is entered into, the owner tells the building contractor that the owner received formal legal advice about the contract before entering into the contract.

35 Right of owner to withdraw from contract if cooling-off warning not given

(1)  This section applies if an owner has not received from the building contractor a residential building consumer guide that is in effect under section 81(3) .

(2)  The owner may withdraw from the contract within 7 days of becoming aware that the owner should have received from the building contractor a residential building consumer guide that is in effect under section 81(3) .

36 Withdrawal procedure

(1)  In this section –

withdrawal notice means a written notice signed by the owner, in relation to a residential building work contract, stating –

(a) that the owner withdraws from the contract; and

(b) the section of this Act under which the withdrawal is made.

(2)  To withdraw from a residential building work contract under section 33 or 35 , the owner must, within the time allowed under the section for the withdrawal –

(a) give a withdrawal notice to the building contractor; or

(b) leave a withdrawal notice at the address shown as the building contractor's address in the contract; or

(c) serve a withdrawal notice on the building contractor in accordance with any provision in the contract providing for service of notices on the building contractor by the owner.

37 Rights and obligations of parties following withdrawal in cooling-off period

(1)  In this section –

pre-paid amount, in relation to a contract, means the amount paid to the building contractor under the contract by the owner before the owner withdrew from the contract;

retainable amount, in relation to a contract, means the sum of –

(a) $100; and

(b) an amount equal to any out-of-pocket expenses reasonably incurred in relation to the contract by the building contractor before the owner withdrew from the contract.

(2)  This section applies if an owner withdraws from a residential building work contract under section 33 .

(3)  If there is a pre-paid amount for the contract that is not less than the retainable amount, the building contractor –

(a) may keep an amount equal to the retainable amount out of the pre-paid amount; and

(b) must refund any balance of the pre-paid amount to the owner.

(4)  If there is a pre-paid amount for the contract that is less than the retainable amount, the owner must pay the building contractor an amount equal to the difference between the retainable amount and the pre-paid amount.

(5)  If there is no pre-paid amount for the contract, the owner must pay the building contractor an amount equal to the retainable amount.

(6)  If an amount is not paid by a person as required under this section, the person to whom it is payable may recover the amount from the other person as a debt.

(7)  Except as provided under subsection (4) or (5) , the owner is not liable to the building contractor in any way for withdrawing from the contract.

38 Rights of building contractor following withdrawal for failure to give warning

(1)  This section applies if an owner withdraws from a residential building work contract under section 35 .

(2)  The building contractor is entitled to receive a reasonable amount for the performance of residential building work under a residential building work contract before the time of withdrawal.

(3)  However, the building contractor is not entitled to receive an amount that is more than the amount the building contractor would have been entitled to receive under the contract.

Part 8 Obligations of Building Contractor

39 Building contractor must give owner copy of residential building consumer guide

(1)  A building contractor must, before the building contractor or the owner enters into a residential building work contract, give the owner a copy of the residential building consumer guide that is in effect under section 81(3) .

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(2)  A document, signed by an owner, containing a statement that a building contractor has given the owner a copy of the residential building consumer guide that is in effect under section 81(3) is evidence of that matter and, in the absence of evidence to the contrary, is proof of that matter.

40 Building contractor to give commencement notice

(1)  A building contractor must, within 10 business days after residential building work to which a residential building work contract relates begins to be performed, give to the owner a commencement notice.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(2)  For the purposes of subsection (1) , a commencement notice is a notice, signed by the building contractor in relation to a residential building work contract, stating –

(a) the day on which the residential building work to be performed under the contract began to be performed; and

(b) the estimated date of practical completion in relation to the contract.

41 Deposits

(1)  In this section –

off-site work, in relation to a residential building work contract, means work that –

(a) relates to or forms part of residential building work; and

(b) is performed at a place that is not the place at which an object resulting from the performance of the residential building work is to be finally installed or constructed under the contract;

set amount means –

(a) the amount, above $20 000, prescribed under a regulation as the set amount; or

(b) if an amount is not prescribed for paragraph (a)  – $20 000.

(2)  A building contractor must not, before starting to perform residential building work under a residential building work contract, demand or receive a deposit under the contract of more than –

(a) if the contract price is equal to or more than the set amount and is not a contract price to which paragraph (c) applies –5% of the contract price; or

(b) if the contract price is less than the set amount and is not a contract price to which paragraph (c) applies – 10% of the contract price; or

(c) for a residential building work contract under which the value of the off-site work is more than 50% of the contract price – 20% of the contract price.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

(3)  In this section, a reference to the contract price for a contract includes, for a cost-plus contract, a reference to the estimated amount for the contract.

42 Progress payments

(1)  In this section –

building site, in relation to a residential building work contract, does not include a place where residential building work has been, is being, or is to be, performed, if the work is required to later be installed or constructed at another place under the contract.

