153 FCR 479
Carr v Finance Corporation of Australia Ltd (No 2) [1982] HCA 43
Australian Competition And Consumer Commission v Theo Holdings Pty Ltd [2000] FCA 665
Source
Original judgment source is linked above.
Catchwords
153 FCR 479
Carr v Finance Corporation of Australia Ltd (No 2) [1982] HCA 43Australian Competition And Consumer Commission v Theo Holdings Pty Ltd [2000] FCA 665
Judgment (19 paragraphs)
[1]
Introduction - Outline of the proceedings
The primary claim in these proceedings is brought by Actol Pty Ltd (Actol), which is, or was at relevant times, the owner of property at Kellyville in New South Wales, against Rise Products Pty Ltd (Rise Products), which is the manufacturer of a pre-fabricated formwork system.
Actol alleges that Rise Products contracted to supply and install its pre-fabricated formwork system on four lots on which Actol was constructing houses.
3Form Structures Pty Ltd (3Form) was a licensed building company which undertook, at least initially, the erection of the formwork for two houses.
Benth Holdings Pty Ltd trading as Gledswood Projects (Gledswood) undertook some work in relation to the erection of the formwork for two houses.
Actol alleges that the formwork constructed for the four houses was defective and seeks compensation for the cost of rectifying the defective formwork, damages for delay in the completion of the project (assessed by reference to the interest paid on a loan taken out by Actol to finance the project), and the repayment of half the sum paid by Actol to Rise Products representing the cost of formwork panels and accessories not delivered. The amount sought by Actol is $476,321.56, consisting of rectification costs of $278,133.56, interest payments of $198,208, and "return of overpayment" of $50,650.
Actol alleges that Rise Products contracted with Actol to supply and install the formwork and that Rise Products breached the statutory warranties incorporated into that contract by s 18B of the Home Building Act 1989 (NSW).
The particulars of breach identified by Actol were:
I Rise Walls were out of square;
II Rise Walls panels require additional support to be held;
III Protruding screws;
IV fibre cement panel joints screw heads protruding from panels;
V Poor join work;
VI Chipped corners of the Rise Walls;
VII Hollows and gaps in panel filling;
VIII Large cracks and blow outs on the Rise Walls;
IX obvious signs on honeycombing;
X sections of fibre cement panel formwork broken;
XI dry slump;
XII uneven fill of concrete.
XIII does not correspond with the sample / demonstration model in quality, state or condition and free from any defects
Rise Products disputes that it contracted to install the formwork. Rise Products alleges that Actol contracted separately with 3Form for the installation of the formwork.
Rise Products also asserts that Gledswood also contracted directly with Actol to undertake work involved in the installation of the formwork.
Actol alleges, in the alternative, that the formwork product supplied by Rise Products was supplied in breach of the consumer guarantees provided by ss 54, 55, 56, 57, 58, 60, 61 and 62 of the Australian Consumer Law (NSW).
Actol further alleges in the alternative, that Rise Products engaged in misleading and deceptive conduct in breach of s 18 of the Australian Consumer Law, including representations as to future matters, which conduct allegedly induced Actol to acquire the Rise Products formwork and thereby sustain loss. Actol alleges that Mr Pszczonka, a director of Rise Products, was knowingly concerned in the representations made by Rise Products.
In light of Rise Products' assertion that Actol had contracted with 3Form and Gledswood rather than Rise Products for the installation of the formwork, Actol joined 3Form and Gledswood to the proceedings and sought compensation from 3Form and Gledswood for breach of statutory warranty. Actol also alleged that Rise Products had acted as either the coordinator or supervisor of the installation of the formwork, pursuant to a "supervision contract" which also incorporated the statutory warranties, and that Rise Products had breached the statutory warranties in the performance of the supervision contract.
Rise Products brought a separate application against 3Form and Gledswood for contribution and indemnity by reason of alleged breaches of duties of care arising pursuant to the Design and Building Practitioners Act 2020 (NSW) and the common law.
[2]
The procedural history
The initial application to the Tribunal (HB 20/35833) was commenced by Actol on 21 August 2020 against Rise Products and Daniel Pszczonka. By order of the Tribunal made on 21 May 2021 Actol was granted leave to join 3Form and Gledswood.
On 8 July 2021 Rise Products filed its cross application against 3Form and Gledswood.
Actol Pty Ltd and Rise Products filed points of claim and points of defence, together with evidence, and the proceedings were listed for hearing before me for two days on 12 and 13 October 2021.
In preparation for the hearing, the parties provided a three volume Tribunal Book containing 1,413 pages. In addition, Actol provided a paginated bundle of 377 pages (Summons Bundle) containing documents produced on summons by 3Form, Gledswood and Rise Products in July and August 2021.
In the course of the hearing, I indicated to the parties that any document in those bundles referred to in submissions or in cross-examination would become part of the evidence in the proceedings unless explicit objection was taken. Subsequently Mr Healy, director of Gledswood, asked that the Tribunal treat as evidence filed on behalf of Gledswood the entirety of the material produced by Gledswood in response to the summons, that is pages 323 to 355 of the Summons Bundle.
Save to the extent that other documents in the Summons Bundle were referred to in cross-examination or in submissions I do not regard those documents as forming part of the evidence and I have had not had regard to them.
At the commencement of the hearing on Tuesday 12 October 2021, which took place by video link, Mr Soliman, solicitor, appeared on behalf of 3Form and sought that the hearing be adjourned on the basis that his firm had only been engaged the previous Saturday.
That application was opposed by Mr Carter of counsel who appeared for Actol and Mr O'Sullivan of counsel who appeared for Rise Products. The application for adjournment was refused and the hearing proceeded.
The evidence included in the Tribunal Book included affidavits filed by Mr Peter Wakefield, a director of Actol, and Mr Douglas (Bob) Woods, a site supervisor employed by Actol, on behalf of Actol, and Mr Daniel Pszczonka, the second respondent to Actol's claim and a director of Rise Products, and Mr Tim Pope, the Chief Executive Officer of Rise Products, on behalf of Rise Products. The Tribunal bundle also included expert reports from Dr Cunniffe, a building consultant, and Mr Whyte, a quantity surveyor, both filed by Actol.
3Form had not filed any evidence before the hearing.
Mr Ben Healy, the director of Gledswood, had included in the documents produced on summons a document headed "To Whom It May Concern" which set out "my recollection of events between Actol Pty Ltd, Rise Products, 3Form and Gledswood Studio". That document (pages 350 and 351 of the Summons Bundle) was received as Mr Healy's statement.
After the lunch adjournment on the first day of the hearing, Mr Mando of counsel announced an appearance for 3Form. Mr Mando sought to renew the application for adjournment. That application was rejected. The hearing continued with Mr Mando representing 3Form.
On the second day of the hearing, when it became clear that the hearing would not be completed that day, Mr Mando indicated that, if the hearing was to be adjourned, his client intended to seek leave to rely upon evidence from Mr Daniel Gharib, a director of 3Form. The hearing was then adjourned until 4 November 2021.
At the commencement of the adjourned hearing on 4 November 2021, Mr Mando sought leave to rely upon a statement from Mr Gharib. That statement had only been provided to the other parties one or two days before the hearing. By reason of particular difficulties experienced by other counsel in dealing with Mr Gharib's evidence in those circumstances, I declined to grant leave to 3Form to rely upon that statement.
Nevertheless, as the hearing was not concluded on that day, and it was convenient to adjourn the hearing for another three weeks, Mr Gharib's statement was permitted to be read and Mr Gharib gave evidence on the fourth day of the hearing on 29 November 2021.
In the course of the hearing, each of Mr Wakefield, Mr Wood, Mr Pszczonka, Mr Pope, Mr Healy, Mr Gharib and Mr Whyte gave oral evidence. On the basis that Mr O'Sullivan was at liberty to make submissions concerning Dr Cunniffe's evidence without cross-examination and no point would be taken in relation to any submission on the basis that a proposition was not put to Dr Cunniffe, Dr Cunniffe's evidence was received without Dr Cunniffe being subject to cross-examination.
Directions were made for the filing of written submissions. On 7 February 2022, before the expiry of the time allowed for the filing of submissions by Rise Products, the Tribunal received notification that 3Form had gone into voluntary liquidation on 3 February 2022 and Peter Hillig had been appointed liquidator pursuant to section 497 of the Corporations Act 2001 (Cth). Upon the appointment of Mr Hillig, pursuant to section 500 of the Corporations Act, the applications could not be proceeded with against 3Form without the leave of a Court.
The Tribunal sought an indication from the parties as to their attitude to the future conduct of the proceedings. Ultimately, both Actol and Rise Products withdrew their applications insofar as they sought relief against 3Form, and 3Form ceased to be a party to the proceedings.
The remaining parties provided written submissions to the Tribunal and Actol filed submissions in reply. The parties also provided a transcript of the hearing. Actol filed a chronology, which the Tribunal had requested. The chronology was incomplete, partial and argumentative, and in some instances provided incorrect references to the evidence. It was therefore of limited assistance. It is clearly not an agreed chronology. Nevertheless, as no alternative chronology was supplied by any other party, I have relied upon Actol's chronology where it provided apparently reliable assistance.
On 7 November 2022, I directed the parties to provide further submissions regarding two issues which it appeared might arise, being:
1. The effect of the Fair Trading Amendment (Monetary Limit on Orders) Regulation 2022 (NSW), which came into force on 18 July 2022; and
2. The decision of the Appeal Panel in John McDonald Building Services Pty Ltd v Gusa [2022] NSWCATAP 60.
Both Actol and Rise Products filed submissions in accordance with my direction and submissions in response to the submissions filed by the other. The latest of those submissions was filed in the Tribunal on 22 November 2022.
[3]
Factual background
Actol owned a property at Kellyville which it was seeking to develop into multiple lots. Actol obtained development consent for subdivision of the property and the construction of a house on each lot within the sub-division. Relevant to these proceedings was a block of six lots (the Site) upon which, from 2017, Actol was seeking to construct houses.
Actol obtained an owner-builder permit. Actol initially utilised a pre-fabricated formwork system supplied by an enterprise called Pro 9 in the construction of houses on two of the lots. Delays were experienced in the construction of those houses and Actol, represented by its director Mr Wakefield, became dissatisfied with the Pro 9 system.
Rise Products is the manufacturer of a pre-fabricated formwork system, sold under the name RiseWall, which is made up of prefabricated fibre cement wall panels which are erected in position in lieu of traditional formwork before reinforcing steel is placed within the formwork so erected and concrete poured to create the walls of the building. Unlike traditional formwork, the Rise Products formwork remains in position after the concrete has set. One claimed advantage of pre-fabricated formwork such as the RiseWall is time savings in the construction process.
In 2019 Mr Wakefield attended a building expo at which Rise Products was an exhibitor, and became aware of the pre-fabricated formwork systems manufactured by Rise Products.
On 14 June 2019 Actol provided a copy of the plans, drawings and specifications for the dwellings on the Site to Rise Products.
On 26 June 2019 a meeting occurred on the Site between Mr Wakefield and Mr Pszczonka. Mr Wakefield's evidence was that Mr Pope was also present.
Mr Wakefield's evidence was that Mr Pszczonka had said:
a. 'our product is of high quality finish';
b. 'our product is true and straight'
c. 'our product is perfect flat finish and you won't have any problems like you did with Pro 9';
d. the product goes up very fast and flexible design and compatible with all plans';
e. 'the product supersedes traditional masonry wall system by reducing costs, time and space';
and that a conversation had also taken place in the following terms:
Mr Wakefield: "You need to supply and install. Whoever you get as the installer has to be competent and have experience with using your product. I don't want anything to do with the installation."
Mr Pszczonka: "Yes, no worries."
Mr Pope: "Yes. We only use competent installers."
Mr Pszczonka 's evidence was that the conversation had been:
Mr Wakefield: "We want to use RiseWall. How do we install it?"
Mr Pszczonka: "We can put you in touch with an installer. We can introduce you to 3Form. They do lots of apartments using products like this."
On 1 July 2019 Ms Lina Hatem, Sales and Technical Manager for Rise Products, forwarded to Mr Wakefield a quote which included the supply of formwork, concrete, labour and steel and provided a total price for "S & I" of $73,247 excluding GST.
On 6 August 2019 Mr Wakefield responded, noting that he would talk to Ms Hatem.
On 7 August 2019 Mr Wakefield provided a further plan on which, Mr Wakefield stated, the "exterior walls [had been] marked up".
On 16 August 2019 Sandie Archer, Finance Officer for Rise Projects Pty Ltd (a related company of Rise Products), emailed Mr Pszczonka and Ms Hatem, providing "updated Actol quotes". I note that the quotations attached to that email are not identified in the evidence.
On 20 August 2019, a meeting took place on the Site which, according to Mr Wakefield's evidence, was attended by Mr Wakefield, Mr Pope of Rise Products, and Mr Gharib and another from 3Form (who can be identified from other evidence as Andrew Francis). Both Mr Pope and Mr Pszczonka gave evidence that Mr Pszczonka was also present. Mr Wakefield's site diary records "meeting with RiseWall and installers Tim Daniel Daniel Andrew".
Mr Wakefield's evidence of the meeting was that a conversation took place in the following terms:
Mr Pope: "This is Daniel and Andrew from 3Form. They are the guys who are going to do the installation on this job. They are familiar with the Rise Products and we have worked with them in the past."
Mr Wakefield: "Ok that's good. How long do you reckon it would take to install."
Mr Francis: "This is a piece of cake and we can do it in a week. We do this all the time."
Mr Wakefield: "Ok that's good, we will see."
Mr Pope: "Lots 3 to 6 will be done in two week, one week to complete the ground and one week to complete the upper floor."
Mr Wakefield: "Ok that's good. So you will organise things and then do I pay you as things fall due?
Mr Pope: "Yes we will organise. But you pay for materials as they fall due and this will be deducted from the final price."
Mr Wakefield "Ok. What about scaffolding? do we need to provide for the pour?"
Mr Gharib: "No we can do it off a mobile scaffold."
Mr Wakefield: "That's a bit of pressure off."
Mr Pszczonka's version of the conversation was:
Mr Pope: "This is Daniel Gharib and Andrew Francis from 3Form. They can do the installation for you.
Mr Wakefield: "Daniel, how long will it take 3Form to do the installation?"
Mr Francis: "A couple of weeks."
Mr Wakefield: "OK, that's good. How and when do I pay?"
Mr Pope: "You pay us for the product in full as you order it along the way. 3Form might invoice you in stages."
Mr Francis: "We can quote you for supply and install."
Mr Pope's evidence was that he had only joined Rise Products on 19 August 2019 and was present purely as an observer. His version of the conversation was:
Mr Pope: "Here are the installers. This is Daniel and Andrew from 3 Form. They have provided you a quote to do the installation on the job."
Mr Wakefield: "OK, good. How long do you reckon it would take to install?"
Mr Francis: "A couple of weeks."
Mr Wakefield "OK, that's good. How do I pay for all of this?"
Mr Gharib "You pay Rise for the product in full as you order it. I expect 3 Form will invoice you at the completion of each stage of the works. If 3 Form invoices you for panel supply, then you pay us directly for the panels and deduct that from what you owe 3 Form at the end. 3 Form will also arrange for steel supply concrete, concrete supply, and concrete pumping but Actol pays this directly and deducts it from their contract sum."
Mr Gharib's evidence in cross examination was that he attended the meeting with Mr Pope, Ms Hatem, Mr Woods and Mr Wakefield. Mr Gharib stated that he was only at the meeting for a short time and that "I just needed to discuss where we were going, what projects we had completed". Mr Gharib agreed that at that meeting he handed to Mr Wakefield a quotation dated 19 August 2019 (the 3Form Quote). Mr Gharib also gave evidence that Mr Wakefield said at the meeting that he was happy with the quote.
Mr Wakefield did not give specific evidence that the 3Form Quote had been handed over at the meeting, however Actol's written submissions acknowledged that it had been.
Both Mr Pszczonka's and Mr Pope's evidence was that Rise Products did not receive a copy of the 3Form Quote.
The 3Form Quote was on 3Form letterhead and addressed to Actol Developments, attention Peter Wakefield. The 3Form Quote referred to the Site and stated:
"We are pleased to quote to the above-mentioned project, our prices in the order of … $194,000 plus GST this includes the following works to the following drawings to lots 3, 4, 5 & 6
Drawings: 9/78, 10/78".
The drawings referred to were the floor plans for both floors for lots 5 and 6.
The 3Form Quote identified that included in the price were:
"Supply & place 257m2 by 4 lots super finish risewall 160
Supply & place 26 corner panels 160 by 4 lots
Supply & place 13 end cap by 4 lots
Supply & place 33 floor track by 4 lots
Supply, pump, and finish concrete to walls
Supply & place reinforcements to walls
All our work will be completed in accordance with drawings
All our work will be completed in accordance with specifications
All our work will be done in a safe manner as to work Cover NSW
All our employees will be inducted to our SWMS and site inductions"
It did not appear to be in contest that the information required to produce the 3Form Quote had been supplied to 3Form by Rise Products.
On 20 August 2019 Ms Hatem forwarded to Mr Wakefield an email headed "Rise Products Quote for Lot 3-6 Kellyville". Mr Wakefield responded asking Ms Hatem to send the email again as no attachment had come through. Ms Hatem sent a further email, which the time-stamp suggests was sent immediately upon receipt of Mr Wakefield's email.
The documents attached, or supposedly attached, to that email were four separate quotations dated 16 August 2019, one for each of lots 3 to 6, for the supply of panels, corner panels, end caps and floor tracks for the RiseWall "160 Series" formwork system. The price on each of the quotations was $25,325.30, inclusive of GST.
Each of the quotations in the Tender Bundle has attached to it five pages of terms and conditions. Actol submits that Rise Products did not supply its terms and conditions to Actol until after a contract was formed between them. Actol also submits that the terms and conditions relate to the opening of a credit account not a standard supply contract. I will address this issue, to the extent necessary, in due course.
On 21 August 2019 Ms Hatem emailed Mr Wakefield:
"Hi Peter
As per phone conversation Daniel doublechecking quantities/m2
Cost breakdown for lots 3 - 4 - 5 - 6 Inc GST
Rise Products
$101,301.20
3Form Structures
Install of Rise Wall
Supply & place of concrete and reinforcements
$113,088.80"
On 23 August 2019 Ms Hatem emailed Mr Wakefield with the subject line "Rise Products & 3Form supply & install quote":
"As per phone conversation 3Form have confirmed that they have not included GST for the Rise Products component in their quote so therefore you haven't been double charged GST.