(2)  A building contractor must not demand or receive an amount, other than a deposit, under a residential building work contract unless the amount is directly related to the progress of the performance at the building site of the residential building work to be performed under the contract.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

43 Building contractor to give notice of practical completion

(1)  A building contractor must, within 10 business days after the date of practical completion in relation to a residential building work contract, give a notice of practical completion to –

(a) the owner; and

(b) [Section 43 Subsection (1) amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] if the residential building work to which the contract relates was work in relation to which a certificate of likely compliance is required under the Building Act 2016 to be given to a person – the person to whom the certificate is required under that Act to be given.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 300 penalty units; or

(b) an individual, a fine not exceeding 100 penalty units.

(2)  For the purposes of subsection (1) , a notice of practical completion is a notice, signed by the building contractor in relation to a residential building work contract, stating that the date of practical completion has occurred.

44 Correction of minor defects and omissions

(1)  In this section –

completion day, in relation to a residential building work contract, means the day when the residential building work to be performed under the contract is completed –

(a) in compliance with the contract, including all plans and specifications for the work and all statutory requirements applying to the work; and

(b) without any defects or omissions, other than minor defects, or minor omissions, that will not unreasonably affect occupation.

(2)  If, on or after the completion day in relation to a residential building work contract –

(a) the owner claims there are minor defects or minor omissions (other than minor defects, or minor omissions, that will not unreasonably affect occupation) in relation to the residential building work performed under the contract; and

(b) the building contractor agrees that there are minor defects or minor omissions (other than minor defects, or minor omissions, that will not unreasonably affect occupation) in relation to the residential building work performed under the contract –

the building contractor, as soon as practicable, must give to the owner a defects document in relation to the minor defects or minor omissions.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

(3)  A building contractor, as soon as practicable, but in any case within 6 months, after giving to an owner a defects document in relation to a minor defect or minor omission, must take all reasonable steps to correct the defect or the omission.

Penalty:  In the case of –

(a) a body corporate, a fine not exceeding 800 penalty units; or

(b) an individual, a fine not exceeding 300 penalty units.

(4)  A building contractor –

(a) does not commit an offence under subsection (3) ; and

(b) is not liable under a residential building contract –

in relation to any failure to correct a minor defect or minor omission in relation to the residential building work performed under a residential building work contract, if the owner does not enable the building contractor to have the access to any land, building, or structure, that the building contractor reasonably requires in order to comply with subsection (3) .

Part 9 Mediation

45 Interpretation of Part 9

In this Part –

[Section 45 Amended by No. 9 of 2023, s. 54, Applied:01 Jul 2024] dispute means a dispute between an owner and either a building contractor or a prescribed licensed professional in relation to –

(a) a residential building work contract entered into by the building contractor and the owner; or

(b) the performance of residential building work under a residential building work contract entered into by the building contractor and the owner; or

(c) [Section 45 Amended by No. 9 of 2023, s. 54, Applied:01 Jul 2024] whether a provision of this Act has been complied with by the building contractor or the owner in relation to the residential building work contract entered into by the building contractor and the owner; or

(d) [Section 45 Amended by No. 9 of 2023, s. 54, Applied:01 Jul 2024] another matter relating to residential building work, or residential building work contracts, that has been prescribed for the purposes of this definition;

mediation panel, in relation to a dispute, means a panel established under section 49(2) ;

notice of dispute means a notice that is lodged under section 47(1) ;

party, in relation to a dispute, means –

(a) a person who has lodged under section 47(1) a notice of dispute in relation to the dispute; and

(b) a person on whom a notice of dispute in relation to the dispute is served under section 47(2) ; and

(c) [Section 45 Amended by No. 9 of 2023, s. 54, Applied:01 Jul 2024] any person who is joined under section 50(3) as a party to the mediation of the dispute;

[Section 45 Amended by No. 9 of 2023, s. 54, Applied:01 Jul 2024] prescribed licensed professional, in respect of a class of building services work within the meaning of the Occupational Licensing Act 2005 , means a person of a class of persons who are prescribed as the licensed professionals for that class of building services work.

46 Application of Part

(1)  Nothing in this Part is to be taken to require a person to lodge a notice of dispute in relation to a matter before the person may exercise any other right the person may have to commence any proceedings in relation to the matter.

(2)  [Section 46 Subsection (2) inserted by No. 9 of 2023, s. 55, Applied:01 Jul 2024] For the purposes of this Part, a reference to a residential building work contract also includes a reference to a contract, whether oral or in writing, that relates to residential building work to which this Act applies if –

(a) residential building work has been performed under the contract; and

(b) the contract is not in effect, under this Act, solely on the basis that the contract does not meet the requirement of section 15 .

47 Lodging of notice of dispute

(1)  A building contractor or an owner may lodge with the Director a notice of dispute in relation to a dispute between the building contractor and the owner.

(1A)  [Section 47 Subsection (1A) inserted by No. 9 of 2023, s. 56, Applied:01 Jul 2024] A notice of dispute may only be lodged under subsection (1)  –

(a) within 6 years after the date of practical completion of the residential building work to which the notice relates; or

(b) if there is no date of practical completion for the residential building work to which the notice relates, within 6 years after the day on which the residential building work was performed by, or on behalf of, the building contractor.

(2)  A building contractor or owner who lodges with the Director a notice of dispute must serve a copy of the notice on the owner, or building contractor, respectively.

(3)  [Section 47 Subsection (3) substituted by No. 9 of 2023, s. 56, Applied:01 Jul 2024] A notice of dispute –

(a) is to specify the grounds of the dispute; and

(b) must be in the form approved by the Director; and

(c) must comply with the relevant provisions of a determination, made under section 11A , that is in force at the time when the notice of dispute is lodged with the Director.

(4)  A person who has lodged a notice of dispute may, by notice to the Director, withdraw the notice at any time.

48 Acceptance of notice of dispute lodged with Director

(1)  The Director, within 10 business days after a notice of dispute is lodged under section 47(1) , must accept or reject the notice of dispute.

(1A)  [Section 48 Subsection (1A) inserted by No. 9 of 2023, s. 57, Applied:01 Jul 2024] Before making a decision under subsection (1) in respect of a notice of dispute, the Director may request additional information, in respect of the dispute to which the notice relates, from one or more parties to the dispute.

(2)  The Director must reject under subsection (1) a notice of dispute in relation to a dispute if the Director is satisfied that –

(a) [Section 48 Subsection (2) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] the notice of dispute has not been lodged within 6 years after the date of practical completion of the residential building work to which the notice relates; or

(ab) [Section 48 Subsection (2) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] a notice of dispute in relation to the same dispute, between a building contractor and the owner, has been accepted under this section; or

(ac) [Section 48 Subsection (2) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] the notice of dispute relates to a matter that is the subject of an adjudication application under the Building and Construction Industry Security of Payment Act 2009 and –

(i) that application has not been rejected, or withdrawn, under that Act; or

(ii) the matter has been resolved, or determined, under that Act; or

(b) proceedings under another Act, or in a court, in relation to the dispute to which the notice relates have commenced.

(3)  [Section 48 Subsection (3) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] The Director may reject under subsection (1) all, or part of, a notice of dispute in relation to a dispute if the Director is satisfied that –

(a) [Section 48 Subsection (3) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] the person lodging the notice of dispute has not made a reasonable attempt to resolve the dispute with the other party to the dispute; or

(ab) [Section 48 Subsection (3) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] the notice of dispute does not contain the information required under this Act to form part of the notice; or

(b) the notice of dispute does not appear to contain any grounds of a dispute; or

(c) the dispute is frivolous or vexatious; or

(d) it is appropriate for the dispute to be dealt with under Part 10 , or under any other Act, or by a court, without mediation occurring.

(4)  [Section 48 Subsection (4) amended by No. 9 of 2023, s. 57, Applied:01 Jul 2024] The Director may not reject under subsection (1) all, or part of, a notice of dispute unless permitted or required to do so under subsection (2) or (3) .

(5)  The Director must, by notice in writing to the building contractor and owner to whom a notice of dispute relates, notify the building contractor and owner of the Director's decision to accept or reject the notice of dispute.

(6)  [Section 48 Subsection (6) inserted by No. 9 of 2023, s. 57, Applied:01 Jul 2024] If the Director makes a decision to reject part of a notice of dispute, the Director is to clearly identify the part of the notice, that has been so rejected, in the written notice given under subsection (5) in respect of the notice of dispute.

49 Establishment of mediation panel

(1)  Within 2 business days after deciding under section 48(1) to accept a notice of dispute in relation to a dispute, the Director is to establish a mediation panel in relation to the dispute.

(2)  The Director is to establish a mediation panel in relation to a dispute by appointing to the panel one or more persons who the Director thinks have suitable qualifications or experience to assist in the mediation of the dispute.

50 Director may join parties to mediation of dispute

(1)  The Director, by notice to a person who, in the opinion of the Director, ought to be a party to mediation of a dispute in relation to which a notice of dispute is lodged, may notify the person that the person is to be a party to the mediation of the dispute.

(2)  The Director is to give a copy of a notice under subsection (1) to the building contractor, and the owner, to whom the notice of dispute relates.

(3)  A person is a party to the mediation of a dispute if the person is notified under subsection (1) that the person is to be a party to the mediation of a dispute.

(4)  A person who is a party to a dispute by virtue of subsection (3) is not required to participate in any mediation under this Part in relation to the dispute.

51 Panel to mediate dispute

(1)  A mediation panel in relation to a dispute may mediate in a dispute and may impose conditions that must be satisfied if the mediation is to proceed.

(2)  If a mediation panel proceeds with the mediation, the mediation panel –

(a) may give directions to the parties to the dispute to assist in the resolution of the dispute; and

(ab) [Section 51 Subsection (2) amended by No. 9 of 2023, s. 58, Applied:01 Jul 2024] may request the parties to the dispute to provide information or documentation, that may be relevant to the resolution of the dispute, within the time frame specified by the mediation panel; and

(ac) [Section 51 Subsection (2) amended by No. 9 of 2023, s. 58, Applied:01 Jul 2024] is to have regard to the Guide to Standards and Tolerances approved by the Director under section 82 ; and

(b) must make a reasonable attempt to assist the parties to agree to a negotiated settlement of the dispute.