Breakdown Exc GST-Lots 3-4 5-6
Rise Products
$23,023 per lot x 4 = $92,092
+ (GST $9,209.20)
3Form Structures
$102,808
+ (GST $10,280.80)
Hope that is clear - let me know there's anything else we need to look at."
On 26 August 2019 Mr Wakefield emailed Ms Hatem:
"Hi Lina,
We would like to give you the go ahead to supply your 160mm insulated Rise wall Super Finish.
3Form to fix the Rise wall product and supply concrete and steel.
Rise wall supply ==$92,092.00 +gst =$9,209.= $101,301.20
3 Form supply and fix = $102,808 + gst =$10,208.80 = $113,088..80
Total = $214,390.00
Do you have a standard contract or 3Form to sign or we will organise, so we have an idea on who's doing what and timing.
Regards Peter."
Actol maintains that, by that email, Actol accepted an offer made by Rise Products by the emails of 21 August and 23 August 2019.
Ms Hatem replied that afternoon:
"Hi Peter
Thank you for choosing Rise Products to be your supplier and 3Form to be your Installer.
Andrew from 3Form will contact you today/tomorrow to discuss the schedule amongst yourselves
That will then be the contract I guess between you and 3Form.
3Form will liase with us for the Fibre Cement orders/deliveries.
Let me know if you need other information
Thank you
Talk soon
Lina"
Ms Hatem attached to that email the four quotations referred to at [59]-[60] above. Actol maintains that this was the first time those documents had been provided to Actol. I will address that issue in due course.
On 3 September 2019, Ms Hatem emailed Mr Wakefield. The subject line of the email was "Actol invoices - Lot 3, Lot 4, Lot 5 & Lot 6". Mr Wakefield responded the same day: "Hi Lina, My wife said that she would pay in three lots". The attachments to Ms Hatem's email do not appear to be reproduced in the evidence. Nevertheless, I infer from Mr Wakefield's response that four invoices for the supply of RiseWall formwork were attached to the email. This inference is supported by a statement from Rise Products addressed to Actol and dated 13 September 2019 which records payment of $16,883.40 in respect of INV-3020 (reference Lot 5) for $25,325.30 and a balance due of $8,441.90 in respect of INV-3020 and $25,325.30 in respect of INV-3021 (reference Lot 6).
Between 4 September and 13 September 2019 Actol paid Rise Products $101,301.20, that is the amount identified in the 21 August and 23 August emails as the price for the supply of the RiseWall product by Rise Products.
The first delivery of RiseWall product to site occurred on 6 September 2019.
The erection of the RiseWall panels commenced shortly thereafter.
Mr Wakefield gave evidence that he observed Mr Pszczonka and Mr Pope attend the Site and provide guidance to workers from 3Form on 12 September 2019 and that he subsequently observed 3Form workers undertaking the installation of RiseWall panels on Site. It is not disputed, as I understand the evidence, that Mr Pope and/or Mr Pszczonka provided advice to 3Form in relation to the installation of the RiseWall product.
Text messages produced by Mr Gharib and Mr Healy disclosed that Mr Healy was introduced by Mr Pope to Mr Gharib and Rabih, another employee of 3Form, on 13 or 14 September 2019, as someone who was familiar with the RiseWall product and available to assist with the erection of the RiseWall panels. Rabih's surname was not, as far as I can tell, disclosed in the evidence and I will refer to him in these reasons for decision as Rabih, no disrespect is intended. On 13 September 2019 at 5:48 pm, Mr Pope sent a text message to Rabih:
"Ben Healy (second installer) and I can meet you on site tomorrow at 7:30 am.
We will try to help your team get on top of things and you can talk to Ben about helping doing one of the houses.
Will that suit you?
I need to confirm with Ben."
Mr Wakefield's evidence was that he was introduced to Mr Healy by Mr Pope on 14 September 2019. This evidence is supported by Actol's site diaries.
Mr Wakefield stated that Mr Pope had introduced Mr Healy as "one of our recommended contractors", that Mr Pope said that he had asked Mr Healy to "observe and help 3Form for a couple of hours today", and that Mr Healy had said:
"Tim has asked me to come along to assist Rise Products and 3Form with the installation and give them some tips and possibly some pointers on the best way to install their panels."
Mr Pope gave evidence that Mr Healy was introduced to Mr Wakefield as "going to be a sub-contractor to 3Form".
Mr Healy's evidence was that he had been brought in "to assist 3Form to meet their agreed deadlines, with the agreement that Actol Pty Ltd pays me directly." Mr Healy gave evidence in cross examination by Mr Carter that he did not have any discussions with any representative of Actol concerning his involvement in the project, the only connection being that Mr Healy rendered an invoice and Actol paid it.
It is apparent that Gledswood undertook the erection of RiseWall formwork on the ground floor level of two of the four houses, independently of 3Form.
Text messages between Mr Pope and Mr Healy over the period 16 to 26 September 2019 suggest that Gledswood, that is Mr Healy and employees, were engaged in the erection of RiseWall panel on the Site during that period. Those text messages also indicate that Mr Healy was dissatisfied with the RiseWall panels. In one text message Mr Healy informed Mr Pope that "the corner penetrations don't work out with the penetrations of the walking system; we are struggling with the hook bars." Mr Pope responded "those corner we[re] a rush job… The 'real ones' have identical profile to wall."
In another text message sent on 26 September 2019 Mr Pope attached a photograph of RiseWall panels and informed Mr Healy that "new panel with larger joined - coming your way soon!" Mr Healy gave evidence that that email had been sent to him in direct response to concerns he had raised about the RiseWall product.
Mr Healy also gave evidence that the product supplied by Rise Products was "completely ad hoc".
Mr Healy described the following issues with the RiseWall product:
"* Prototype product was supplied - Fibre Cement has a shelf life and the first batch of sheet delivery were extremely fragile.
* Internal/external profiles did not match the FC profile - the supplied profile was supplier in a 1.5m length for a 3m sheet and the holes for reo did not align.
* The screws were not fit for purpose - the supplied screws were not countersunk screws and we only had 10mm of 'bite' to join the sheets together, the weight of the product could not be held together with the supplied fastenings. Rise Products knew this was a problem. Hence, Tim Pope's message (attached)
* Glues and Screws - we constantly ran out of this product which made installing the product difficult. No agreement could be reached with Gledswood returning due to Rise Products constant mismanagement of their own product and ancillaries.
* The cappings provided for around window and door openings were not fit for purpose - the supplied product seemed to be a James Hardie linea board, and could not be fastened into the FC product. To eradicate this, Rise Products supplied metal angles after the install and were expecting the installers to return and install at no additional charge."
Mr Gharib also gave evidence, in cross examination by Mr Carter, that the products supplied by Rise Products were "the issue" in terms of having the formwork ready for concrete pour. Mr Gharib stated that he was uncomfortable putting concrete in the RiseWall formwork because 3Form couldn't "get it … to be stable without concrete in it". Mr Gharib stated that, when he raised these issues with Rise Products:
"They started coming up with different ways to hold it together. One way was the corners … And - where the two panels meet, put sheets of ply trying to hold the two together. There was all different avenues of trying to make it work but at the same time we had a connection ..... if you couldn't hold the connection to it enough it ….. trying to make it work but I wasn't really comfortable. That's why I didn't want to proceed."
On 2 October 2019 Mr Healy sent to Mr Wakefield an invoice on Gledswood letterhead dated 27 September 2019 and addressed to Actol Pty Ltd. The invoice was in the amount of $11,000 inclusive of GST for "Progress Claim on installation of the Rise product walling system as agreed."
On 3 October 2019 Mr Wakefield sent an email to Mr Healy confirming payment of the invoice.
Also on 3 October 2019, Mr Francis (of 3Form) forwarded an email to Mr Wakefield, copied to Ms Hatem, attaching an invoice from InfraBuild Construction Solutions for reinforcing steel. Ms Janice Wakefield, Mr Wakefield's wife who was responsible for the payment of Actol's accounts, responded suggesting that the attached invoice was not the correct invoice but confirming that the correct amount had been paid to the reinforcing supplier.
On 15 October 2019 Mr Sheldon Hutchin of Rise Projects, who identified himself as "Site Manager", sent an email to Mr Liam Porritt and Mr Pope. Mr Hutchin stated that he had attended the Site at Mr Porritt's request and had observed "the following items that cause some concern and need for questions". Mr Hutchin continued:
"1. Plumbing points will need to have large holes cut in the product to allow for pressure fitting to be fitted, how do these get patched and keep the same aesthetics.
2. Electrical point will need to be installed using mounting blocks, yes?
3. Internal corner plastic angles warp in the heat of the day, how do these get finished?
4. External corner plastic cover moulds on internal walls, how do these get finished? Setting with plaster will not adhere to the plastic
5. Current screws being used to pin sheets together strip thread before pulling into FC Sheeting, this may cause sheets to split under load of pour. This was seen today at Charles street on walls that were maximum 1400mm high. 3000mm walls will have at least 3 times the load on them when pouring. Can an alter all screw be sourced?
6. FC Sheet inserts around window reveals need to have holes at sequential spacing to ensure it adheres/binds with concrete when poring. I believe they will just pop of if left as they are now when stripping formwork.
7. Current sheets have tongues that vary in width from 10mm to about 20mm, this causes issues pinning sheets together. Is this normal practice or quality of materials supplied.
8. 3000mm high panels seem to flex in the middle, possible deflection under pouring loads. I believe knee bracing would be required to prevent this.
9. Timber battens and props are not sufficient for this product. Installers would need a $ figure to supply Top Hats and adjustable tilt braces so walls can be monitored and adjusted if required during pours."
Mr Hutchin attached photographs to the email on which he had inserted comments:
"Screw with fine thread suitable for use in metal not plastic as it will strip under pressure easily."
"Joining tongues range from 10 mm to 20 mm, very inconsistent."
"Screw heads do not bite enough into FC [fibre cement] sheeting and are proud of wall surface."
"Joining tongues behind FC sheeting are to narrow, this causes screws to fracture sheeting and then relies on screws to hold in plastic rib only."
The photographs on which the last two comments were inserted showed screws driven into panels, presumably RiseWall, which had cracked in the region of the screws.
Actol relied upon this document as evidence that the RiseWall product was not fit for purpose or not of acceptable quality. Rise Products disputed that the document could be relied upon in that manner. I will address this issue in due course.
On 18 October 2019 Mr Pope emailed Mr Gharib and Mr Healy (copied to Mr Pszczonka and Ms Hatem). The email was headed "Kellyville/Actol - Pre-pour Review":
"Firstly I was good to see 'light at the end of the tunnel' for finishing the ground floor walls before filling.
Further to today's pre-pour review I hereby share the following as my insights as to what you need to keep an eye on/address before pouring concrete
1) Rise Wall is a finished wall-so ultimately the walls must be straight, plumb & square. Bob (and Peter) have reiterated this numerous times so please make sure you have doubled checked this. I believe this needs to be done with a string or laser line. The external face will rendered so you have some tolerance but the internals are intended to be set & painted.
2) Screw fixings that are not going to be removed need to be flush for setting-especially in the setting rebate at the joints
3) Screw fixings are supposed to be 250mm centre in every joint, bottom track etc-I noticed areas missing screws and this spacing being longer. This will risk the panel failing during the pour.
4) Steel reinforcement needs to be completed as per the drawings provided by Actol. Some things that I noticed are;
a. Starters bars need to be at even centres.
b. The detail over the larger opening (some windows and garage door) needs to be completed
c. Corner hook bars and vertical bars need to be double checked You need to make sure Actol get the engineer to inspect once you are completed
5) Check bracing and alignment whalers are tight and strong-otherwise the wall may move during pour
6) Ends & corners still need to be completed is some areas
7) The top of panels need to align at the same heights-otherwise you will not be able to finish the top of the concrete pour level for the next panels to be installed;
a. I noticed with Lot 3 (first house) there is change in level where the rebate stepped down - I suggest you resolve how to address this with Actol
8) Window and door openings- I assume you have double checked these. Otherwise they are going to be hard (and expensive) to correct
9) External Corners-you need to make sure these are aligned, square and vertical. Otherwise they won't be able to adjust these later;
a. I have advised several time that one corner on Lot 3 (the first house) at the lower level near stair is not properly installed - I suggest you try and resolve how to rectify this with Actol.
10) Gaps-there are a lot of gaps, holes, especially around openings that will need to be filled to make sure core filling does not 'escape'
You suggest you also make sure Actol (the builder);
1) Fill the gap at the bottom of the panels where the rebate was wrong-otherwise the panels may blow-out here due to no fixings
2) Finish their services and make sure they are 'sealed' and firmly fixed
With regards the concrete pour, Actol confirmed 3Form are responsible for placing the concrete including access. There are four houses and three different levels for each so I suggest this gets planned asap."
On 29 October 2019 Mr Gharib emailed to Mr Healy a copy of the 3Form Quote. Mr Healy responded the same day in an email copied to Mr Pope and Ms Hatem,:
"Thanks Daniel. Is there a monetary breakdown for labour vs material? As agreed upon last Tuesday, I am after a breakdown for the two dwellings we are completing. Currently, I only have the capacity to complete the 2x jobs we have commenced in Kellyville."
Shortly thereafter, Mr Pope emailed Mr Healy, copied to Ms Hatem:
"Lina - please confirm for Ben what Rise Products supply quote was that needs to be deducted from this. Ben FYI it was around $94k
Ben on this basis the budget for two dwellings is 50k for
1) install of panels
2) supply and install of reo
3) supply, pump and place concrete
Peter can advise reo supply to date and that cost can be halved and deducted from the 50k.
I am sending this FYI to try and assist but as you are trying too you need to get these agreed with 3Form".
Site diaries maintained by Mr Wakefield suggest that 3Form ceased to attend the Site after 6 November 2019.
On 6 November 2019 Mr Pope sent an email to Mr Healy:
"As discussed - I have prepared the attached a spreadsheet as an initial 'attempt' to breakdown the quote for Units 3-6 (four houses).
None of this has been discussed with 3Form at all.
I am simply trying to share with you how I understand the 3Form quote came together
This being with the view to seeing if you/Gledwood Studios is willing & able to take over the project from here and finish it.
I just want to try and get this project done & dusted for Peter/Bob/Actol so we can all move onto the next one.
In doing this I have;
1) Used the Rise Wall panel supply take off for the basis of quantities
2) Calculated the volume of concrete based on the 160mm insulated panel (internal width of 110mm) and deducted the windows and doors;
a. I have applied an estimated $220/m3 for concrete supply (only) - this needs to be verified
3) Estimated the cost for reinforcement for the project at $8k-Actol is going to give us the cost to date tomorrow so we can assess this and adjust if required
4) I have assumed we are going to need to two concrete pours for each level (four pump visits to complete the project) as follows;
a. First pour up to window sills and 1m all wall via a line pump-done from concrete slab and scaffolding. This will require 3 agitators which we can space out by an hour each (at least);
i. I have assumed $1k for pump hire for the day-this needs to be verified
b. Second our using a boom pump to place the remaining 2m This will require 7 agitators which again we can come back to back but will allow at least 1 hour between pouring on-top of each other;
i. I have allowed $2k per day for boom pump- this needs to be verified
5) I have allowed $2.5k for the additional prop hire and purchase of the angles for the windows
6) I think the above has 'some fat in it' (TBC) and comes to a total of $44k;
a. Let's do some homework on quotes from pump hire and concrete suppliers to verify this
When this is deducted off the $102k budget remaining after panel supply-leaves $59k for installation of panels or around $58/m2
Based on this m2 rate .
3Form is due approx. $15k for two houses GFL only-I suggest for this they need to come back and strip their materials and take them away once the walls are poured. .
Gledswood is also due this for the 2 GFL-less what you have been paid to date ($10k)-would mean you get another $6k (roughly). .
This would leave $28k for the 4 x LV1;
o Based on needing 4 men for 3 weeks at $350/day/man to complete these floors this would total $21k leaving around $6k margin (or 24% profit on labour).
Noting that in doing the LV1 you will have;
the new panels with the extended glue tracks
corners with aligned punch holes
props for every panel
metal angles for every opening
So based on the above (albeit a 'first cut') I would have thought this looks doable.
If you can have a look at this and then let's discuss your thoughts around 'tidying' this up to reach a decision."
Mr Healy responded that evening:
"Thank you sending this through.
Please find amendment attached.
If we are in agreeance with your attached $/m2 rate, then I have attached the actual breakdown of costs thus far. Also, I want it recorded that any works that Jarrod B Carpentry performs, and invoices, does not affect my allowance of funds for the job.
Using your spreadsheet, I believe the figure will be closer to the $23k, without taking into consideration the additional delivery costs, etc
Less the $3k for the ply sheeting.
Also, who pays for the crane to lift the product to the first floor?
Who takes responsibility for any blowouts/bulging?
Giving us extended glue tracks is great, but the amount of cutting for the upper floors of this project is going to be excessive in time consumption on this job.
Who is to supply the additional plyboard to secure the connection between sheets? There'll be $3k worth of product just for that.
There's a reason why 3form are attempting to shun their commitment to Peter.
$350/day for 5x days = $1,750
Less 9.5% for superannuation is $166.25
Less Income Tax is $443.00
Equates to $1,140.75 a week, or $228.15c a day (with no contingency of leave loading)
Unfortunately, I don't have a labour force that will be viable on the proposed day rate.
And I certainly don't work for that amount of money.
Respectfully, I'm going to pursue the remaining part payment of $7,754.28 + GST with this job and walk away."
On 7 November 2019 Mr Pope and Mr Wakefield exchanged emails concerning amounts which had been paid to 3Form (or more accurately to the steel supplier for reinforcing).
Mr Pope sent a further email to Mr Healy on 12 November 2019:
"Please see attached a further developed breakdown of Kellyville.
I have included actual rates for supply reo (to date), concrete quoted by Hymix and concrete pump as quoted.
Unfortunately the reo costs to date have been higher than the first estimate so Dan (and I) have agreed to cover the cost of the props and angles.
You will see I have deleted the $3k for form ply as this should be able to be re-use materials from GFL on the first.
I have left the labour to complete as per your response.
I have had a discussion with 3Form and they are prepare to hand the contract over (from here) if they can get paid $15k + GST.
Dan we will back on site on Thursday with Jarrod to make sure we get the window angle openings completed.
Dan also has spoken with the scaffolder RP use, and they are quoting the project ASAP - so let's assume at this stage (but to be confirmed) that there will be scaffold to pour concrete off.
With regards placing concrete we propose to use the concreter that does Rise Projects work, and Dan (and I) will be on site during the pours. As per the spread sheet we propose two days pouring for GFL - Day 1 (1/3rd all walls all houses), Day 2 (2/3rds all walls all houses). If there is any 'blow-out' we just need to have you and one other on site to cut-out and replace form-ply. Based on this, this risk would seem managed.
Rise Products has the new panels & corners in stock - and with all the props and angles from GFL should enable a really 'clean' installation on Level 1 - the final training run!
So based on all the above it looks like the project can be completed within the remaining contract sum.
If you can take over the contract (with 3Form getting $15k) Dan & I can then work with you to get the project finished - hopefully on a good note.
This would see us all ready to take on GWH (in a about a months-time)
Could you have a read of this, and look at the spreadsheet and let me know your thoughts."
Mr Healy responded on 13 November 2019:
"Everything considered, including the spreadsheet and 3form's ability to simply walk away from the Project.
Gledswood will not be returning to Kellyville.
If 3form will still get paid the $15k, even after Jarrod finished their work, then I will opt for the same exit strategy.
Please instruct Jarrod to complete the angles on our units also (less the ones we have completed), and like 3form, I will not be footing the bill for Jarrod.
I will return to site to remove my props and braces when suitable.
I will advise Peter from Actol of my decision.
If 3form get $15k, I'll be electing for $16k, as my reo is completed and Jarrod will be there for a week finishing their Door openings.
These window angles should have been delivered originally with the product, not after we have completed the window openings.
And better still, only half the product showed and we run out of screws! Who pays me for a return trip??
The installer is footing the bill for all these amendments with no means for remuneration.
And I am not convinced that the First Floors will be any different."
Mr Pope replied to Mr Healy:
"Noted an understood.
Could you agree to not advise Peter/Actol until Dan and I have spoken with him?
We also need to resolve 3Form so we we aim to go and see them Friday
if not - just let me know and we will work around this".
On 14 November 2019 Mr Wakefield emailed Mr Pope:
"Further to our phone conversation yesterday, can you confirm that 3 Form and Ben from Gledswood Projects will not be returning to the site and that Rise Products will be finishing 3 Forms Lots 3 and 6 lower ground floors. Then who will be doing the upper floors and what time frame is this to take. If 3 Form are no longer want to do the job who will the contract be with. This is not what was sold to me at the meeting, there were all the promises of we'll do this in a week and it'll be true and straight. At the moment there are corners out of square and walls out of plumb. Steel to go in various places. I know that you are here on Monday to start to rectify this work ready for a pour."
On 15 November 2019 Mr Pope emailed Mr Wakefield:
"I would like to hereby clarify Rise Products offer to help complete the installation of Rise Wall to Units 3-6.
3Form (the Contractor for installation) and Gledswood Projects (3 Form subcontractor) have progressed the GFL panel installation to point almost ready for core filling. There remains some further works around installing additional bracing to the window and door openings, installation of steel reinforcement over the larger openings, gap filling, final screws fixings and squaring off and aligning panels.
We acknowledge 3Form and Gledswood have had difficulty in undertaking the installation for various reasons associated with working with new product.
Rise Products is frustrated (as we understand you are) as to the progress to date (and time taken) and would like to see Rise Wall installation completed competently from here.
Rise Products has spoken with 3Form (and Gledswood) whom have (both) expressed their desire to look at another way to complete the project without their further involvement (if possible).
With this in mind, Dan Pszczonka and I (Rise Products) have agreed to offer to take over the completion of the Rise Wall installation (from here) if this is amenable to yourself (Actol).
This offer is based on the following:
1) Rise Projects will take over the contract based on the quote provided by 3Form (refer attached).
2) Actol does not pay 3Form any monies. We understand Actol has paid Gledwood $10k (please advise if this is not the case) and similarly we would request no further monies are paid to them. Rise Projects will make arrangement to pay these companies for the installation work completed to date upon completion of the GFL core-filling.
3) Rise Products will manage the installation of Rise Wall going forward.
4) Upon completion of the GFL core filling, Rise Products will receive payment of;
a. Installation of GFL panels -$35k less $10k (tbc) = $25k
b. Concrete supply and place - $20k
5) On completion of core filling the first level panels Rise Walls, Rise Products will receive payment of the remaining contract sum less the cost of steel reinforcement supplied for the project
6) Actol will provide scaffolding access to place concrete from in between each unit as well the external side of Unit 6
The proposed timing is as follows;
1) Agreement reach between Rise Projects and Actol (ideally today)
2) Upon written agreement (as above) Rise Project will recommence on site to complete the work to pour GFL walls. The aim being by the end of next week (weather permitting).
3) Actol completes scaffolding in readiness for concrete pour by the end of the week.
4) Rise Products recommences first floor panel installation when Actol completes the first level flooring and perimeter scaffolding (all units) for edge protection.
I trust the above is clear and received favourably and in the vein intended, being an offer assist Actol getting the installation of Rise Wall completed. We look forward to your response".
A copy of the 3Form Quote was attached to that email.
Mr Wakefield responded on 16 November 2019:
"Yes we have paid Gledswood Projects $10,000.00 + GST = $11,000.00.
I don't know where you are getting your figures from, my calculations are 3 Forms total price was $102,808.00 the SQ mts are nearly the same for bottom and top floors.
Divide it by 2 = $ 51,404.00 less steel of $10,491.92
$ 10,491.92
= $ 40,912.08 Less $10,000.00 to Gledswood
$ 10,000.00
= $ 30,912.00 plus GST This includes the $20,000.00 for concrete and pump.
If you disagree with the split then we will remeasure.
ACTOL PTY LTD dose not agree with your figures. If you feel you need to put angles on the corners then you need to put them on. 3 Form and Gledswood need to rectify their work immediately.
We brought your rise Wall Super Finish on the proviso that it was installed by competent installers and a concrete pump handler. We also based our decision on your (Tim) and Dans words to the effect 'This will go up in no time and be straight and square, you'll have no problems with this. 3 Form also confirmed this at the meeting and said that it would be done in a week. We didn't think it would be done in a week but did think 3 weeks was reasonable. It has been 9 weeks and still not finished ground floors.
You put the blame on the installers, but Ben from Gledswood Projects, you Tim asked him to come and see 3 Form install the walls for the first time and to give them any tips on how to do it easier.
After seeing it installed and talking to the installers, you and Dan I think the product needed modifying because it the installers were having a hard time at it. Admittedly 3 Form were new and Ben was good at installing it.
Now you have to pull out all the blocking to window openings and put metal angles because of a big chance it could blow out at those points.
In the meeting the question was asked to 3 form 'do you need scaffolding to fix or pour' no we use mobile scaffolds and move them around. We asked what about the braces, they are no worries was the answer.
Based on the way the ground floor walls were done and the time it has taken and you guys new about the time it was to take to install, we will not be doing the upper floors and will seek a full refund of upper floors that was paid in good faith."
Actol maintains, in the alternative, that if Rise Products had not contracted to install the RiseWall formwork on 26 August 2019, then from 15 November 2019 Rise Products "actively became '… Involved in, or involved in coordinating or supervising, any work involved in the construction of a dwelling'". I do not understand that Rise Products disputes that Mr Pope and Mr Pszczonka became more actively involved in the completion of the installation of the formwork and concrete after mid-November 2019, but Rise Products does dispute that that occurred pursuant to any contractual arrangement.
On 19 November 2019 Mr Pope emailed Mr Wakefield:
"As discussed this morning Rise Product will endeavour to assist 3Form to complete of the GFL (Units 3-6) in accordance with their quote/agreement.
We will proceed to mobile resources back to site to complete the final works in readiness for concrete pour.
Ideally you could please arrange for scaffolding to the perimeters to facilitate access for the concrete placement."
On 20 November 2019 Mr Pope emailed Mr Gharib:
"As discussed with Rabi last week, Rise Products has been unable to reach agreement with Actol/Peter to step-in and take over the contract to complete the work on this project.
Peter is insisting that 3Form complete the ground floor and that he does not want to proceed with L1.
He has verbally advised that he will pay for GFL based on the pro-rata m2 when this is complete.
He has advised he will not pay Gledswood/Ben any more money.
Based on the above, in the same vein as to what Rise Products was trying to achieve that being us assisting 3Form finish the project and get paid under the contract we are willing to;
1. Supply adjustable propping to assist with aligning the wall -250 props are already on site and partially installed. These cost $3/prop/week and we will aim to get these off-hired within a month - approx $2.5k.
2. Supply metal angles to all opening to reduce the risk of bulging during concrete placement - 50% of these are installed and remainder are delivered to site. These costs around $3.5k
3. Provide labour to complete the work in readiness for concrete placement. We have already had three men for 3 days and envisage this will require 2-3 more days - around $3.5k
4. Provide additional supervision to assist with the concrete pour/s
We intend to get guys on site (as per Item 3 above) tomorrow and aim to finish everything this week.
Based on the above, 3Form will need arrange concrete pumping next week. We recommend that you be prepared to do this over two days to reduce the risk of any blow.
We also recommend that 3Form arrange concrete supply that Actol pays for- so that you get this at the best possible rate so the least amount is deducted from the contract sum.
One house has been scaffolded and we have requested Actol prepares the others but there is some likely-hood this won't happen in time. On this basis we need to be prepared to place the concrete via our own means of access as per the original quote.
FYI Peter is also demanding Rise Products refund the panels specially made (with insulation etc) for L1 - this is an argument RP will try to resolve directly with Actol.
We all acknowledge this project has been less than ideal, however the only thing to do is finish the GFL scope to be able to get paid.
Can you please confirm that you are Ok to proceed accordingly."
The Site diaries maintained by Actol disclose that on 26 November 2019 Mr Wakefield was injured falling "through roof" and was taken to hospital. It is also apparent that WorkCover closed the Site until 29 November 2019 (seemingly after scaffolding had been installed) and that Mr Wakefield was discharged from hospital on 2 December 2019.
It is not in dispute that the initial concrete pour occurred on 18 December 2019. The Site diary records that Mr Woods was on-site with two labourers for Actol. The annotation in the Site diary regarding the concrete pour is:
"Danny [Pszczonka] controlled the pour. Pump concrete to half of walls. Rise Products 4 = Tim, Jarrod. HD projects pump people 2."
Concrete Sales Pty Ltd trading as concretesales.com.au issued an invoice to Actol on 18 December 2019 for delivery of 35 m³ of concrete on that date. HD Projects Pty Ltd rendered an invoice addressed to Actol for concrete pump hire on 18 December 2019. The invoice was dated 31 December 2019 and emailed to Actol on 6 January 2020.
Jarrod B Carpentry Pty Ltd issued an invoice to Rise Products Pty Ltd on 14 January 2020. The invoice included charges for "Pour bottom half of rise wall with Tim", "Fix reo to engineer spec with Tim", "Pour top half of rise wall with Tim and J'Maine" and "strip braces, angles and formwork".
It was not disputed that Jarrod B was Jarrod Bordecino (or Baldocino) and that he had attended the concrete pour on 18 December 2019 at Mr Pope's request.
On 8 January 2020 Mr Wakefield emailed Mr Pope:
"Rise Products Pty Ltd. 6th January 2020
Attention Tim
Tim, I draw your attention to the placement of reinforcement and concrete at [the Site].
After our discussions, on several occasions, about the incomplete steel reinforcement and inadequate bracing to the garage door lintels, you have placed concrete in these areas before rectifying any of the errors.
After inspecting all lintels we have found,
reinforcement bars are not lapped as required,
sitting on what we believe to be the board forming the soffit of the lintels leaving insufficient concrete cover,
areas of hollowness in the poured portions of the walls
and excess concrete on the reinforcement bars preventing or obstructing the future pouring of the concrete into the unfilled portions of the walls.
Bob Woods has pointed out to you on several occasions the poor and incomplete state of the reinforcement and each time you have stated you would fix it prior to placing the concrete.
On Wednesday 18th December you informed Bob Woods that the pour would not proceed past the height of the bottom of the lintels however you then placed the concrete to the top of lot 3.
Actol Pty Ltd has offered throughout the exercise to assist in the placement of the steel and you have stated that yourself and Jarrod would complete it prior to pouring, the latest was on the day of the pour when Bob Woods suggested you come to Site on the following day with Jarrod and together with Actol Pty Ltd, would complete the rectification but you refused the offer.
We understood the pump- operator was experienced in placing the concrete in this type of wall, it appears he was not instructed correctly or he was not willing follow the instructions and as a result we have concrete in all lintels preventing the completion of necessary steel reinforcement.
Bob Woods was forced to stop the operator from pouring concrete into various lintels but his reaction was to state he was unable to stop and start his pump to move to another area every five minutes.
I was under the impression that you were only going to pour concrete approximately halfway up the walls on all four lots only.
After our meeting with you Tim on 7-1-2020, we did further inspections of lot 3.
We removed the soffit linings from the back-sliding door and window.
We found no cover on the vertical reo bars of the sliding door and there appears to be no vertical reo bars to the dining room window.
The engineer is on holidays until the 13-01-2020. I understand that you have other work pending, but on our site there is still sufficient work to do without an engineer's inspection. If you want to wait for the engineer to inspect then the further delay is your responsibility. We will organise an inspection ASAP with the engineer.
We would also like to know in writing as to how you are going to rectify the blow outs,concrete hollows in the walls, bowed walls including humps and hollows to the skirting and cornice lines.
Actol Pty Ltd now require those responsible, be it 3Form, Rise Products or their subcontractors, to remove all necessary concrete, reinforcement steel, and formwork then replace the same to achieve the promised quality result for this project."
Mr Pope responded on 10 January 2020:
"Rise Products has a supply only contract and is assisting in completing this project.
We planned to pour the walls on Friday 20th January but unfortunately had to cancel due to not being able to access the necessary labour resources (due to bush fires). The reinforcement adjustments were going to be done in the morning prior to pouring concrete.
Rise Products re-planned to complete the second pour this week and I attended site (on Tuesday) to arrange this. Further to identification of the remaining reinforcement issues Jarrod and I will attend site on Monday to address these.
If an engineer inspection is to be made we would require this done on Monday afternoon and would like to attend this.
We have only been able to book the 45m boom pump on Tuesday afternoon (TBC). HD projects advises this equipment will likely not be available for the rest of the week as they have a large project for Macquarie University.
Rise Products also has to re-allocate resources after next week which will make it difficult to advise when we could then assist to complete the second pour.
The completed works will be assessed (for defects) once completed.
I trust we can work together as above in the interest of getting the GFL wall filled so the following works can commence".
Mr Wakefield replied on 12 January 2020:
"You have a short memory, at the start I made it very clear that I did not know much about your product and therefor was not interested in just buying your product and installing it myself. The deal was that for me to buy your product you also had to organise an experienced installer to do the job. Your first choice of contractor was Clyde from H D Projects who gave you a price of $60.00/sq mtr, this was to dear so you went to 3Form who were cheaper. It turns out that they have not installed this material before and that this was their first go at it. You had Ben from Gledswood Projects to come out to oversee them doing the installation and to provide feedback to them on the best way to do the installation. They were obviously struggling so you engaged Ben to do lot 4. This was to show 3 Form on how to install it. You've had a falling out with both contractors because of price and this is where we are at now. Dan, Lina, and you were so confident that your walls would be straight, square, plumb and true. In everyone's words you were saying "you won't have a problem with these walls and we'll do the bottom four lot walls in a week. How many weeks later is it now?? Tim I think you need to look at what you've said before because the more stories you tell the hole just gets bigger."
The second concrete pour took place on 14 January 2020. Concretesales.com.au issued an invoice to Actol on 14 January 2020 for the delivery of 19 m³ of concrete on that date. HD projects issued an invoice to Actol on 17 January 2020 for concrete pump hire on 14 January 2020. DJK Carpentry and Construction Pty Ltd issued an invoice to Rise Products on 15 January 2020 for "day labour hire" for apprentices and tradesmen (three days in each case). Actol's Site diary for 14 January 2020 records both Mr Wakefield and Mr Woods being present together with two labourers. The diary records "Pump the rest of walls, Rise Products 3 - Tim Jarrod +1, HD projects 4."
In late January 2020, 3Form, assisted by Rise Products, sought to recover payment for work carried out on the Site.
On 22 January 2020 Mr Pope emailed Mr Gharib setting out a calculation of the amount which he apparently suggested should be the subject of a payment claim to be issued by 3Form to Actol. The calculation proceeded by determining the remaining contract sum, calculated by deducting from the amount of the 3Form Quote the amounts paid by Actol to Rise Products and others, for RiseWall panels, reinforcement, concrete supply and the concrete pump, dividing that by two (to give a price for the installation of the ground floor RiseWall), deducting the $10,000 paid to Gledswood and deducting a further 10% of the amount so calculated for defect rectification.
Mr Pope stated:
"Please see below and attached for how I see the payment claim. Happy to discuss. I highly recommend you submit this done strictly in accordance with the Security of Payment Act."
On 3 February 2020 Mr Gharib forwarded to Mr Wakefield, copied to Mr Pope and Ms Hatem, an email attaching a tax invoice on the 3Form letterhead addressed to Actol for "Works completed to date - LOTS 3, 4, 5 & 6 Installation ground floor Rise wall". The invoice stated "This claim is made under the security of payment act NSW".
That evening, apparently not having realised that the invoice had been forwarded to him, Mr Pope emailed Mr Gharib:
"Please send me a copy of the invoice if you can so we can double check it for compliance with Security of Payment as well as be prepared if/when Peter Wakefield calls.
That said, if he does call us - we will redirect him to you."
On 6 February 2020 Mr Wakefield emailed Mr Pope:
"I emailed you on the 16 - 11 - 2019 stating that we are not going ahead with your product and would seek a full refund of top floor walls that was paid for.
We are asking you to refund the monies and a breakdown of how you arrived at the particular $ amount you think it needs to be paid back."