(3)  A mediation panel may assist in the resolution of a dispute in any manner it thinks fit that is not inconsistent with any guidance material that is issued under section 52 in relation to the performance of the functions, and the exercise of the powers, of a mediation panel under this Part.

(4)  [Section 51 Subsection (4) inserted by No. 9 of 2023, s. 58, Applied:01 Jul 2024] For the avoidance of doubt, a mediation panel may refuse to proceed with mediation for any of the following reasons:

(a) a party to the mediation has failed to comply with a direction given, or a request made, by the mediation panel;

(b) a party to the mediation has failed to comply with a condition imposed on the mediation by the mediation panel;

(c) a reason specified in a determination, in force under section 11A , as a reason that a mediation panel may refuse to proceed with mediation;

(d) any other reason that the mediation panel considers appropriate.

52 Director may issue guidance materials

(1)  The Director may issue guidance materials in relation to the performance of the functions, and the exercise of the powers, of a mediation panel under this Part.

(2)  [Section 52 Subsection (2) omitted by No. 9 of 2023, s. 59, Applied:01 Jul 2024] .  .  .  .  .  .  .  .

52A Completion of mediation

[Section 52A Inserted by No. 9 of 2023, s. 60, Applied:01 Jul 2024]

(1)  If the parties to a dispute reach a settlement of the dispute as a result of mediation under this Part, the mediation panel for the dispute must –

(a) issue a certificate of mediation (agreement) in respect of the settlement; and

(b) prepare a document, setting out the terms of the settlement, to be registered under section 53; and

(c) provide to the Director and each party to the dispute a copy of –

(i) the certificate of mediation (agreement) issued in respect of the settlement; and

(ii) the document setting out the terms of the settlement.

(2)  If the parties to a dispute do not reach a settlement of the dispute as a result of mediation under this Part, the mediation panel for the dispute must –

(a) issue a certificate of mediation (dispute not resolved) in respect of the dispute; and

(b) within 2 business days after the certificate is issued, provide to the Director and each party to the dispute a copy of the certificate of mediation (dispute not resolved) issued in respect of the dispute.

(3)  A certificate issued under this section, or a document prepared for the purposes of this section, is to be in accordance with each relevant provision of a determination, made under section 11A , that is in force at the time when the certificate is issued or document is prepared.

53 Where parties reach settlement within relevant period

(1)  The Director may register, or refuse to register, a settlement of a dispute by the parties to the dispute.

(2)  Without limiting the circumstances in which the Director may refuse to register a settlement, the Director may refuse to register a settlement in relation to a dispute if he or she is satisfied that the settlement –

(a) was not entered into in good faith by a party to the dispute; or

(b) was entered into as a result of unconscionable conduct by a party to the dispute or a person acting on behalf of a party to the dispute; or

(c) is not the result of a genuine attempt by the parties to the dispute to ensure the settlement is fair to all the parties to the dispute.

(3)  [Section 53 Subsection (3) amended by No. 9 of 2023, s. 61, Applied:01 Jul 2024] If the parties to a dispute agree to a settlement of a dispute and the Director registers the settlement, the parties who are to be bound by the settlement must sign a document setting out the terms of the settlement.

(4)  [Section 53 Subsection (4) omitted by No. 9 of 2023, s. 61, Applied:01 Jul 2024] .  .  .  .  .  .  .  .

54 Where parties fail to settle dispute within relevant period

If a settlement, registered by the Director under section 53(1) , to a dispute is not, within 20 business days after the Director establishes a mediation panel in relation to the dispute, signed by the parties to the dispute who are to be bound by the settlement –

(a) the mediation panel must cease to assist the parties to the dispute; and

(b) the mediation panel must notify the Director that the mediation panel has ceased to assist the parties to the dispute.

55 Use of evidence obtained in the course of mediation

(1)  Evidence of anything said, or of any admission made, in the course of mediation under this Act –

(a) is not admissible in any proceedings before any court, tribunal or body, including under Part 10 ; and

(b) may not be used by the Director, or a State Service officer or State Service employee, for the purposes of the Occupational Licensing Act 2005 .

(2)  Any document prepared for the purposes of, in the course of, or as a result of, mediation under this Act –

(a) is not admissible in any proceedings before any court, tribunal or body, including under Part 10 ; and

(b) may not be used by the Director, or a State Service officer or State Service employee, for the purposes of the Occupational Licensing Act 2005 .

(3)  Subsections (1) and (2) do not apply with respect to any evidence or document –

(a) if the persons who take part in mediation under this Act and, in the case of a document, the persons identified in the document, consent to the admission of, or the use of, the evidence or document; or

(b) if the parties involved in the mediation agree to the waiver of the privilege set out in those subsections; or

(c) if the document was prepared to give effect to a decision taken, or an undertaking given, or a settlement, in relation to the mediation.

55A Costs of mediation under this Part

[Section 55A Inserted by No. 9 of 2023, s. 62, Applied:01 Jul 2024] Unless otherwise agreed between the parties to a dispute, the costs of mediation under this Part are to be shared equally between the parties to the dispute.