Also on 6 February 2020 at 9:35 am Mr Wakefield emailed Mr Gharib:
"I don't know where you got your $26,528.56 from because it is less all other associated cost to finish the walls also we have additional costs to add relating to cleaning the site, checking poor standard of works. Can you give me a break down of how you arrived at this price?? Further more you pulled your men off the site and were not coming back and it was left up to Rise Wall to negotiate a new agreement to take over the contract at more costs. Rise Wall now claim that they were now working for you to finish the job. I think that you had better get out here and see the standard of work that you 3Form and Rise Wall have done because it is very unprofessional. Until all the defects, of which are to numerous to list are fixed we are not paying any monies."
At 10:25 am Mr Wakefield forwarded a text message to Rabih, of 3Form, attaching a number of photographs with the comment: "Hi Rabih, this is mostly what Rise Products did on your behalf. Peter".
124 The text message is evidenced by screenshots from a telephone apparently belonging to Rabih. The screenshots included in the evidence include, above the photographs, the message:
"Bob Rise Products was helping 3Form. You will need to liaise with 3Form from here. That said I am speaking to them daily so will pass this on also."
The evidence does not explain the source of this message.
At 1:58 pm Mr Gharib responded to Mr Wakefield's email, copied to Mr Pope:
"I dont understand what you really are trying to say we have a contract and you breach it the second you decided to pay be [sic Ben] with out my aprovel you payed rose without my aproval you got other contractors to carry on my work so please lets not go down this road i have acurd alot of damages due to the fact that you went around paying people that i had to sighn off on so this invoice stands and will not be negotiated
I dont care what has to be done but the fact that you decide to pay ben and not 3form tells me that there was so.e sort of agreement between use so im not going to turn this into prove whats mine or else i submit the hole invoice since 3form havnt reseaved a dollar yet and you are not to pay people with out my concent".
Mr Wakefield replied:
"You need to talk to Tim as he organised Ben to check on your workers and to provide any tips on installation. That was on a Saturday the next thing he turns up on Monday and says that he is doing lot 4. What went on between you three for him to start lot 4 is beyond me. He finished lot 4 and did lot 5 with your approval. I haven't engaged any trades to install your walls."
Mr Pope emailed Mr Gharib at 8:44 am on 7 February 2020:
"I am happy to meet this morning if you wish - just let me know when and where suits. That said I also recommend you follow the security of payment process (exactly) so you can action this claim under this process to try and get paid. I will look into what we understand the next step to be and let you know but there is plenty on the internet you can read also."
Mr Gharib replied at 8:55 am:
"Stop talking to me about payment acts i not going there court for your fuck up you were going to sort it buddy".
Mr Pope responded at 9:04 am:
"The only reason I am talking about the Security of Payment Act is because it is the legal mechanism in NSW to deal with construction related payment disputes. If you follow this - you have the best chance of getting paid. I acknowledge this is not something you normally have to do, so we are trying to help you with this, but it has to come from 3Form as you have the contract with Actol. The process is not hard to follow-albeit it does need to be followed strictly to enable it to be enforced. I can come and see you and/or give you a call to discuss."
At 2:13 pm that day Mr Gharib emailed Mr Pope, Ms Hatem and Mr Pszczonka:
"I find it really disrespectful the way you are treating 3form I have attached pictures that peter sent your guys made the walls worse
And you have told him that you are only a supplier and have nothing to do with installation
If so why did you bring ben into the picture he made it go wrong it was a test we were your guinea pigs Peter doesn't want to pay and you have the nerve to tell me take him to court
That's is a very wrong move mate I wanted to do one house to test the product and then the next one go smooth but you decide to bring in your friend and make deals with him then he gets payed and we don't I find that rude and irresponsible then I ask for a quote and you want to charge accessories and the same rate you give everyone else know we are just a number in your books
Mate this is not on you also changed you word 3 times at mascot every time its only in your best interest beside that you have also offer Andrew a job when we first me
So I'm sorry but I will not be copping the loss at peters job it was all your fault thing went wrong Please explain to me why I should use rise after all this afs give me a excellent product and same rates no games plaved im not there trial
You have given me the same rate you give everyone even though I was the first to try your product mate it is a joke I would like to have a meeting and you are yet to organize it
I have tried getting you
Decode
Getani
Mascot 2
Clovely
I told shane your product was good when they called me
I tell everyone about rise and this is what I get
This is socking I want to sort it out asap it's a joke even the invoices get are not right mate so please get back to me and I cc your partner daniel and lena because id like them to be at the meeting".
On 8 February 2020 Mr Pope and Mr Gharib exchanged emails concerning the holding of a meeting "to discuss and try and resolve (or at least agree a way forward) to the issues you [Mr Gharib] have raised".
On 13 February 2020 Mr Wakefield emailed Mr Pope:
"It's been a week and no response on a refund, so does this mean that I have to pursue other channels to get my monies."
Mr Pope responded:
"I apologise for the delay. We will provide a response as soon as possible."
Also on 13 February 2020 Mr Wakefield emailed Mr Gharib:
"It's been a week and you have not bothered to say whether you want to come and inspect the defective work done by Rise Products supposedly on your behalf. If I don't here from your ASAP then it would be apparent that you are not interested in rectifying any of the defects. You will leave me no options to pursue legal channels."
Mr Gharib responded:
"Hey champ I will come out this week but you have breached contract by paying other contractor so the recefication will have to be done by rise".
Twenty minutes later, Mr Gharib replied again:
"I will come me and the boys from rise and meet on site I will get back to you tomorrow on and day and time".
On 17 February 2020 Mr Pope emailed Mr Gharib attaching a "Security of Payment template" and suggesting that Mr Gharib cut-and-paste the document onto 3Form company letterhead and submit it to Mr Wakefield.
On 21 February 2020 Rabih texted Mr Wakefield:
"Hey Peter, I've spoken to rise walls will be organising a meeting for next week, I'm just in a meeting couldn't answer your call mate".
Mr Wakefield forwarded a further photograph to Rabih at 1.15 that afternoon, commenting:
"this is the shoddy workmanship that we are finding that Rise Products have done. There's a lot more to see. Get on to them and organise a time early next week. I want to put in my windows."
Rabih and Mr Wakefield exchanged further text messages over the following days relating to the arranging of a meeting with Rise Products.
On 27 February 2020 Mr Gharib forwarded to Mr Wakefield a document on 3Form letterhead, headed "Payment Claim", seeking payment of $29,191.41 for "work carried out to 30 January 2020". The document stated "This is a payment claim under the Building and Construction Industry Security of Payment Act 1999 (NSW)." It is apparent that Mr Gharib had forwarded that document to Mr Pope on 18 February 2020 presumably for his comments/approval.
Mr Wakefield responded the same day:
"We have no problem paying for work completed. But in this circumstance whether you 3Form or Rise Products have done such defective works that we will not pay any monies until the defective work is rectified to a industry standard. We also have back charges because you walked off the site and Rise Products had to complete the works. This will be all discussed at tomorrows meeting. For the record I reckon your invoice figures are wrong."
It is apparent from the text messages exchanged between Mr Wakefield and Rabih referred to above that the meeting referred to in Mr Wakefield's email was cancelled because Mr Pszczonka could not attend.
On 28 February 2020, Mr Gharib emailed Mr Wakefield:
"We have to meet to resolve this matter
First of all I came to start the job
Then I started on one with a faulty product you had supplied
Then ben came into the picture without my written consent so contract was breached
Then he gets paid witch breaches contracted again
Then rise wall comes to try fix the issue and pulls off my bracing without my consent again breach
Then they get payed for a faulty product and ruin my walls again it's a breach
43
Then I submit invoice and I get told I cant get payed because rise fucked the job ben has been payed rise got payed for a faulty product and you breached contract 4 times
So please explain who is at fault
Lets no play games I have had it with you ben and rise I'm sick of you guys running in circles"
In early March Mr Pope consulted solicitors seeking advice concerning 3Form's position under the Building and Construction Industry Security of Payment Act 1999 (NSW) and the appropriate way forward after 3Form had issued the further invoice following the template provided by Mr Pope. Mr Pope forwarded that advice to Mr Gharib on 6 March 2020
On 16 March 2020 Mr Wakefield emailed Mr Pope, copied to Mr Healy and Mr Gharib:
"Hi Ben, Tim, and Daniel,
After our meeting today to try and resolve the problems onsite I have organized a building consultant to go over the work in question and provide a report on the said works. I find it very disappointing when two meetings have been made and the first meeting gets cancelled because Rise Products owner Daniel has to go interstate and can't make it. The second one, another excuse he can't make it because he has a meeting. So no wonder nothing got resolved today."
On 1 May 2020 Actol's solicitors issued a letter of demand to Rise Products. The letter alleged breaches of implied warranties under the Home Building Act, breaches of consumer guarantees under the Australian Consumer Law, and misleading and deceptive conduct, and sought payment of the sum of $277,000. The letter also recorded that Actol intended to commence rectification works and asked that Rise Products inform the solicitors within 14 days if they wished to undertake an inspection of the Site.
Rise Products' solicitors responded on 22 May 2020. Their letter maintained that Rise Products had contracted only to supply and not to install the panels. The letter further noted that Actol had failed to collect the additional panels (that is the panels intended for the first-floor levels), which the letter asserted Rise Products had been storing for "approximately 8 months" (ie since September 2019), and demanded that Actol collect the balance of the panels within seven days, failing which Rise Products would sell or otherwise dispose of the product.
Proceedings in the Tribunal were commenced by Actol on 21 August 2020.
[4]
Actol's claims
As noted above, Actol seeks:
1. Compensation from Rise Products, or in the alternative Gledswood, for breach of statutory warranty under the Home Building Act;
2. In the alternative, compensation from Rise Products for breach of consumer guarantees under the Australian Consumer Law (NSW);
3. Additionally or in the alternative, compensation from Rise Products for misleading and deceptive conduct and from Mr Pszczonka for knowing involvement in the misleading and deceptive conduct;
4. Restitution of the cost of the RiseWall formwork which Actol paid for but which was never delivered.
It is convenient to address the claims in that order.
[5]
Rise Products' liability for breach of statutory warranty
The central issue in these proceedings is the nature of the contractual arrangements between Actol, Rise Products and 3Form. Actol maintains that Rise Products contracted to supply and install the RiseWall formwork on four lots for a total price of $214,390. Actol submits that Rise Products failed to comply with the statutory warranties implied into that contract pursuant to s 18B of the Home Building Act.
Rise Products disputes that it contracted to install the formwork, maintaining that Actol contracted with 3Form for the installation work.
There is a lack of clarity concerning what Actol says constituted the contract.
The particulars included in Actol's Further Amended Points of Claim state that the contract was partly written, partly oral and partly implied. Those particulars do not identify the oral parts of the contract. The part of the contract said to be implied was the implied terms allegedly arising pursuant to s 18B of the Home Building Act. The documents identified in the Points of Claim as constituting the written part of the contract were:
"a. Email dated 14 June 2019 and plans enclosed;
b. Emails dated 20, 21, 26 August 2019;
c. Quote for $214,390;
d. Email dated 3 September 2019"
I interpret particulars a, b and d as identifying the following documents:
1. The email of 14 June 2019 by which Actol forwarded plans for the dwellings (see [39] above)
2. The email of 20 August 2019 by which Ms Hatem forwarded quotes for the four lots (see [58] to [60] above)
3. The email from Ms Hatem to Mr Wakefield of 21 August 2019 (see [59] above)
4. The email from Mr Wakefield to Ms Hatem dated 26 August 2019 in which Mr Wakefield gave "the go ahead" (see [63] above)
5. The exchange of emails between Ms Hatem and Mr Wakefield on 3 September 2019 concerning invoices and payment (see [67] above).
It is not clear what document Actol is referring to in particular c. Uninstructed by Actol's submissions I would have understood it to be the 3Form Quote, which was for $194,900 plus GST, that is $214,390. However, it is reasonably clear from Actol's submissions that Actol does not submit that the 3Form Quote constituted part of the contract. In Actol's written submissions in chief (paragraph 81) Actol submitted that, at the time that Actol sent the email of 26 August 2019 "all that Actol had before it from Rise was the quotation document" being the email from Ms Hatem to Mr Wakefield of 23 August 2019 (see [62] above). I note that Rise Products does not suggest that particular c refers to the 3Form Quote.
Actol's written submissions in chief suggest:
"80. On the basis of the objective theory of contract, on 23 August 2019 at 12.08pm there had been a second offer made by Rise and there had been subsequent acceptance of that second offer by Actol on 26 August 2019 at 1.09pm."
It was only in Actol's submissions in reply (paragraph 14) that Actol identified the alleged oral parts of the contract as being the conversations at the site between Mr Wakefield and Mr Pszczonka (whether or not Mr Pope was present) on 26 June 2019 (see [40] to [41] above) and between Mr Wakefield, Mr Pszczonka, Mr Pope and Mr Gharib on 20 August 2019 (see [47] to [48] above).
The written parts of the contract identified by Actol in its submissions in reply (paragraph 14) appear to reflect the particulars in the Points of Claim, save that the submissions do not refer to any document not identified in particulars a, b and d which might qualify as "quote for $214,390".
Rise Products maintained that the contract was wholly in writing and comprised of Rise Products' four quotes dated 16 August 2019, which it submits were accepted by Actol, either by Mr Wakefield's email of 26 August 2019, or by Actol's subsequent conduct in paying for the product and taking delivery of the panels and associated items for the ground floor.
As I have noted above, Actol disputes that it received the four quotes before 26 August 2019. This issue was not the subject of detailed submissions. I note that Mr Wakefield included in the exhibit to his statement a copy of an email chain consisting of two emails from Ms Hatem with the subject line "Rise Products quote for lot 3-6 Kellyville". The first email was sent at 11:01 am on 20 August 2019. The second was sent at 11:03 am on 20 August 2019. As I have noted above (at [58]) the time-stamp on the second email suggests it was forwarded immediately upon receipt of the email from Mr Wakefield, sent in response to the first email, asking Ms Hatem to send the email again.
Mr Wakefield included in his exhibit, immediately following these emails, a copy of the four quotes dated 16 August 2019 which Actol maintains in its submissions were not received before 26 August 2019. In his statement Mr Wakefield does not explain the inclusion of these documents.
In cross-examination by Mr O'Sullivan, Mr Wakefield was taken to each of the four quotes and agreed that he received them all together on 20 August 2019. I regard the inclusion of the quotes in the exhibit immediately following the two emails of 20 August 2019 as further acknowledgment by Mr Wakefield that those documents were attached to the second email. I find that the four quotes dated 16 August 2019 were received by Actol on 20 August 2019.
The task for the Tribunal, in determining the terms and content of the contract between Actol and Rise Products is to determine the "objective intention" of the parties, as appears from their communications and conduct.
As McColl JA held in County Securities Pty Ltd v Challenger Group Holdings Pty Ltd [2008] NSWCA 193, at [149] - [150]:
"149 The meaning of the terms of a contractual document is to be determined by what a reasonable person would have understood them to mean: Toll (FGCT) Pty Limited v Alphapharm Pty Limited [[2004] HCA 52; (2004) 219 CLR 165].
150 Whether a contract has been formed, and the terms of contractual arrangements, requires objective determination: Equuscorp Pty Limited v Glengallan Investments Pty Limited [[2004] HCA 55; (2004) 218 CLR 471](at [34]) per Gleeson CJ, McHugh, Kirby, Hayne and Callinan JJ; Ermogenous v Greek Orthodox Community of SA Inc [2002] HCA 8; (2002) 209 CLR 95 (at [25]) per Gaudron, McHugh, Hayne and Callinan JJ; Pacific Carriers Limited v BNP Paribas [2004] HCA 35; (2004) 218 CLR 451; Toll (at [40]). Objective determination requires consideration, not only of the text of the documents, but also the surrounding circumstances known to participants, and the purpose and object of the transaction, but not the participants' subjective beliefs: Pacific Carriers Limited [v BNP Paribas [2004] HCA 35; (2004) 218 CLR 451] (at [22]) per Gleeson CJ, Gummow, Hayne, Callinan and Heydon JJ; Toll (at [40]); International Air Transport Association v Ansett Australia Holdings Ltd [2008] HCA 3; (2008) 82 ALJR 419 (at [8]) per Gleeson CJ."
See also the judgment of Spigelman CJ at [8] - [12].
It is clear that there was a contract between Actol and Rise Products, both parties acknowledge as much. Neither party suggests that 3Form contracted with Actol to supply the RiseWall product, as the 3Form Quote appears to propose.
It is also clear that the contract was not wholly in writing. The email from Mr Wakefield of 26 August 2019 did not explicitly refer to the quotations which Rise Products submits it was accepting. The email could only be connected to the quotations by consideration of the surrounding circumstances.
It is therefore necessary to consider the whole of the surrounding circumstances, including, to the extent that it indicates the parties' understanding of what they had agreed and therefore throws light on that agreement, the parties' subsequent conduct: Woodward v Warwick Green Building Pty Ltd [2021] NSWCATAP 210 at [53] and cases there cited.
In support of its submission that Rise Products contracted to supply and install the RiseWall product, Actol relies upon Mr Wakefield's evidence of the conversation on Site on 26 June 2019, that he had said "You need to supply and install" and that Mr Pszczonka had agreed. Actol also relies upon the email of 1 July 2019 by which Rise Products provided a quotation for "S & I" (which was clearly an abbreviation of "supply and install") in relation to the RiseWall product.
I do not consider that either of those matters could be ultimately determinative of the nature of the contract. There was further correspondence between Actol and Rise Products after 1 July 2019. The quotation provided on that date was clearly superseded by what went after.
I am not persuaded that Mr Wakefield did make the statement which he claims to have made at the meeting on 26 June 2019. Mr Pszczonka did not agree that it was said. In my view Mr Wakefield's evidence was influenced by his view that Rise Products was responsible for the problems Actol had experienced with the RiseWall product. Mr Wakefield gave evidence that Mr Pope was at the meeting on 26 June 2019. Mr Pope's evidence, which was not challenged, was that he had not joined Rise Products until 19 August 2019.
It is apparent from the quotation of 1 July 2019 that Rise Products did at that time contemplate entering into a contract to supply and install the RiseWall formwork on the Site. However, the subsequent correspondence indicates in my view that that option was not pursued but rather Rise Products introduced 3Form as a company prepared to undertake the installation.