Part 10 Matter may be determined by Tasmanian Civil and Administrative Tribunal

[Part 10 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] [Division 1 of Part 10 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

56 Interpretation of Part

[Section 56 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] In this Part –

relevant notice of dispute means a notice lodged under section 47(1) in respect of the residential building work that forms a matter that is within the jurisdiction of the Tribunal, to review or determine, by virtue of this Part;

TASCAT Act means the Tasmanian Civil and Administrative Tribunal Act 2020 ;

Tribunal means the Tasmanian Civil and Administrative Tribunal.

57 Application of Part

[Section 57 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] For the purposes of this Part, a reference to a residential building work contract also includes a reference to a contract, whether oral or in writing, that relates to residential building work to which this Act applies if –

(a) residential building work has been performed under the contract; and

(b) the contract is not in effect, under this Act, solely on the basis that the contract does not meet the requirement of section 15 .

58 TASCAT to review certain decisions

[Section 58 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

(1)  The Tribunal has the jurisdiction to review the following decisions under the Act:

(a) a decision of the Director under section 48 to reject a notice of dispute;

(b) a decision of the Director under section 53(1) to register, or refuse to register, a settlement in respect of a dispute;

(c) a decision prescribed to be a reviewable decision for the purposes of this section;

(d) a decision referred to in this subsection that has been referred to the Tribunal under section 65 .

(2)  For the avoidance of doubt, the review, by the Tribunal, of a decision specified in subsection (1) is –

(a) within the review jurisdiction of the Tribunal; and

(b) allocated to the Civil and Consumer stream of the General Division of the Tribunal.

59 TASCAT to determine certain matters

[Section 59 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

(1)  Subject to subsection (2) , the Tribunal has the jurisdiction to determine the following:

(a) whether residential building work has been completed satisfactorily, if a notice has been lodged under section 47(1) in respect of a dispute relating to the work;

(b) whether residential building work complies with the requirements of –

(i) this Act; or

(ii) another Act that applies to the work or to the building where the work is to be performed;

(c) a dispute between the parties to a residential building work contract as to the terms of the contract including, but not limited to –

(i) the legal and practical effect of one or more terms of the contract; or

(ii) whether something is, or is not, a term of the contract;

(d) a matter referred to in this subsection that has been referred to the Tribunal under section 65 .

(2)  The Tribunal only has jurisdiction to determine a matter referred to in subsection (1) if –

(a) there is a relevant notice of dispute in respect of the matter; and

(b) one of the following applies in respect of the matter:

(i) the Director has rejected the relevant notice of dispute under section 48(3)(d) ;

(ii) a settlement in respect of the matter has been registered under section 53 ;

(iii) a certificate has been issued in respect of the matter under section 52A .

(3)  For the purposes of subsection (1)(a) , residential building work is taken not to have been completed satisfactorily if –

(a) the work has not been completed or is deficient; or

(b) the work has not been completed to the standard, or using the materials, required under the contract; or

(c) a statutory warranty that applies in relation to the work has been breached; or

(d) the Tribunal has made an order in respect of the work and the order has not been complied with; or

(e) a requirement under another Act, that applies in relation to the work, has not been complied with including, but not limited to –

(i) relevant certificates, permits, notices or orders issued under the Building Act 2016 ; or

(ii) relevant determinations made by the Director under the Building Act 2016 ; or

(f) the work has caused, or resulted in, damage to any building, structure or residential building work.

(4)  For the avoidance of doubt, a matter specified in subsection (1) as being within the jurisdiction of the Tribunal is –

(a) within the original jurisdiction of the Tribunal; and

(b) allocated to the Civil and Consumer stream of the General Division of the Tribunal.

60 TASCAT not to determine certain matters

[Section 60 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

(1)  Despite sections 58 and 59 , the Tribunal does not have the jurisdiction to determine the following matters:

(a) any matter that is the subject of an adjudication application under the Building and Construction Industry Security of Payment Act 2009 and –

(i) that application has not been rejected, or withdrawn, under that Act; or

(ii) the matter has been resolved, or determined, under that Act;

(b) any matter that is the subject of proceedings under another Act, including enforcement or review proceedings, if those proceedings have not been completed, finalised or otherwise discontinued under that Act;

(c) any matter that is the subject of a work-completion claim, or adjudication application, under this Act as in force immediately before the commencement of Part 6 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 , if –

(i) the person served with the claim has complied with the claim in accordance with this Act, as in force immediately before the commencement of Part 6 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 ; or

(ii) an expert panel has issued a declaration under this Act, as in force immediately before the commencement of Part 6 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 , that the residential building work to which the matter relates has been completed satisfactorily;

(d) any matter that relates to a residential building work contract that was entered into by the parties –

(i) before 1 January 2017; or

(ii) on or after 1 January 2017 if, in the opinion of the Director, the contract has substantially the same terms, and essentially replaces, a contract that was entered into before that date.

(2)  The exclusion of a matter from the jurisdiction of the Tribunal under subsection (1)(a)  –

(a) only applies to such part of the residential building work to which an adjudication application under the Building and Construction Industry Security of Payment Act 2009 has been made; and

(b) does not prevent the Tribunal from determining a matter in respect of a part of the residential building work in respect of which the adjudication application has not been made.

(3)  For the avoidance of doubt, this Act, as in force immediately before the commencement of Part 6 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 , applies in respect of any matter referred to in subsection (1)(c) or (d) .

61 Application of TASCAT Act to disputes

[Section 61 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] In addition to the requirements of the TASCAT Act and the Tribunal, an application to the Tribunal for the determination of a matter, relating to a dispute, that is within the jurisdiction of the Tribunal by virtue of this Part –

(a) may only be made by a party to the dispute, or mediation of the dispute, to which the matter relates; and

(b) must specify –

(i) each proceeding, and dispute resolution, that has been commenced in respect of, or in connection with, the matter; and

(ii) whether those proceedings have, or dispute resolution has, been completed or discontinued, or is still in progress; and

(c) must include –

(i) if the notice of dispute was rejected by the Director in accordance with section 48 , a copy of the written notification, of that rejection, given by the Director under section 48(5) ; and

(ii) if there has been a settlement registered under section 53 in respect of the dispute, a copy of the settlement so registered; and

(iii) if there has been a certificate issued under section 52A in respect of the matter, a copy of the certificate so issued; and

(d) if the application relates to residential building work that has not been completed satisfactorily, must clearly identify each manner in which the applicant believes that the residential building work, that forms the basis of the matter, is taken not to have been completed satisfactorily within the meaning of section 59(3) .

62 Determination of matter by Tribunal

[Section 62 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

(1)  For the avoidance of doubt, in determining a matter that is within the jurisdiction of the Tribunal by virtue of this Part –

(a) the Tribunal is to take into account the provisions, or terms, of each of the following that are applicable to the matter:

(i) this Act and any other relevant Act;

(ii) the NCC;

(iii) the Guide to Standards and Tolerances approved by the Director under section 82 ;

(iv) each contract, entered into in respect of the residential building work, that forms the basis of the matter, including each variation of, and amendment to, that contract;

(v) each of the following notices and orders made or issued under the Building Act 2016 in respect of the residential building work that forms the basis of the matter:

(A) a defective work order made under section 209A of that Act;

(B) a notice issued under Division 2 of Part 18 of that Act;

(C) an order made under Division 3 of Part 18 of that Act;

(vi) each approval, or document, given, issued or otherwise granted –

(A) in respect of the residential building work that forms the basis of the matter; and

(B) under, or in accordance with, an Act; and

(b) section 79 of the TASCAT Act applies in respect of the Tribunal.

(2)  In addition to any other power that the Tribunal has under the TASCAT Act, the Tribunal may take one or more of the following actions when determining proceedings for a matter that is within the jurisdiction of the Tribunal by virtue of this Part:

(a) order the payment of a sum of money –

(i) that the Tribunal has found owing to a party to proceedings; or

(ii) that the Tribunal considers reasonable to award a party to proceedings as damages, including exemplary damages or damages in the nature of interest; or

(iii) in restitution to a party to proceedings;

(b) order the repayment of a sum of money that the Tribunal has found –

(i) was paid by a party to proceedings to another party to proceedings; and

(ii) was paid outside the terms of a contract in force between the parties;

(c) order a party to proceedings, or another person specified in the order –

(i) to rectify defective residential building work; or

(ii) to complete incomplete residential building work;

(d) if an order of the Tribunal is made that requires a person other than a party to proceedings to rectify or complete residential building work, order a party to proceedings to pay the other person an amount, as specified by the Tribunal in the order, for the reasonable costs of rectifying or completing that work;

(e) declare that a term of a residential building work contract is unjust;

(f) declare that a term of a residential building work contract is, or is not, void, including an unjust term of the contract;

(g) vary, by order, a term of a residential building work contract, including an unjust term of the contract;

(h) declare that a settlement, registered under Part 9 , is binding and enforceable;

(i) specify a period, or timeframe, in which an action, specified in the order, must be taken or completed;

(j) make any other order that it considers fair, or reasonable, in respect of the matter.

(3)  For the avoidance of doubt, an order made under subsection (2)(a) , (b) or (d) is a monetary order within the meaning of the TASCAT Act.

(4)  The Tribunal may not make an order under subsection (2)(c) in respect of proceedings if –

(a) the proceedings relate to whether residential building work has been completed satisfactorily; and

(b) an order is already in force under subsection (2)(c) in respect of the residential building work.

(5)  In determining whether a term of a residential building work contract is unjust under subsection (2)(e) , the Tribunal may take into account one or more of the following in respect of the term, the contract or a party to the contract:

(a) the intelligibility of the contract generally and of the term in particular;

(b) the consequences to the parties to the contract if the term is complied with, or not complied with, and the relative hardship of those consequences to each party;

(c) the relationship of the term to the other terms of the contract;

(d) whether unfair pressure, undue influence or unfair tactics were used to obtain the consent, to the contract, of a party to the contract;

(e) whether, at the time when the term was agreed to, the building contractor knew, or reasonably ought to have known, that the term would cause the owner undue hardship;

(f) whether the term is unconscionable, harsh or oppressive;

(g) any other factor that the Tribunal considers relevant.