I accept Actol's submission that Rise Products was involved in the preparation of the 3Form Quote, which Mr Gharib handed to Mr Wakefield on 20 August 2019. Mr Gharib's evidence was that he had not previously communicated with Mr Wakefield and that Mr Pope had provided the information necessary to prepare the quote. Mr Gharib could only have prepared the 3Form Quote on the basis of information provided by Rise Products. I note that the quantities of RiseWall panels and accessories listed in the 3Form Quote reflected the quantities set out in the four quotations from Rise Products forwarded by Ms Hatem to Mr Wakefield that day. I infer from the subsequent correspondence between Ms Hatem and Mr Wakefield concerning the breakdown of the price quoted by 3Form, that the 3Form Quote had been prepared on the basis that the price for the supply of the RiseWall product would be the amount included in the four quotations.
Although the 3Form Quote stated a single price for the supply and installation of the formwork, it is clear that, even on 20 August 2019, the day of the meeting when the quote was handed to Mr Wakefield, the parties did not intend that 3Form would purchase the RiseWall product from Rise Products and supply it to Actol.
In my view the emails sent by Ms Hatem to Mr Wakefield on 21 and 23 August 2019 clearly demonstrate that the parties were looking at supply and installation as two separate matters involving separate arrangements between Actol and Rise Products and between Actol and 3Form.
Nothing in the email from Mr Wakefield to Ms Hatem of 26 August 2019 contradicted that proposition. Mr Wakefield specifically stated, "we would like to give you the go ahead to supply" the RiseWall product and that, "3Form to fix the Rise wall product and supply concrete and steel". Mr Wakefield then specifically enquired about a "standard contract or 3Form to sign" and suggested Actol might organise it. The Tribunal enquired of Mr Wakefield during his evidence whether the email should read "contract for 3Form to sign". Mr Wakefield's response was:
"To be quite honest, I couldn't honestly say."
Regardless of whether the word should have been "or" or "for", viewed objectively, that email can only be construed as proposing two separate agreements.
That interpretation is confirmed by the response from Ms Hatem the same day, "Thank you for choosing Rise Products to be your supplier and 3Form to be your installer" and, "Andrew from 3Form will contact you today/tomorrow to discuss the schedule amongst yourselves That will then be the contract I guess between you and 3Form". Actol did not point to any evidence that Mr Wakefield had communicated with Ms Hatem to contradict the clear statement in that email that there would be a contract between Actol and 3Form.
I find that, by the exchange of emails between Mr Wakefield and Ms Hatem on 26 August 2019, Actol and Rise Products entered into a contract for the supply by Rise Products to Actol of the RiseWall panels and associated items referred to in the four quotes sent to Actol on 20 August 2019 at a price of $101,301.20 inclusive of GST. That contract was not a "contract to do residential building work" and accordingly did not include the implied warranties set out in s 18B of the Home Building Act.
The corollary of the conclusion that the contract between Actol and Rise Products was for the supply of RiseWall product only is that Actol contracted directly with 3Form for the installation and filling with concrete of the RiseWall formwork.
The mechanism by which 3Form became bound to a contract with Actol is not clear and was not fully explored either in evidence or submissions. Mr Gharib gave evidence that Mr Wakefield had said at the 20 August meeting that he was happy with the 3Form Quote, but it was not submitted by any party that that communication resulted in the formation of a contract. Nevertheless, 3Form attended the site and commenced work. That conduct was itself confirmation of the existence of a contract binding 3Form to carry out the installation work. Once it has been determined that Rise Products had not contracted to carry out the work, the contract by which 3Form was bound to carry out the work must have been with Actol.
Actol relied on the fact that, apart from the delivery of the 3Form Quote and the meeting on 20 August 2019, there was no communication between Mr Wakefield and Mr Gharib prior to 3Form commencing work, as supporting its case that there was no contract between Actol and 3Form, and that Rise Products had contracted to install the RiseWall product, employing 3Form as its subcontractor.
In my view that circumstance can be explained on the basis that Rise Products acted as disclosed agent for 3Form during the negotiations in August 2019. In circumstances where the email correspondence between Actol and Rise Products objectively discloses an intention that Actol would enter into separate contracts with Rise Products and 3Form, that is the conclusion which inevitably arises.
I do not consider that the subsequent conduct of any of the parties points to any different conclusion.
It is clear that Rise Products was concerned that the project should succeed. The RiseWall product supplied by Rise Products to Actol was a new product and Rise Products was looking to promote that new product. Rise Products' concern to promote the new product explains the conduct of Rise Products in introducing Gledswood and in subsequently employing other subcontractors (ie Jarrod B Carpentry and DJK Carpentry and Construction) to assist in the completion of the formwork. To the extent that Mr Wakefield and Mr Woods gave evidence of observing Mr Pope giving instructions to workers employed by 3Form, that is consistent with Rise Products providing technical advice in relation to the installation of its new product. I do not consider it provides any support to Actol's case that Rise Products contracted to install the product.
The conduct of both Gledswood and Actol was only consistent with Gledswood either contracting directly with Actol or subcontracting to 3Form. Mr Wakefield suggested that he had paid Gledswood directly because Rise Products had told him to, but he did not identify any particular communication by which that instruction was given. In particular, Mr Healy submitted an invoice to Actol directly.
The only evidence of any discussion between Mr Wakefield, or anyone else on behalf of Actol, and Mr Pope or Mr Pszczonka , or anyone else on behalf of Rise Products, concerning the amount to be paid to Gledswood was the assertion by Mr Wakefield, with which Mr Pope "generally agreed", that on 22 October 2019 he and Mr Woods had had a meeting with Mr Pope, Mr Gharib and Mr Healy at which "the topic discussed … was the prices that 3Form and Gledswood were charging for the installation". Mr Wakefield stated that he was only there as an observer and played no part in the discussions.
That meeting took place nearly three weeks after Actol had paid Gledswood's invoice for $11,000.
In cross-examination, Mr Wakefield agreed that the discussion at the meeting on 22 October 2019 took place in the context of discussions about Gledswood "taking over the job, the whole lot".
3Form objected to the fact that Actol had made payment to Gledswood, apparently because it was assumed that that payment would come out of 3Form's contract price. However, 3Form does not appear to have objected at the time to Gledswood coming onto the Site and undertaking work.
As I have noted above, from about 15 November 2019 onwards, 3Form had apparently abandoned the job and Gledswood had declined to continue. From that time Rise Products became more actively involved, including directly contracting with Jarrod B and DJK to undertake work preparing the formwork and to assist with the concrete pour. The evidence also suggests, and I so find on the balance of probabilities, that Rise Products was responsible for booking the concrete supply and the concrete pump even though the invoices were addressed to Actol.
I accept that Rise Products did undertake supervision of the project after 15 November 2019, if not before, and I also accept that that supervision constituted residential building work within the definition of that term in clause 2 of schedule 1 to the Home Building Act. However, s 18B of the Home Building Act implies warranties into "every contract to do residential building work".
Unless Actol and Rise Products entered into a contract by which Rise Products agreed to undertake the coordination or supervision of the installation of the RiseWall panels, there was no contract between Actol and Rise Products into which the s 18B warranties could be implied.
I note that Rise Products did offer to take over the job by its letter of 15 November 2019. That offer was not accepted. Rather, Mr Wakefield rejected the offer and notified Rise Products that Actol would not be using RiseWall for the upper floors (despite having paid for panels for that purpose).
The nature of the arrangement thereafter was set out in Mr Pope's letter to Mr Wakefield of 19 November 2019 (see [105] above), that is, Rise Products "will endeavour to assist 3Form to complete the GFL (units 3 - 6) in accordance with their quote/agreement", and Mr Pope's email to Mr Gharib of 20 November 2019 (see [106] above) in which Mr Pope informed Mr Gharib that Rise Products had been unable to reach agreement with Actol to step in and take over the contract, that Actol was insisting that 3Form complete the ground floor, and that Rise Products was prepared to assist 3Form by supplying adjustable propping and metal angles and providing labour to complete the work and additional supervision to assist with the concrete pour.
Although Actol's points of claim refer to "the Supervision Contract", Actol did not plead that Actol and Rise Products entered into a contract in November 2019 by which Rise Products, for consideration, agreed to undertake supervision of the project. The relevant paragraph of Actol's Further Amended Points of Claim alleges no more than that "Rise Product acted as either the co-ordinator or supervisor of the installation of the Rise Wall at the Site." Actol's written submissions focussed on establishing that Rise Products was involved in the co-ordinating or supervising of the placement and filling of the RiseWall panels. There is no submission directed to the proposition that Rise Products was doing so pursuant to any contract.
Rise Products' conduct is entirely consistent with it being solely concerned, whether for reputational reasons or otherwise, to assist 3Form/Actol, gratuitously, to ensure the project was completed.
I am accordingly not persuaded that Rise Products entered into any contract with Actol for the provision of residential building work and it follows that I do not find that Rise Products breached any contractual obligation (including breach of statutory warranty) in relation to the installation of the RiseWall panels, or the supervision of the installation. Actol did not plead (or rely upon) any other basis upon which Rise Products might have been held liable for the defective installation of the RiseWall panels.
[6]
Gledswood's liability for breach of statutory warranty
I am satisfied that, through Gledswood undertaking work in the expectation of payment by Actol, Gledswood did enter into a contract with Actol to undertake work installing RiseWall panels on the site. The precise mechanism by which that occurred was not fully explored in the evidence. Nevertheless, it is apparent that Actol (in the person of Mr Wakefield and Mr Wood) knew that Gledswood was on-site and undertaking work. Actol dealt directly with Mr Healy, to the extent that Mr Wakefield and Mr Wood appeared satisfied with the work carried out by Gledswood, in contrast to that carried out by 3Form, and paid Gledswood's invoice immediately upon submission.
Mr Wakefield's evidence was that Mr Healy had asked on 2 October 2019 whether he could be paid for the work that he had done, and Mr Wakefield had said "okay, I am happy to pay your progress claim". Mr Wakefield did not suggest that he had obtained approval of the amount of the payment from either Rise Products or 3Form. Mr Healy did not suggest that he had sought approval to the submission of his invoice from either Rise Products or 3Form.
Actol paying Gledswood directly is not necessarily inconsistent with Gledswood being a sub-contractor of Rise Products or 3Form. Nevertheless, in my view, Actol paying Gledswood without clearing the amount of the payment with Rise Products or 3Form is inconsistent with Gledswood being a sub-contractor to one of those companies.
The initial text message from Mr Pope to Rabih on 13 September 2019 (see [72] above) suggests that "you can talk to Ben [Healy] about helping doing one of the houses". However, there is no evidence of any communication or conduct by which 3Form agreed to, or even acquiesced in, Gledswood undertaking some of the installation work on its behalf.
The consequence of the foregoing conclusion is that Gledswood did owe an obligation to Actol to comply with the statutory warranties in s 18B of the Home Building Act.
However, as Mr Healy submits, the evidence tendered by Actol does not permit me to draw the conclusion that there has been any breach of warranty by Gledswood. The evidence discloses that Gledswood undertook the erection of RiseWall formwork on two (or all of one and most of a second) houses. The evidence of Dr Cunniffe was that:
"The following defects were identified in all Lots 3 - 6:
(a) some walls were not plum or square;
(b) some had obvious signs of honeycombing,
(c) sections of the fibre cement panel formwork were broken.
(d) most fibre cement panel joints had hexagonal screw heads protruding from the panels.
(e) a section of reinforcing steel was protruding from the concrete.
(f) areas of the formwork were not filled with concrete."
Dr Cunniffe described honeycombing as "an industry term describing concrete that has not been compacted and having gaps causing it to be structurally inadequate."
Putting Actol's case at its highest, only (a), (c) and (d) could be attributed to the manner of erection of the formwork.
Of the particulars of damage set out in the Further Amended Points of Claim (see [7] above), only I, III, IV, V and X, that is:
I Rise Walls were out of square;
…
III Protruding screws;
IV fibre cement panel joints screw heads protruding from panels;
V Poor join work; [and]
…
X sections of fibre cement panel formwork broken;
…
could be attributed to the manner of erection of the formwork.
Dr Cunniffe's opinion, as expressed in his report, was:
"9.1 I am of the opinion that RISE PRODUCTS suppliers of RISEWALL, a proprietary walling system is not a licenced contractor, and therefore is not licenced to install its permanent formwork in New South Wales.
9.2 I am of the opinion that in order to facilitate the sale to ACTOL, RISE PRODUCTS engaged 3FORM STRUCTURES PTY LTD (an inexperienced contractor for the installation of RISEWALL), and GLEDWOOD PROJECTS PTY LTD (Ben Healy, the director of Gledswood Projects and former employee of RISE PRODUCTS) to install the walling system on site.
9.3 I am of the opinion that the defects in the walling system onsite were caused due to a lack of experience on the part of 3Form STRUCTURES PTY LTD, and, RISE PRODUCTS, as Tim Pope the CEO was onsite supervising the installation of the walling systems.
9.4 I am of the opinion the finish of the surfaces with hexagonal screws, blown out walls, cracked panels, walls out of square and out of plumb are all defective and unacceptable practices in the building of residential housing. Whilst the product brochure does state that the joints can be plastered over, I am of the opinion that considerable remedial works would need to be carried before this could be done.
9.5 I am of the opinion that defects listed requires rectification to the sum of $177,882.41."
Dr Cunniffe also stated in his report:
"8.15 The walls being out of plumb is not a manufacturing defect. It is an installation issue. The formwork and bracing should have been set up for the walls to be plumb when completed.
…
8.19 The wall blow outs are an indication of inadequate bracing. This is not a manufacturing issue. It is an installation issue. The strength of the fibre cement panels would have been calculated by the engineer for the site. The use and positioning of the bracing is a key factor in whether the panels would hold up during the core-filling process.
…
8.21 The use of hexagonal screws to hold the panels in place may indicate that the bracing method was inadequate. Given the number of screws employed, the scale of the problem is significant. With the core-filled concrete cured the formwork is then redundant and therefore the screws are no longer needed. …"
As Rise Products submitted, this opinion strays well beyond Dr Cunniffe's expertise or the proper role of expert evidence. Nevertheless, I accept that paragraphs 8.15, 8.19, 8.21 and 9.4 of Dr Cunniffe's report do contain opinion evidence which Dr Cunniffe is qualified to give.
Dr Cunniffe's report includes photographs of the filled RiseWalls on lots 4 and 5, which were the lots for which Gledswood undertook the erection of RiseWall panelling. However, there is no description in the report of what each photograph is supposed to show. It is apparent that the photographs were provided to Dr Cunniffe by Actol's solicitors.
The primary reason why I conclude that Gledswood is not liable to Actol for breach of implied warranty is that it is clear that Gledswood had not been involved in the work on site after 11 November 2019. It is not in dispute that other carpenters (Jarrod B and DJK) carried out work on the site after that date up to and including the concrete pours on 18 December 2019 and 14 January 2020.
Mr Healy maintained that those who came after him had "removed and rearranged props on our site and hindered/touched/installed on our work prior to concrete pour." Gledswood's written submissions referred to evidence from Mr Wakefield, in response to questions from Mr Healy, that the carpenters retained by Rise Products had:
"reinstalled bracing. They pulled some bracing off and put it back on. Mostly bracing and they did some corner angles. I noticed on lot four where the corner angles weren't done. And lintels…"
I am not persuaded that the evidence before the Tribunal is sufficient to establish on the balance of probabilities that any of the defects identified in the filled RiseWalls on lots 4 and 5 were a consequence of any failure by Gledswood to comply with its obligation to carry out the residential building work with due care and skill.
I also note Mr Pope's evidence:
"13 ... I noted some defects and omissions in the works, such as walls being out of plumb or screws left in place that should have been removed. Usually, such things would be remedied at the end of the job. The defects and omissions I observe were all what, in my experience, I considered to be normal imperfections that would be rectified towards the end of the job. No concrete pour is ever perfect and almost always, some rectification work is required at the end of job to fix minor and common imperfections. For example, any surfaces that are rough or out of plumb can be "skinned" with concrete or render to make them smooth and plumb. Peter Wood had told me that the walls would all be rendered so I assumed that any such defects would be rectified by the application of render. I am unable to comment on "lack of bracing" and "steel placed incorrectly" without further details of the supposed defect."
Mr Pszczonka also gave evidence in cross examination that timber patching screwed over a wall would have been placed to "patch over … a join or a crack or whatever to provide additional support" and would be removed after installation.
I also note that Dr Cunniffe's evidence (and costings) do not distinguish between items such as protruding screw heads and plywood patches over joins or cracks which, according to Mr Pope's and Mr Pszczonka's evidence, would be removed at the end of the job (in other words, incomplete work) and defects such as blowouts and walls out of plumb, honeycombing et cetera, which were not mere matters of finishing.
Gledswood did not purport to complete the job of erecting and filling the formwork and cannot be said to have breached any contractual obligation to Actol by failing to remove screw heads and patches which would in the ordinary course have been removed after the concrete had been poured.
Accordingly, the claim against Gledswood by Actol (and, to the extent it arises, the claim by Rise Products against Gledswood) must be dismissed.
[7]
Rise Products' liability for breach of Consumer Guarantees
The Australian Consumer Law (NSW) (ACL) provides a number of guarantees in respect of any supply in trade and commerce of goods or services to a consumer.
It is clear in this case that Rise Products was supplying goods (being the RiseWall product) and that the supply occurred in trade and commerce.
In those circumstances the guarantees regarding the provision of services are not relevant: Wilson v Winnicott [2021] NSWCATAP 211.
In any event, as I have held, Rise Products did not agree to supply services to Actol.
Although Actol pleaded reliance on each of ss 54 to 58 of the ACL, Actol did not present any submissions in support of the proposition that the panels had been supplied by description or sample or demonstration model (ss 56 and 57) or that the panels supplied failed to meet any such description or sample or that there had been any failure to ensure facilities for the repair of the panels or parts (s 58).
The consumer guarantees in respect of which Actol made submissions were the guarantee in s 54 of the ACL that the goods will be of acceptable quality and the guarantee in s 55 of the ACL that the goods would be reasonably fit for any purpose made known to Rise Products by Actol and any purpose for which Rise Products had represented the goods would be reasonably fit.
[8]
Supply to a consumer
The consumer guarantees are only applicable to the supply of the RiseWall panels if the panels (and associated items) were supplied to Actol as a consumer.