(6)  Despite subsection (5)(b) , in determining if a term of a residential building work contract is unjust, the Tribunal is not to take into account any injustice that arises, or that may arise, from circumstances that were not reasonably foreseeable when the term was agreed to.

(7)  When making an order in respect of residential building work and in addition to any other matter that the Tribunal considers relevant, the Tribunal is to take into account, if relevant –

(a) what, in the opinion of the Tribunal, is the reasonable price or cost, or the reasonable price and cost, of the residential building work; and

(b) if a residential building work contract is in place in respect of the residential building work, the price or cost, or price and cost, of the residential building work specified in the contract.

(8)  The regulations may prescribe one or more of the following:

(a) the maximum cumulative amount of damages that may be awarded by the Tribunal under an order in relation to residential building work;

(b) a maximum amount of a class of damages that may be awarded by the Tribunal under an order in relation to residential building work;

(c) a maximum amount that may be awarded by the Tribunal, under an order in relation to residential building work, for any other reason.

63 Impact of termination of residential building work contract

[Section 63 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] For the avoidance of doubt, the termination of a residential building work contract does not affect the jurisdiction of TASCAT under this Part in respect of a matter that occurred under the contract before it was terminated.

64 Effect of TASCAT proceedings on residential building work contract

[Section 64 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] Subject to any order or decision made by the Tribunal, the commencement of proceedings under this Part, or the determination of proceedings commenced under this Part, does not, of itself –

(a) operate to stay, suspend or alter the relevant residential building work contract in respect of the matter to which the proceedings relate; or

(b) affect a right or an obligation of a person under the relevant residential building work contract, in respect of the matter to which the proceedings relate.

65 Court may refer matters to Tribunal

[Section 65 Substituted by No. 9 of 2023, s. 63, Applied:01 Jul 2024] The Supreme Court, or the Magistrates Court, may refer proceedings that have been commenced in the court to the Tribunal if the relevant court is satisfied that –

(a) the proceedings are within the jurisdiction of the Tribunal; and

(b) the Tribunal is the most appropriate authority to determine the proceedings.

66.

[Section 66 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

67.

[Section 67 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

68.

[Section 68 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

69.

[Section 69 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

70.

[Section 70 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

71.

[Section 71 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

72.

[Section 72 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

73.

[Section 73 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

74.

[Section 74 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

75.

[Section 75 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

76.

[Section 76 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

77.

[Section 77 Repealed by No. 9 of 2023, s. 63, Applied:01 Jul 2024]

Part 11 Miscellaneous

78 Avoidance of requirements of Act

(1)  A contract, agreement or arrangement made or entered into, orally or in writing, is void, so far as it has or purports to have the purpose or effect of in any way, directly or indirectly, defeating, evading or avoiding the requirements of this Act.

(2)  Any exclusion, limitation, modification, or waiver, of a right conferred by this Act, or a statutory warranty implied by this Act, is void.

79 Infringement offences

(1)  In this section –

infringement offence means an offence against this Act or the regulations that is prescribed by the regulations to be an infringement offence.

(2)  The Director, or a person authorised by the Director, may issue and serve an infringement notice on a person if he or she reasonably believes that the person has committed an infringement offence.

(3)  An infringement notice may not be served on an individual who has not attained the age of 16 years.

(4)  An infringement notice –

(a) is to be in accordance with section 14 of the Monetary Penalties Enforcement Act 2005 ; and

(b) is not to relate to more than 3 offences.

(5)  The regulations –

(a) may prescribe, for infringement offences, the penalties payable under infringement notices; and

(b) may prescribe different penalties for bodies corporate and individuals.

80 Proceedings for offences

Despite any other Act, proceedings for an offence against this Act or the regulations may only be commenced within 12 months after the Director first becomes aware, or ought reasonably to have become aware, that the alleged offence occurred.

81 Director may approve residential building consumer guides

(1)  The Director may, by notice in the Gazette –

(a) approve a residential building consumer guide; and

(b) specify the date on which the guide is to take effect.

(2)  A residential building consumer guide is to –

(a) contain information about the operation of this Act; and

(b) contain any other information relevant to the operation of this Act that the Director considers necessary.

(3)  A residential building consumer guide is in effect on and from the day specified in the notice under subsection (1) as the day on which it takes effect, until the day specified in a notice under subsection (6) as the day on which the rescission of the guide takes effect.

(4)  As soon as practicable after approving under subsection (1) a residential building consumer guide, the Director must cause a notice to be published in 3 newspapers circulating generally in Tasmania specifying –

(a) that the residential building consumer guide has been approved; and

(b) the purpose of the residential building consumer guide, with particular reference to section 39 ; and

(c) how and where copies of the residential building consumer guide may be obtained; and

(d) the date on which the residential building consumer guide is to take effect; and

(e) any other information relating to the residential building consumer guide that the Director considers necessary.