Section 3 of the ACL relevantly provides:
3 Meaning of consumer
Acquiring goods as a consumer
(1) A person is taken to have acquired particular goods as a consumer if, and only if:
(a) the amount paid or payable for the goods, as worked out under subss (4) to (9), did not exceed:
(i) $40,000; or
(ii) if a greater amount is prescribed for the purposes of this paragraph - that greater amount; or
(b) the goods were of a kind ordinarily acquired for personal, domestic or household use or consumption; or
(c) the goods consisted of a vehicle or trailer acquired for use principally in the transport of goods on public roads.
(2) However, subs (1) does not apply if the person acquired the goods, or held himself or herself out as acquiring the goods:
(a) for the purpose of re-supply; or
(b) for the purpose of using them up or transforming them, in trade or commerce:
(i) in the course of a process of production or manufacture; or
(ii) in the course of repairing or treating other goods or fixtures on land.
…
Amounts paid or payable for purchases
(4) For the purposes of subs (1) or (3), the amount paid or payable for goods or services purchased by a person is taken to be the price paid or payable by the person for the goods or services, unless subs (5) applies.
…
Presumption that persons are consumers
(10) If it is alleged in any proceeding under this Schedule, or in any other proceeding in respect of a matter arising under this Schedule, that a person was a consumer in relation to particular goods or services, it is presumed, unless the contrary is established, that the person was a consumer in relation to those goods or services.
…
Supplies to consumers
(12) In this Schedule, a reference to a supply of goods or services to a consumer is a reference to a supply of goods or services to a person who is taken to have acquired them as a consumer.
It is clear that the amount paid by Actol exceeds $40,000. I do not accept Actol's submission that the relevant amount was the price of the products supplied in respect of each lot. As Rise Products submitted, there was one agreement for the supply of RiseWall product for a total price in excess of $100,000. Contrary to Actol's submissions, it was not open to Actol to commence four separate applications in respect of the four houses.
It follows that the RiseWall panels could only have been supplied to Actol as a consumer if they were "goods of a kind ordinarily acquired for personal, domestic or household use or consumption".
Actol submitted that the RiseWall panels were goods of a kind ordinarily acquired for personal, domestic or household use or consumption. Actol referred to the judgment of Young J in Bunnings Group Limited v Laminex Group Limited [2006] FCA 682; 153 FCR 479 in support of that submission.
The question in that case, which was determined under the equivalent provisions in the Trade Practices Act 1974 (Cth), was whether reflective foil insulation products and reflective foil laminate with a glass wool blanket adhered to it, which were used in the construction of warehouses, were goods of a kind ordinarily acquired for personal, domestic or household use or consumption.
Young J referred to authorities concerning the meaning of the term "goods … of a kind ordinarily used for household purposes" in sales tax legislation and stated, at [80] - [87]:
"80 In my opinion, several propositions of relevance to this case can be extracted from the authorities.
81 First, the word 'ordinarily' means 'commonly' or 'regularly', not 'principally', 'exclusively' or 'predominately': see Clean Investments at [Clean Investments Pty Ltd v Commissioner of Taxation (2001) 105 FCR 248] 273 [97] per Lindgren J; Chubb [Commissioner of Taxation v Chubb Australia Ltd (1995) 56 FCR 557] at 560 per Burchett J, and at 57 per Hill J; Hygienic Lily [Hygienic Lily Ltd v Deputy Commissioner of Taxation (1987) 13 FCR 396] at 399-400 per Gummow J. Counsel for the respondent invited me to depart from these authorities, and to hold that the word 'ordinarily' as used in s 74A(2)(a) means 'predominately'. In view of the authorities to which I was referred, I doubt that I am free to adopt such a construction. In any event, I am not persuaded that the word 'ordinarily' in s 74A(2)(a) [of the Trade Practices Act] means 'predominately' rather than 'commonly' or 'regularly'. On the contrary, I consider that the meaning which best accords with the policy and the purposes of the TPA is that of 'commonly' or 'regularly'. I am conscious that the Full Court of the Victorian Supreme Court in ICI Australia Operations Pty Ltd v Deputy Commissioner of Taxation (Vic) (1987) 82 ATC 5110 said at 5112 that the concept of 'ordinarily used for' equals 'whose primary but not necessarily exclusive purpose and customary use is'. However, I do not agree that the word 'ordinarily' should be given such a connotation in s 74A(2)(a) or elsewhere in the TPA.
82 Secondly, it is preferable to pose the statutory question (ie the question whether the goods in issue in the particular case are goods of a kind ordinarily acquired for personal, domestic or household use or consumption) as a single composite question: see Clean Investments at 273 [91]-[93] per Lindgren J; Diethelm at 472 per Hill J; and Chubb at 559[F] per Burchett J. …
83 Thirdly, depending on the precise statutory question and the circumstances of the particular case, it will be relevant to inquire as to the essential character of the goods in question. …
…
86 In my opinion, in the context of s 74A(2)(a) of the TPA, the essential character test is relevant, but the inquiry does not end there. The statutory question cannot be answered without a broader inquiry into the evidence concerning the design, marketing, pricing and potential uses of the type of goods in question.
87 Fourthly, the question posed by s 74A(2)(a) is ultimately a question of fact and degree. In Chubb at 559, Burchett J described the question which arose under Item 1 of the Third Schedule of the Sales Tax (Exemptions and Classifications) Act 1935 (Cth) in the following way:
'That is a question of fact into which degree and impression must enter largely, but I do not think its resolution is assisted much by turning back to the essential character of the article. Rather, attention must be focused on the statutory question whether goods of that kind are ordinarily used for household purposes.'
In the same case, Hill J said at 572 that the trial judge's finding that certain safes were of a kind ordinarily used for household purposes involved:
'… a question of judgment based upon a consideration of the description and in some cases photos or drawings of the relevant safe. No error is apparent in her Honour's judgment, although it is possible that minds could differ as to the outcome in a particular case.'
These assessments are borne out by the actual decisions in Diethelm and Chubb. Both cases ultimately turned on the sufficiency of the evidence to discharge the burden of proof which rested on the applicant for sales tax exemption."
At [107] to [108], his Honour held:
"107 There is an obvious difference between these sales tax cases and s 74A(2)(a) of the TPA. Section 74A(2)(a) refers to 'goods of a kind ordinarily acquired for personal, domestic or household use or consumption' (my emphasis). Even more clearly than the words 'ordinarily used for', this language invites attention to design features and purposes, cost quality and pricing considerations, and the range of uses and applications for the goods which have been targeted in advertising and promotional material. I see no reason why the permissible range of evidence should not extend to what French J called 'the commercial realities of [the] manufacture and sale' of the relevant goods and, as Tamberlin J suggested, similar goods made by other manufacturers. Nor do I see any reason why the use of this evidence is to be confined to the 'genus' question (assuming it is to be addressed separately), rather than being used to assist more broadly in determining the composite statutory question.
108 I therefore accept that a broad range of evidence may be relevant and potentially useful in answering the statutory question. At the same time, I recognise the importance of bearing constantly in mind that the statutory question is whether the goods are of a kind ordinarily acquired for personal, domestic or household use or consumption. Care must be taken to ensure that the detail of the evidence does not blur this question, or distract the Court from the appropriate inquiry. It would, for example, be a mistake to become so focused on the properties, attributes and intended and advertised uses of the particular goods that the Court fails to address the statutory question. This risk would materialise if the kind of goods were to be identified so narrowly that it amounted to little more than a description of the particular goods."
His Honour concluded, at [112] to [114]:
"112 It is correct, as the respondent argues, that white-faced foil laminates have special attributes and applications. They are, and were at all relevant times, significantly more expensive than uncoated reflective foil laminates, and are in fact used almost exclusively in commercial and industrial applications. However, as the applicant's experts said, there is nothing other than price that would make them unsuitable for use in residential applications. The respondent contends that the special attributes, special applications and greater cost of white-faced and other decorative foil laminates render them so distinctive that they must be regarded as goods of a different kind from reflective foil laminates. I do not accept this contention.
113 Having regard to the whole of the evidence, I am satisfied that the products are goods of a kind ordinarily acquired for personal, domestic or household use or consumption within the meaning of s 74A(2)(a). In reaching this conclusion, I have taken into account the differences in marketing, price, attributes and ordinary use of the products by end users upon which the respondent relies. I have also taken into account the common features and applications of reflective foil laminates and white-faced foil laminates. In my opinion, the proper characterisation of the products must give due weight to the three essential properties of the products. They are and were acquired and used in building constructions because they possess those essential properties. To classify the products narrowly on the basis of the particular feature that the foil face is coated with polypropylene would give undue weight to this single facet or characteristic of the particular products, and would misapply the statutory phrase.
114 In my opinion, the special features relied upon by the respondent do not mean that white-faced and other decorative foil laminates are goods of a kind different from reflective foil laminates. Rather, it indicates that white-faced and other decorative foil laminates are a product variant, amongst many different product variants, of standard reflective foil laminates. Nor can it be said that white-faced or decorative foil laminates are the only reflective foil laminates that function as a form of internal roof or wall lining. Both uncoated reflective foil laminates and white-faced foil laminates are and were commonly left exposed to view in commercial and industrial buildings as the only form of roof or wall lining. The relevant difference between the two variations is that if there are special needs for washability, corrosion resistance, light reflectivity, or simply a desire to present a more finished appearance, white-faced foil laminates can provide those extra features at an additional cost."
I note that in this case neither party led evidence specifically directed to the question whether the RiseWall panels were "goods of a kind ordinarily acquired for personal, domestic or household use or consumption".
Nevertheless, Actol did play to the Tribunal a video and tendered other promotional material which establishes to my satisfaction that the RiseWall product is goods of a kind ordinarily acquired for personal, domestic or household use or consumption.
The evidence, as far as it goes, suggests that the product is intended for the construction of residential housing as much as for commercial buildings. Although it is not a product likely to be used by the ordinary homeowner, it is ordinarily used by licensed builders in the construction of residential buildings for ordinary homeowners. It is implicit in the distinction sought to be drawn in Bunnings Group between reflective foil laminates and the "white faced foil laminates" under consideration in that case that a product ordinarily used in the construction of residential housing is "goods of a kind ordinarily used for personal, domestic or household use or consumption".
I further note the provisions of s 3(10) of the ACL. The onus of establishing that the product is not such a good lay upon Rise Products. I do not consider that Rise Products has led evidence to enable me to conclude that the RiseWall product is not goods of the kind ordinarily acquired for personal, domestic or household use or consumption.
Rise Products nevertheless submitted that Actol acquired the goods for the purpose of using them up or transforming them, in trade or commerce, in the course of a process of production or manner of manufacture or in the course of repairing or treating other goods, or fixtures on land (so that, by virtue of the exception in sub-s 3(2) of the ACL, Actol did not acquire the goods as a consumer).
Rise Products relied upon the undisputed fact that Actol was constructing the houses on the Site in order to sell them. Rise Products submitted that Actol acquired the RiseWall product in order to use it for the construction of the concrete walls for the houses, which was a process of production or manufacture.
Actol did not directly address this submission, which was clearly pleaded by Rise Products in its Points of Defence.
My researches have been able to locate only three authorities dealing with sub-s 3(2) of the ACL or the equivalent provision in the Trade Practices Act.
In Laws v GWS Machinery Pty Ltd [2007] NSWSC 316, Rothman J rejected the submission that the purchaser of a tyre for a tractor used in the purchaser's business acquired the tyre for the purpose of using it up in the course of a process of production or manufacture.
Theo Holdings Pty Ltd v Hockey; Australian Competition And Consumer Commission v Theo Holdings Pty Ltd [2000] FCA 665; (2000) 99 FCR 232 involved consideration of the provisions of ss 65F to 65P of the Trade Practices Act which permitted the relevant Minister to direct the recall of "goods that are intended to be used, or are of a kind likely to be used, by a consumer ...". The applicants were suppliers of fire doors.
Dowsett J held that "consumer" in s 65F was intended to have the same meaning as elsewhere in the Act, that is the meaning defined by the equivalent provision to s 3 of the ACL.
At [27], his Honour stated:
"It seems probable that the applicants expected their doors to be purchased by builders for installation in buildings being constructed by them on land belonging to others. A supply to such a builder would be for resupply (by the builder), and so that builder would not acquire the doors as a consumer. It follows that the applicants' doors were not intended for use by a consumer. Whether such a builder would also acquire the doors "for the purpose of using them up or transforming them ... in the course of production or manufacture or of repairing or treating other goods or fixtures on land; ...", it is not necessary to decide. The terms "production or manufacture" and "repairing or treating" may not be appropriate to describe construction of a building. I should add that counsel for ACCC submitted that persons using buildings in which the doors had been installed might be consumers of those doors. Such a usage of language would be unusual. Further, it is clear that para 65F(1)(a) focuses on the goods at the time of their supply by the relevant corporation. If one were asked at that time to describe the possible use of such a product, one would certainly say that it was for installation in a building." [Emphasis added.]
That paragraph was cited by Murphy J in 20*20 Pty Ltd v D&G Developments Pty Ltd [2009] WASC 343, at [45], as authority for the proposition that:
"Windows and doors are goods of a kind ordinarily acquired for household use, but where they are acquired by a builder for building work, they are acquired for the purpose of resupply."
In my view, the RiseWall product was acquired by Actol for the purposes of being used up in trade or commerce in the course of a process of production, being the construction of for dwelling houses for sale at a profit. Notwithstanding the reservation expressed by Dowsett J, I consider that the construction of houses for sale at a profit is appropriately described as a "process of production".
Accordingly, Actol did not acquire the RiseWall product as a consumer and its claim for breach of the consumer guarantees under the ACL must fail.
Against the possibility that my conclusion in that regard is not correct, I shall consider whether Actol's claim would have succeeded if Actol had acquired the RiseWall product as a consumer.
Rise Products maintained that Actol had not established that the RiseWall product was not of acceptable quality or not fit for purpose. Rise Products submitted that Actol's expert had not suggested that the RiseWall product was not of acceptable quality or fit for purpose but had rather pointed to issues with the installation of the RiseWall product as being the cause of the deficiencies in the concrete walls.
Actol submitted that there was ample evidence that the product was not of acceptable quality and not fit for purpose. Actol pointed to the document prepared by Mr Hutchin, who was employed by an associated company to Rise Products. Actol also relied upon Mr Gharib's evidence (see [82] above) and Mr Healy's evidence (see [81] above). Actol referred in particular to the inconsistent or insufficient joining tongue, to which Mr Hutchin and Mr Healy both referred, and which Mr Pszczonka acknowledged had been improved in subsequent batches of the product.
Actol submitted that, in circumstances where Rise Products had not adduced any expert evidence to refute that evidence, the Tribunal should more readily conclude that the RiseWall product supplied to Actol was not of acceptable quality and not fit for purpose.
The evidence of the witnesses, both for Actol and for Rise Products, and of the promotional material published by Rise Products discloses that the RiseWall product was promoted and sold as an easily installed formwork system and that that was a purpose which Rise Products represented that the RiseWall product was reasonably fit for.
I conclude that, in two respects, the product supplied to Actol was not of acceptable quality and not reasonably fit for the purpose of being an easily installed formwork system.
The first respect was the inconsistent tongue width to which Mr Hutchin referred, which I conclude led to the difficulties in joining sheets to which Mr Gharib referred.
The second respect was that the corner panels supplied by Rise Products did not match the profile of the wall panels, as acknowledged by Mr Pope in his text message to Mr Healy (see [78] above).
The consequence of a finding that the RiseWall product failed to comply with the consumer guarantees of acceptable quality and fitness for purpose would be that Actol would be entitled to seek the remedies set out in ss 259 to 263 of the ACL. Because the panels had been incorporated into the homes, Actol could not reject the goods, but it would have been entitled, pursuant to s 259(4) of the ACL, to "recover damages for any loss or damage [it] suffered … because of the failure to comply with the guarantee if it was reasonably foreseeable that [Actol] would suffer such loss or damage as a result of such a failure."
In my view, it was reasonably foreseeable that Actol would suffer damage, through delays in construction, if the RiseWall product was not fit for the purpose of being an easily installed formwork system and not of acceptable quality.
I am not persuaded that the defects in the finished walls identified by Dr Cunniffe were a foreseeable consequence of the failure of the RiseWall product to comply with the consumer guarantees. The bulk of those defects were a result of the manner in which the products were installed and filled with concrete. Those which could not be so described related largely to the protruding screw heads and timber panels over joins. In my view, even if it were established that those issues were a consequence of defects in the RiseWall panelling, they were items that would in the ordinary course have been removed, as Mr Pope and Pszczonka said, after the concrete had set as part of the final finishing. In other words, I am not satisfied that those items were not simply elements of the installation task which had not been completed.
Accordingly, the only damages recoverable by Actol would be compensation for the delay in completion of the buildings. However, I am not persuaded that Actol has presented sufficient evidence to enable me to assess the cost to Actol of the delays to the construction of the four houses caused by the supply of the defective RiseWall product.
Actol's claim for delay costs simply claimed two-thirds (that is four of six houses) of the interest cost on the loan which Mr Wakefield stated had been "taken out for construction of the six houses".
Mr Wakefield asserted that the project had been delayed by eight months, comprised of:
1. The time taken to complete the lower floor walls ready for pouring concrete pour (four months)
2. The time taken for Actol to organise an alternative system for the upper floors (two months)
3. The time taken while Actol waited for Rise Products, 3Form and Gledswood to return to rectify defects.
Even if I were prepared to accept that evidence as reliable, which I do not, as it lacks either detail or cogent reasoning, it does not enable me to assess the extent to which the particular failures of the RiseWall panels delivered by Rise Products caused delays to the completion of the project.
I do not accept that any delay in the project was entirely the consequence of the problems with the RiseWall product. 3Form's decision to walk away from the job may have been partly attributable to the problems with the RiseWall product, but I do not consider that a contractor washing its hands of its obligation under a contract to install the product is a foreseeable consequence of the delivery of product with the two deficiencies which I have found.
If I had concluded that Rise Products was liable for breach of the consumer guarantees, I would not have awarded more than nominal damages, as Actol has failed to provide evidence sufficient to enable an assessment of its loss: see Gallagher v Masters Installation Pty Ltd [2017] NSWCATAP 117, at [51].
[9]
Misleading and deceptive conduct
The misleading and deceptive conduct case maintained by Actol was not outlined with clarity in the Points of Claim or Amended Points of Claim filed before the hearing. On the first day of the hearing, I directed Mr Carter to provide "a very explicit identification of what you say the representations were… [with] each representation identified specifically as words that were said by someone to someone on a particular occasion".