(5)  The Director must, by electronic means and any other means the Director considers necessary, take all reasonable steps to ensure that copies of a residential building consumer guide are publicly available.

(6)  The Director may, by notice in the Gazette –

(a) rescind a residential building consumer guide; and

(b) specify the date on which the rescission is to take effect.

(7)  As soon as practicable after rescinding under subsection (6) a residential building consumer guide, the Director must cause to be published, in 3 newspapers circulating generally in Tasmania, a notice specifying –

(a) that the guide has been rescinded; and

(b) the date on which the rescission of the guide is to take effect.

(8)  A notice of the approval of, or of the rescission of, a residential building consumer guide is not –

(a) a statutory rule for the purposes of the Rules Publication Act 1953 ; or

(b) subordinate legislation for the purposes of the Subordinate Legislation Act 1992 .

82 Guide to Standards and Tolerances

(1)  The Director may approve one or more Guides to Standards and Tolerances.

(2)  The Director may approve as a Guide to Standards and Tolerances a document that specifies either or both of the following:

(a) the quality and standards required in relation to residential building work;

(b) whether or not a building structure, or other object, created as a result of the carrying out of residential building work is defective.

(3)  The Director, by electronic means and any other means the Director considers necessary, must take all reasonable steps to ensure that copies of a Guide to Standards and Tolerances are publicly available.

(4)  The Director may rescind a Guide to Standards and Tolerances.

(5)  A Guide to Standards and Tolerances is not –

(a) a statutory rule for the purposes of the Rules Publication Act 1953 ; or

(b) subordinate legislation for the purposes of the Subordinate Legislation Act 1992 .

83 Remuneration of panel members

(1)  A member of a panel is entitled to be paid, in relation to his or her carrying out the functions of the panel, the remuneration, and the expenses (including travelling and subsistence allowances), determined by the Minister.

(2)  A State Service officer or a State Service employee who is a member of a panel is not entitled to be paid remuneration, in relation to his or her carrying out the functions of the panel, unless authorised by the Minister to be so entitled.

84 Members of panels disqualified if interested

(1)  In this section –[Section 84 Subsection (1) amended by No. 9 of 2023, s. 64, Applied:01 Jul 2024]

[Section 84 Subsection (1) amended by No. 9 of 2023, s. 64, Applied:01 Jul 2024] application means a notice of dispute within the meaning of section 45 .

(2)  A member of a panel is disqualified from mediating or adjudicating an application if he or she has a material personal interest in a contract, dispute, or party to the contract, to which the application relates.

(3)  As soon as practicable after becoming aware that he or she is disqualified from mediating or adjudicating an application, a member of a panel must –

(a) cease to deal with the application; and

(b) serve notice in writing on the Director, specifying that the member is disqualified from mediating or adjudicating the application.

(4)  [Section 84 Subsection (4) omitted by No. 9 of 2023, s. 64, Applied:01 Jul 2024] .  .  .  .  .  .  .  .  

(5)  [Section 84 Subsection (5) omitted by No. 9 of 2023, s. 64, Applied:01 Jul 2024] .  .  .  .  .  .  .  .

85 Liability of Director and members of panels

The Director, and any member of a panel, does not incur any personal liability in respect of any act done, or omitted to be done, in good faith in the performance or exercise, or the purported performance or exercise, of any function or power of the Director, or the member, respectively, under this Act.

86 Fees payable to Building Administration Fund

[Section 86 Amended by No. 12 of 2016, Sched. 3, Applied:01 Jan 2017] Any amount of money received under this Act by the Director is to be paid into the Building Administration Fund within the meaning of the Building Act 2016 .

87 Regulations

The Governor may make regulations for the purposes of this Act.

88 Administration of Act

Until provision is made in relation to this Act by order under section 4 of the Administrative Arrangements Act 1990  –

(a) the administration of this Act is assigned to the Treasurer; and

(b) the department responsible to the Treasurer in relation to the administration of this Act is the Department of Justice.

89 Savings and transitional

The repeal of the Housing Indemnity Act 1992 by this Act does not affect any right or obligation imposed on a person under that Act in respect of a warranty implied by that Act in a contract to which that Act applied before its repeal.

89A Savings and transitional on commencement of Part 6 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023

[Section 89A Inserted by No. 9 of 2023, s. 65, Applied:01 Jul 2024]

(1)  The amendments made to this Act by the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 do not apply in respect of a residential building work contract entered into before 1 January 2017.

(2)  For the avoidance of doubt, this Act, as in force immediately before the commencement of Part 6 of the Residential Building (Miscellaneous Consumer Protection Amendments) Act 2023 , applies in respect of a residential building work contract entered into before 1 January 2017.

90.   

See Schedule 1 .

90.

See Schedule 1 .

91 Legislation repealed

The legislation specified in Schedule 2 is repealed.

SCHEDULE 1 - Consequential Ame SCHEDULE 1 - Consequential Amendments

Section 90 Judicial Review Act 2000

SCHEDULE 2 - Legislation repea SCHEDULE 2 - Legislation repealed

Section 91

| Housing Indemnity Act 1992 (No. 49 of 1992) |