Actol then filed in the course of the hearing a Further Amended Points of Claim which particularised the representations as follows:
a. the performance and products to be:
i. process / timeframe to be:
(1) delivery of the Product on Lots 3-6 by mid-September 2019;
(2) installation for Lots 3-6 overall to take no more than two (2) weeks from the date of delivery;
1 week for ground floor installation of Rise Walls on lots 3 - 6;
1 week for upper floor installation of Rise Walls on lots 3-6.
(Timing Representation)
Particulars
Affidavit of Peter Wakefield dated 17 December 2020
Paragraph 11- Daniel Pszczonka to Peter Wakefield in a meeting on 26 June 2019 "our product goes up very fast" and
"our product supersedes traditional masonry wall system by reducing cost time and space"
Paragraph 23-24 - Tim Pope to Peter Wakefield in a meeting on 20 August 2019- "Lots 3 to 6 will be done in two-week, one week to complete the ground and one week to complete the upper floor"
(3) Rise Products to engage competent agent/subcontractor familiar with the product to attend to the installation of the same;
(Oral Installation Representation / Installation Representation / Contractor Representation)
Particulars
Affidavit of Peter Wakefield dated 17 December 2020
Paragraph 12, 24
Paragraph 12 - Daniel Pszoncka to Peter Wakefield in a meeting on 26 June 2019 as follows:
Peter: You need to supply and install. Whoever you get as the installer has to be competent and have experience with using your product. I don't want anything to do with the installation.
Daniel: yes, no worries
Paragraph 24-Tim Pope to Peter Wakefield in a meeting on 20 August 2019 as follows:
Tim This is Daniel and Andrew from 3Form. They are the guys who are going to do the installation on this job. They are familiar with the Rise Products and we have worked with them in the past.
Peter ok that's good......
ii. the product to be of high quality installation and flexible design that is compatible with all types of finishes, reducing overall build time and any defects.
(Performance Representations)
Particulars
Affidavit of Peter Wakefield dated 17 December 2020
Paragraph 11- Daniel Pszczonka to Peter Wakefield in a meeting on 26 June 2019 as follows:
"our product is of high quality finish"
"our product is true and straight"
73
"our product is perfect flat finish and you won't have any problems like you did with Pro 9"
"the product goes up very fast and flexible design and compatible with all plans"
[references to the tender bundle have been omitted]
It is immediately apparent from that extract that there is a disconnection between the representations pleaded and the conversations alleged to contain the alleged representations.
Most obviously, there is nothing in the particulars regarding the "Timing Representation" which refers to the time frame for delivery of the RiseWall product, and there is no reference to reducing overall build time or reducing defects in the particulars of the "Performance Representations".
Nevertheless, the allegations made by Actol in relation to the Timing and Performance Representations are tolerably clear. The Timing Representation was that the installation of the RiseWall panels for all four houses would take one week for the ground floor and one week for the upper floor, which representation was alleged to have been made expressly by Mr Pope at the meeting on 20 August 2019. The "Performance Representation" consisted of four statements allegedly made by Mr Pszczonka to Mr Wakefield at the meeting on 26 June 2019 (see [41] above).
In its written submissions Actol stated that the alleged statement made by Mr Pszczonka that the "product goes up very fast" was a "precursor to the timing Representation", that is, not itself a representation relied upon by Actol as constituting misleading or deceptive conduct.
The "Oral Installation Representation/Installation Representation/Contractor Representation", which Actol in its written submissions referred to as the "Installation Representation" (a form of reference which I will adopt), was that any installer introduced by Rise Products would be competent. Actol submitted in its written submissions that the representation incorporated the proposition that Rise Products would "accept responsibility for the install and engage competent installers".
The Further Amended Points of Claim alleged that Actol relied upon each of the representations in entering into the contract with Rise Products. In circumstances where I have determined that the contract between Actol and Rise Products for was for the supply only of the RiseWall product, I understand that allegation to extend to the entry into contracts with 3Form and Gledswood.
Paragraph 25 of the Further Amended Points of Claim alleges that the representations were:
"misleading or likely to mislead in contravention of section 18 of the ACL as:
a. Rise Product did not perform, comply with and submit to the requirements of the agreements with Actol;
b. The
i. Timing Representations
ii. Oral Installation Representation / Installation Representation / Contractor Representation
iii. the Performance Representations,
caused Actol to proceed on the basis that Rise Products would perform, comply with and submit to the requirements of the agreement with Actol, even though Rise Product was intending not to comply."
It is not clear how Actol asserts that Rise Products' asserted failure to comply with the requirements of a contract rendered the representation misleading. In any event, as I have found that Rise Products did not contract with Actol for the installation, the allegation cannot be established.
Sub-paragraph 25(b) of the Further Amended Points of Claim appears to plead reliance rather that rather than falsity, except to the extent that it alleges that Rise Products did not intend to comply with the representations.
Actol did not put to either Mr Pszczonka or Mr Pope in cross-examination that Rise Products did not intend to comply with any representations.
Rise Products submitted:
"123 These allegations add nothing to Actol's claim for breach of contract because the only reliance Actol placed on the representations was to enter into the Contract: Amended Points of Claim para [23], [26] …. The only reason why the representations are alleged to have been deceptive or misleading is that Rise did not comply with the agreement: Amended Points of Claim para [25] (a); …; or "caused Actol to proceed on the basis that Rise... would perform, comply with and submit to the requirements of the agreement": Amended Points of Claim para 25[b)]….
124 It follows that even if Actol establishes that Rise made the misrepresentations, Actol has not suffered any damage by reason of the making of the alleged misrepresentations that is different or independent from any loss it suffered by reason of any alleged breach of the Contract. The only thing these allegations add to Actol's claim is pointless complexity. …"
Despite the inadequate pleading of the case, it is apparent from Actol's written submissions that its case is that:
1. The Timing Representation was misleading because the RiseWalls were not erected in two weeks;
2. The Installation Representation was misleading because Rise Products did not "accept responsibility for the Install and engage competent installers experienced with installing the Rise Wall 160 Product"; and
3. The Performance Representation was misleading because "the Product supplied did not meet the standards as represented … by Mr Pszczonka".
Actol also pleaded that the representations were made in respect of a future matter and relied upon s 4 of the ACL.
That section provides:
"4 Misleading representations with respect to future matters
(1) If:
(a) a person makes a representation with respect to any future matter (including the doing of, or the refusing to do, any act); and
(b) the person does not have reasonable grounds for making the representation;
the representation is taken, for the purposes of this Schedule, to be misleading.
(2) For the purposes of applying subsection (1) in relation to a proceeding concerning a representation made with respect to a future matter by:
(a) a party to the proceeding; or
(b) any other person;
the party or other person is taken not to have had reasonable grounds for making the representation, unless evidence is adduced to the contrary.
(3) To avoid doubt, subsection (2) does not:
(a) have the effect that, merely because such evidence to the contrary is adduced, the person who made the representation is taken to have had reasonable grounds for making the representation; or
(b) have the effect of placing on any person an onus of proving that the person who made the representation had reasonable grounds for making the representation.
(4) Subsection (1) does not limit by implication the meaning of a reference in this Schedule to:
(a) a misleading representation; or
(b) a representation that is misleading in a material particular; or
(c) conduct that is misleading or is likely or liable to mislead;
and, in particular, does not imply that a representation that a person makes with respect to any future matter is not misleading merely because the person has reasonable grounds for making the representation.
I accept that the Timing Representation, if proved, would be a representation with respect to a future matter. I do not accept that the Installation Representation or, save in one respect, the Performance Representation were representations with respect to future matters. The Installation Representation, if made, could only have been referring to 3Form, not to any installer which Rise Products might introduce in the future. The Performance Representation, if made, related to the RiseWall product in general, not to the specific product which would be delivered to Actol. The one respect in which the Performance Representation might be characterised as a representation as to the future is the statement, allegedly made by Mr Pszczonka, that "you won't have any problems like you did with Pro 9".
Accordingly, it is only the Timing Representation and one aspect of the Performance Representation, if proved, which attract the operation of s 4 of the ACL.
Actol pleaded that it relied upon the representations in entering into the contract with Rise Products. As noted above, in circumstances where I have found that the contract between Actol and Rise Products was for supply only of the RiseWall product, I interpret that allegation as amounting to the proposition that Actol would not have agreed to purchase the RiseWall product and would not have entered into a contract with 3Form to install the product if the representations had not been made.
Actol also pleaded that Mr Pszczonka:
"b. Was knowingly concerned and had actual knowledge of the essential matters which made up the Rise Product's contravention and their falsity, as Rise Product's representations were made by Daniel Pszczonka or at his request.
c Is a person involved in that contravention within the meaning of Section 236 of the Australian Consumer Law."
Actol relied in support of Mr Pszczonka's liability as an accessory on the judgment of Gleeson CJ in Pollock v Hicks [2015] NSWCA 122 at [78] - [79]:
"One further matter should be mentioned lest it be thought that it had been overlooked. There is debate in the authorities as to whether it is necessary to establish that the person allegedly involved in a contravention knew that the conduct was misleading or unconscionable (as the case may be), or whether it is enough to prove awareness of the matters that enable the acts constituting such conduct to be so characterised: see Medical Benefits Fund of Australia v Cassidy (2004) 205 ALR 402 at [15] where Moore J (with whom Mansfield J agreed; cf Stone J at [80]) expressed the view that all that would be necessary would be for the accessory to know of the matters that enabled the representations to be characterised as either relevantly false or misleading.
A similar approach was taken in Keller v LED Technologies Pty Ltd [2010] FCAFC 55; 185 FCR 449 at [336] where Besanko J (with whom Jessup J agreed) said:
In a case concerning representations, the essential elements of the contravention are the fact that the representation was made and that, in a case such as the present, it was misleading or deceptive, or likely to mislead or deceive (s 52) or was false (s 53(a) and (c)). To establish accessorial liability it must be established that the relevant person knew the representation was made and the facts which made it misleading or deceptive, or likely to mislead or deceive, or false. It need not be shown that the relevant person actually drew the conclusion that the representation was misleading or deceptive, or likely to mislead or deceive, or was false. [Emphasis added.]
Actol claimed that its losses flowing from its reliance upon the representations were those sought to be recovered in respect of its contract and consumer guarantee claims, that is the cost of rectification of the RiseWalls, delay costs and the value of the RiseWall products not delivered.
[10]
Did Rise Products or Mr Pszczonka make the representations alleged by Actol?
[11]
The Timing Representation
I am not persuaded that Rise Products or Mr Pszczonka made the Timing Representation as pleaded. The representation was specific, that is as set out above at [271].
As I have already observed, Actol did not, in the particulars provided in the Further Amended Points of Claim, identify any evidence of any representation concerning the timing of the deliveries of product.
The alleged representation which Actol particularised and relied upon in its written submissions was a representation that the installation would take no more than two weeks from the date of delivery of the panels.
In its written submissions Actol submitted that the following evidence clearly establishes "that the timing representation was made"
"233. At the Site Meeting on 26 June 2019, Mr Pszczonka stated to Mr Wakefield that "the product goes up very fast" as a precursor to the Timing Representation.
234. Rise's own Website included marketing material sets out "Short Lead Times - On Site within two days from placing the Order". … "4 x faster than blockwork or traditional formwork to install" ….
235. During Cross-Examination Mr Pszczonka confirmed that a conversation took place in respect of timing … with Mr Wakefield however was unable to recall the specifics.
236. In accordance with the Timing Representation, Mr Pszczonka later confirmed that he expected an install could take "Four weeks / Six Weeks / Two Weeks" ….
237. Whilst Mr Pope alleges that he only attended the meeting as an observer …, Mr Pszczonka in Cross-Examination makes no reference to Mr Popes role as an "observer" and rather confirms the contrary. He stated that Mr Pope had specific involvement in the discussions of timing, namely "I was aware there was a conversation about the timing of things. Scaffolding and the - Tim's conversations and stuff" ….
238. Rise's evidence by Mr Pope and Mr Pszczonka that it was "Andrew" from 3Form who stated that the works would take "a couple of weeks" … and while both participated in the communication they none the less remained silent and did not correct the proposed installer."
Actol submitted:
"239. In the event that Mr Pope and Mr Pszczonka evidence on this topic is preferred over Actol's, then based on Rise's own evidence, the Timing Representation is still made good by virtue of their silence."
In support of the submission that the silence of Mrs Pszczonka and Pope constituted misleading and deceptive conduct Actol submitted:
"204. Silence may amount to misleading or deceptive conduct, if the person who is said to have been misled or deceived had a reasonable expectation that if the relevant matter existed it would be disclosed: see Demagogue Pty Ltd v Ramensky (1992) 39 FCR 31 at 41 per Gummow J.
205. More recently in Nadinic v Cheryl Drinkwater as trustee for the Cheryl Drinkwater Trust [2020] NSWCA 2, Barrett AJA observed at [40] that:
'Silence is itself a fact that must be assessed like any other and, unless the circumstances as a whole are such as to give rise to a reasonable expectation of disclosure of some relevant fact known to exist but not communicated, there is no basis on which silence of itself can warrant an inference of a representation that the fact does not exist.' "
I am not persuaded on the balance of probabilities that Mr Pope said that the formwork would be erected in two weeks. Mr Pszczonka in cross examination did not accept that that was said. In cross examination of Mr Pszczonka, Mr Carter put to him Mr Wakefield's version of the conversation on 20 August 2019 (see [48] above). Mr Carter asked "Do you recall that - listening to that conversation?" The cross-examination continued:
MR PSZCZONKA: No, but I do - I'm aware that there was a conversation about the timing of things. Scaffolding and the - Tim's conversations and stuff, I'm-I'm sorry, I just don't......
MR CARTER: And would it-would it be consistent that - for the 160 product that it would - should have taken installation of about one week for a ground floor?
MR PSZCZONKA: They're the installers. They're the ones saying how long it takes. We-like, I can't-you know, more people, it's faster. Not many people, slower. I-yes, I'm-
MR CARTER: And Mr-that was actually Mr Pope saying those things. So you don't have any recollection of Mr Pope saying that it will take one week-"Lots 3 to 6 will be done in two weeks, one week to complete the ground floor and one week to complete the upper floor"?
MR PSZCZONKA: I'm sorry, I'm just - I'm not - I know that the conversation - people are saying these times, but, you know, who said what, like, it's-yes, I'm sorry, it's just a very long time ago, but I remember 3Form saying that, yes, this is how long things were going to take. Yes. You know, came from the conversation.
MR CARTER: Okay. … Mr Pszczonka, if Mr Pope had said that it would take one week to do the ground floor and one week to do the first storey and that was wrong, it's reasonable to say you would have corrected him at that meeting. wouldn't you?
MR PSZCZONKA: Look, I'm not exactly sure if Tim said it or 3Form said it. I- you know, that's probably a question for Tim.
MR CARTER: You just have..... you can remember the conversation, you can't remember the exact details.
MR PSZCZONKA: I actually honestly can't 100 per cent remember if I was even there. I remember being there for different meetings. You know, I can't remember conversations from two and a half years ago. You know, it's pretty - pretty difficult. Very difficult.
MR CARTER: Well,
MR PSZCZONKA: And actually who said what at the meetings, like, it's - it's difficult.
At a later point, Mr Carter put the question to Mr Pszczonka:
"Assuming that on the 6th of September the product was delivered to site and Rise installers were ready and the builder was ready, how long would you expect the ground floor would have taken to erect/install and the concrete poured?"
The evidence continued:
MR PSZCZONKA: Probably forever because we don't do install, but independent installers, I probably would have said - I'd probably say four - four weeks or something.
MR CARTER: Four weeks for the ground floor? MR PSZCZONKA: Yes. Four weeks/six weeks/two weeks. I don't know.
MR CARTER: Well - - -
MR PSZCZONKA: Two weeks/four weeks. MR CARTER: Two-two - - -
MR PSZCZONKA: The more … the builder have prepared for them the better.
There is no supporting evidence for the proposition that Mr Pope said that the installation of both floors would take two weeks. Mr Pszczonka's evidence was that he would have expected to take it to take between two and six weeks for the ground floor alone, depending on how well the builder had prepared for the installers.
Mr Pope's evidence was that Mr Francis of 3Form had said that the installation would take a couple of weeks. I note that Mr Wakefield's own email of 16 November 2019 (see [103] above) states that 3Form said it would be done in a week.
I am not persuaded that Mr Pszczonka or Mr Pope adopted that estimate in any way or were under any duty or obligation to correct it.
In any event Mr Wakefield stated in his email of 16 November 2019 that he did not think it could be done in a week. Mr Wakefield confirmed in cross examination that he "knew a week was probably tight."
That evidence is inconsistent with the proposition that Actol relied upon any representation that the installation could be completed in two weeks.
I accept that Rise Products did not lead evidence that any representation that the formwork could be installed in two weeks was based on reasonable grounds. However, I have found that that representation was not made.
I am not called upon to decide whether Rise Products made any more general representation about the speed with which the RiseWall product could be erected.
The Tribunal is required by s 38(4) of the Civil and Administrative Tribunal Act 2013 (NSW) to act "with as little formality as the circumstances of the case permit and according to equity, good conscience and the substantial merits of the case without regard to technicalities or legal forms". However, it is also required to afford the parties procedural fairness.
Actol relied upon the provisions of s 4 of the ACL to cast an evidentiary onus upon Rise Products to tender evidence that it had reasonable grounds to make the representation alleged. In those circumstances, procedural fairness required that Actol specify in advance of the hearing the precise representations which it relied upon. It is not open to Actol to allege a different representation which Rise Products was not on notice it was required to justify.
[12]
The Installation Represention
I have already indicated that I do not accept that Mr Wakefield made the first statement particularised by Actol as constituting part of the Installation Representation (see [174] above). If that statement was not made, Mr Pszczonka could not have agreed to it and the proposition that Rise Products represented that it would "accept responsibility for the install" cannot be maintained.
I accept that on 20 August 2019 Rise Products introduced 3Form to Actol as an appropriate installer. Mr Pszczonka's evidence was that Mr Pope said to Mr Wakefield that 3Form "can do the installation" (see [49] above).
Neither Mr Wakefield's version of the conversation, "They [3Form] are familiar with the Rise Products and we have worked with them in the past" (see [48] above), nor Mr Pszczonka's version, involved an express statement that 3Form was competent.
I accept that, by introducing 3Form as an appropriate installer, Rise Products represented that it believed them to be competent. However, Actol did not rely upon such a representation and did not seek to establish that it was not true, that is that Rise Products did not believe 3Form to be competent.
In any event, I am not satisfied that Actol has established that 3Form was in fact not a competent installer. To the extent that there is evidence before the Tribunal concerning 3Form's performance as an installer of the RiseWall product, it suggests that 3Form was having the same difficulties as Mr Healy but was not able to overcome those difficulties as efficiently or effectively.
Mr Gharib's evidence was that 3Form had had experience with other wall construction systems, but had not installed RiseWall product at any site before August 2019.
Mr Gharib gave evidence that, at the start of the project, Mr Pope and Ms Hatem were on-site "trying to teach us how to use the product and show us how it worked". He also stated that Ms Hatem was there "most of the time we were there" and that "we told her we knew how to do it and then told her what needs to be fixed".
Mr Gharib further stated that "from our knowledge we know where to put the bracing" but that the bracing was not the problem with the RiseWall product.
I have set out above Mr Gharib's evidence concerning the problems 3Form experienced with installing the RiseWall product (see [82] above).
It is fair to say that Mr Carter's cross-examination of Mr Gharib did not in any way seek to establish that either Mr Gharib or 3Form were not competent to install the RiseWall product.
I do not find that such representations as were made by Rise Products concerning the installation of the RiseWall product were misleading or deceptive in breach of s 18 of the ACL.
[13]
Performance Representations
Mr Pszczonka acknowledged in cross-examination that it was his usual practice in 2019 to "promote the positive parts of the RiseWall product to potential customers" which included telling potential customers that the RiseWall product:
"is a high quality finish"
"is true and straight once erected"
"is a perfect flat finish"
"[goes] up very fast"
"[is] a flexible design" and
"[is] compatible with all drawings, specifications and plans".
Mr Pszczonka did not dispute Mr Wakefield's version of the conversation in which Mr Wakefield alleged that the Performance Representations were made.
I accept that representations to the effect of the Performance Representations, as particularised by Actol in the Further Amended Points of Claim, were made by Mr Pszczonka to Mr Wakefield in June 2019.
However, as noted above, the representations concerned the RiseWall product generally, not the specific goods delivered to the Site.
Although I have found that the product delivered to the Site was not of acceptable quality and not fit for the purpose of being an easily installed formwork system, Actol did not tender evidence and did not seek to establish that the RiseWall Super Finish 160 Series product was, generally, not:
of high quality finish
true and straight
perfect flat finish
capable of erection very quickly
flexible in design or
compatible with all plans.
Mr Pszczonka's evidence concerning the conversation with Mr Wakefield in June 2019 was:
"I recall a conversation along the lines set out. Pro 9 is a competitor's product that in my view, leaves walls with a rough surface. Rise Products' Rise Wall products use fibre cement sheets that leave a much smoother surface than Pro 9."
That suggests that the statement "you won't have any problems like you did with Pro 9" was made in the context of discussions concerning the surface finish of the product.
In that context, even if the representation is characterised as a representation as to a future matter, there was evidence that Rise Products had reasonable grounds for the representation, that is "Rise Wall products use fibre cement sheets that leave a much smoother surface than the Pro 9".
Mr Pszczonka was not challenged on his evidence in that regard.
Accordingly, I am not persuaded on the balance of probabilities that Actol has established that the Performance Representations were misleading and deceptive in breach of s 18 of the ACL.
It follows that Actol's case pursuant to s 18 of the ACL must fail, both against Rise Products and against Mr Pszczonka.
[14]
Reliance and Damages
I note that, even if I had found that Rise Products and/or Mr Pszczonka had breached s 18 of the ACL, I would not have found that Actol had established any loss flowing from those breaches.
Actol pleaded that, but for the representations, it would not have entered into the contract with Rise Products. Had Actol not entered into the contract with Rise Products for the acquisition of the RiseWall formwork, it would have needed to utilise another method of constructing the ground floor walls of the four houses.
Actol's evidence did not disclose what alternative method Actol would have adopted. As the anticipated advantages of the RiseWall system included the speed with which it could be erected and the cost of acquiring and erecting it, it may be assumed that any alternative method of installation of the ground floor walls would have been more expensive than the sum agreed with Rise Products and 3Form.
The measure of Actol's loss would be the difference between what it has cost Actol to acquire and fill the RiseWall formwork, including the rectification of defects, and what it would have cost Actol to construct the ground floor walls if it had adopted a different method of construction.
Actol would also be entitled to claim compensation for the additional time which the completion of the walls took beyond what would have been the case if an alternative method of construction had been adopted.
Actol did not tender any evidence to establish either the alternative method of construction it would have used, the cost of that alternative method of construction, or the time which walls constructed by that alternative method would have taken to completion.
It cannot be said that such evidence would not have been available should Actol have sought to obtain it. Accordingly, on the principles outlined in Gallagher v Masters Installation Pty Ltd [2017] NSWCA 117 at [51], no compensation can be awarded.
Because the claim for misleading and deceptive conduct has failed, it is not necessary to consider Rise Products' submission that the claim is apportionable and that 3Form and Gledswood are concurrent wrongdoers.
[15]
Actol's claim to reimbursement of the cost of goods not delivered
Actol's claim to reimbursement of the cost of the goods not delivered by Rise Products, as pleaded and outlined in its written submissions, is founded upon the alleged repudiation of the contract by Rise Products.
Actol relied upon the failure of 3Form (and Rise Products) to complete the construction of the ground floor walls within three weeks of delivery of the formwork panels for the first floor. Actol submitted:
"A period of nine week passing, with no final installation or concrete pour date in sight, signalled an intention by Rise not to comply with the agreement that Actol says that it entered into with them. The delay was simply unreasonable. It was a breach of an essential term of the contract.
…
Actol therefore says it was entitled to accept Rise's repudiatory conduct and signal its intention to not proceed with the first floor panels."
As Rise Products had no obligation to install the formwork or finish the walls, I do not accept that Rise Products had repudiated the contract between Rise Products and Actol.
However, I am satisfied that the issues with the product, which I have referred to above, were such that Actol was entitled to reject the undelivered portion of the goods the subject of the contract.
Rise Products' own evidence was that the panels for the upper floors had been specifically manufactured for the project. Mr Pope stated in his affidavit:
"The product had to be custom-made for the job at the Site and is still sitting in a warehouse in St Marys."
It is implicit in that evidence that the panels for the first floor to which Mr Pope referred incorporated the same issues with inconsistent tongue widths as the product which had been delivered for the construction of the ground floor. Had Rise Products sought to deliver the balance of the order, Actol would have been entitled to reject it as not of acceptable quality and not fit for purpose.
In circumstances where Rise Products has not sought to deliver the goods, I consider that Rise Products has implicitly accepted that the goods have been rejected. Rise Products has not sought to tender performance of the balance of the contract in the form of the delivery of defect free product. Although Rise Products did, by its solicitors' letter of 22 May 2020, demand that Actol arrange for the collection of the remaining product, that was the product in storage since September 2019, which Actol was not required to accept. Rise Products has not at any stage indicated that it has available product which does not suffer from the issues which I have identified. In these circumstances, the only available conclusion must be that Actol rescinded the contract, or the parties have abandoned it, to the extent that it requires the delivery of the balance of the order.
In those circumstances, Actol is entitled to restitution of the amount paid for the goods which were not delivered. The amount in question is half of the sum paid by Actol for the RiseWall product, that is $50,650.60.
The question arises whether the Tribunal has jurisdiction to order the repayment of that sum. The claim made by Actol arises in restitution, as reimbursement of monies paid for goods not delivered. Although the goods were intended for incorporation into a residential building, I do not consider that Actol's claim to repayment of monies paid for the goods is a "building claim" within the meaning of s 48A of the Home Building Act. "Building claim" is defined in s48A, for the purposes of Part 3A of the Home Building Act, as follows:
"building claim means a claim for -
(a) the payment of a specified sum of money, or
(b) the supply of specified services, or
(c) relief from payment of a specified sum of money, or
(d) the delivery, return or replacement of specified goods or goods of a specified description, or
(e) a combination of two or more of the remedies referred to in paragraphs (a)-(d),
that arises from a supply of building goods or services whether under a contract or not, or that arises under a contract that is collateral to a contract for the supply of building goods or services, but does not include a claim that the regulations declare not to be a building claim."
"Building goods or services" is defined as follows:
"building goods or services means goods or services supplied for or in connection with the carrying out of residential building work or specialist work, being goods or services -
(a) supplied by the person who contracts to do, or otherwise does, that work, or
(b) supplied in any circumstances prescribed by the regulations to the person who contracts to do that work."
Although the undelivered RiseWall panels were contracted to be supplied for the carrying out of residential building work, the construction of reinforced concrete walls, they were not contracted to be supplied by the person who contracted to do, or otherwise did, that work. There is no provision in the regulations which affects either definition.
Accordingly, the Tribunal does not have jurisdiction pursuant to s 48K of the Home Building Act to order restitution of the amount paid for the undelivered RiseWall product.
Nevertheless, the Tribunal does have jurisdiction pursuant to s 79J of the Fair Trading Act 1987 (NSW) to determine a consumer claim.
A "consumer claim" is defined, relevantly, in s 79E as:
"a claim by a consumer, for one or more of the following remedies, that arises from a supply of goods or services by a supplier to the consumer (whether or not under a contract) or that arises under a contract that is collateral to a contract for the supply of goods or services -
(a) the payment of a specified sum of money".
Pursuant to s 79D "consumer" includes a small proprietary company within the meaning of the Corporations Act 2001 (Cth).
Section 79H provides:
"For the purposes of this Part:
(a) a person or body claiming to be a consumer is to be presumed to be a consumer until the contrary is proved, and
(b) in any legal proceedings (including proceedings before the Tribunal), the onus of proving that a person or body claiming to be a consumer is not a consumer is on the party who seeks to establish that fact."
Although Actol alleged in its Further Amended Points of Claim that it was a "consumer" within the meaning of the Competition and Consumer Act 2010 (Cth), it does not explicitly allege that it is a consumer for the purposes of the Fair Trading Act. Nevertheless, it is clear, both from the nature of the claims made in the Further Amended Points of Claim and from Actol's written submissions, that it does claim to be a consumer for the purposes of the Fair Trading Act. Rise Products did not tender evidence to establish that Actol is not a small proprietary company within the meaning of the Corporations Act, (where that term is defined in s 45A(2)). I therefore proceed on the basis that Actol is a small proprietary company and therefore a consumer for the purposes of the Fair Trading Act.
Pursuant to s 79D of the Fair Trading Act, "supplier means a person who, in the course of carrying on (or purporting to carry on) a business, supplies goods or services." Clearly Rise Products supplies RiseWall product in the course of carrying on a business.
Accordingly, the claim by Actol against Rise Products for reimbursement of the amount paid for the undelivered goods is a consumer claim and the Tribunal has jurisdiction to determine it pursuant to s 79J of the Fair Trading Act.
The question then arises whether the limit of the Tribunal's jurisdiction in respect of the claim is $40,000, as limited by s 79S of the Fair Trading Act at the time the proceedings were commenced, or $100,000, as provided by regulation 13A of the Fair Trading Regulation 2019 (NSW), which came into effect on 18 July 2022.
Section 79S of the Fair Trading Act relevantly provides:
"79S Monetary limit on Tribunal's jurisdiction to make orders
(1) The Tribunal has no jurisdiction to make, in respect of a particular consumer claim, an order or orders in favour of the claimant (or, where there are two or more claimants, in favour of those claimants) if the relevant total under or because of the order or orders would exceed the prescribed amount.
(2) For the purposes of subsection (1), the relevant total is the total of -
(a) the amount or amounts (if any) of money to be paid, and
(b) the value or values (if any) of the work to be performed, or the services to be supplied, and
(c) the amount or amounts (if any) of money to be declared not to be due or owing, and
(d) the value or values of goods (if any) to be delivered or replaced.
…
(7) In this section -
…
prescribed amount means $40,000 or such other amount as is prescribed for the purposes of this section."
Regulation 13A of the Fair Trading Regulation 2019 (NSW), which was inserted into the Regulation by the Fair Trading Amendment (Monetary Limit on Orders) Regulation 2022 (NSW) and came into effect on 18 July 2022, provides:
"13A Monetary limit on Tribunal's jurisdiction to make certain orders
For the Act, s 79S(7), definition of prescribed amount, the amount of $100,000 is prescribed."
The amendment regulation did not contain any transitional provisions indicating whether the increased jurisdictional limit of $100,000 would be applicable to proceedings which had already commenced.
Rise Products submitted that, by virtue of the presumption against the retrospective operation of legislation, regulation 13A should not be construed as affecting existing proceedings.
Actol submitted, in reliance upon the decision in Gaskell and Bourke v Northshore Homes Pty Ltd and Nazha [2021] NSWCATCD 33, that, by reason of the provisions of s 74(3) of the Fair Trading Act, neither s 79S nor regulation 13A limited the damages that could be awarded in these proceedings. Actol's submissions otherwise appeared to submit that, if the jurisdiction of the Tribunal was limited by the provisions of the Fair Trading Act, the applicable limit upon the Tribunal's jurisdiction should be $100,000.
Section 74(3) of the Fair Trading Act relevantly provides:
"74 Actions for damages and compensation orders
…
(3) The Tribunal may decide the matter of whether a person has suffered loss or damage because of the conduct of another person that constitutes a local contravention or a contravention of Chapter 2 or 3 of the ACL if that matter arises in connection with another matter the subject of proceedings in the Tribunal. In deciding the matter of loss or damage, the Tribunal may award such sum, and make such ancillary orders, as it thinks fit."
In Gaskell the Tribunal determined that the limitation in s 79S did not apply to a claim against the second respondent, a director of the first respondent building company, for misleading and deceptive conduct in breach of s 18 of the ACL. The Tribunal found that it had jurisdiction in respect of the claim for breach of s 18 pursuant to s 73(4) of the Fair Trading Act, because the claim arose "in connection with another matter the subject of proceedings in the Tribunal, namely the owner's case against the first respondent in relation to a building claim as defined by the Home Building Act". Actol's submissions regarding the decision in Gaskell did not appear to comprehend the basis upon which the Tribunal found it was not restricted in the amount it could award by s 79S of the Fair Trading Act.
Section 74(3) only vests jurisdiction in the Tribunal with respect to claims for damages in respect of contraventions of chapters 2 and 3 of the ACL. Chapter 2 of the ACL comprises sections 18 to 24. Chapter 3 of the ACL comprises sections 29 to 150.
A claim for restitution of monies paid for goods not delivered is not a claim for damages in respect of a contravention of chapters 2 or 3 of the ACL.
Accordingly, s 74(3) of the Fair Trading Act is clearly not applicable and it is unnecessary to consider the decision of the Appeal Panel in John McDonald Building Services Pty Ltd v Gusa [2022] NSWCATAP 60 which, at first blush, appears to be inconsistent with the decision in Gaskell.
Thus, the issue requiring to be determined is whether regulation 13A is applicable in these proceedings.
Section 30 of the Interpretation Act 1987 (NSW) provides:
"30 Effect of amendment or repeal of Acts and statutory rules
(1) The amendment or repeal of an Act or statutory rule does not -
(a) revive anything not in force or existing at the time at which the amendment or repeal takes effect, or
(b) affect the previous operation of the Act or statutory rule or anything duly suffered, done or commenced under the Act or statutory rule, or
(c) affect any right, privilege, obligation or liability acquired, accrued or incurred under the Act or statutory rule, or
(d) affect any penalty incurred in respect of any offence arising under the Act or statutory rule, or
(e) affect any investigation, legal proceeding or remedy in respect of any such right, privilege, obligation, liability or penalty,
and any such penalty may be imposed and enforced, and any such investigation, legal proceeding or remedy may be instituted, continued or enforced, as if the Act or statutory rule had not been amended or repealed.
(2) Without limiting the effect of subsection (1), the amendment or repeal of an Act or statutory rule does not affect -
(a) the proof of any past act or thing, or
(b) any right, privilege, obligation or liability saved by the operation of the Act or statutory rule, or
(c) any amendment or validation made by the Act or statutory rule, or
(d) the operation of any savings or transitional provision contained in the Act or statutory rule.
(3) This section applies to the amendment or repeal of an Act or statutory rule in addition to, and without limiting the effect of, any provision of the Act or statutory rule by which the amendment or repeal is effected.
(4) In this section, a reference to the amendment or repeal of an Act or statutory rule includes -
(a) a reference to the expiration of the Act or statutory rule,
(b) a reference to an amendment or repeal of the Act or statutory rule effected by implication,
(c) a reference to the abrogation, limitation or extension of the effect of the Act or statutory rule, and
(d) a reference to -
(i) the exclusion from the application of the Act or statutory rule, or
(ii) the inclusion within the application of the Act or statutory rule,
of any person, subject-matter or circumstance."
In considering whether an amendment to legislation has retrospective effect, the principle applicable at common law, that is in the absence of a provision such as s 30, was expressed by Dixon CJ in Maxwell v Murphy (1957) 96 CLR 261 at 267:
"The general rule of the common law is that a statute changing the law ought not, unless the intention appears with reasonable certainty, to be understood as applying to facts or events that have already occurred in such a way as to confer or impose or otherwise affect rights or liabilities which the law had defined by reference to the past events. But, given rights and liabilities fixed by reference to past facts, matters or events, the law appointing or regulating the manner in which they are to be enforced or their enjoyment is to be secured by judicial remedy is not within the application of such a presumption. Changes made in practice and procedure are applied to proceedings to enforce rights and liabilities, or for that matter to vindicate an immunity or privilege, notwithstanding that before the change in the law was made the accrual or establishment of the rights, liabilities, immunity or privilege was complete and rested on events or transactions that were otherwise past and closed. The basis of the distinction was stated by Mellish LJ in Republic of Costa Rica v Erlanger [(1876) 3 Ch D 62, at 69]. 'No suitor has any vested interest in the course of procedure, nor any right to complain, if during the litigation the procedure is changed, provided, of course, that no injustice is done'."
As Pearce records in Statutory Interpretation in Australia, Ninth Edition 2019, at 10.37:
"it does not appear that the courts regard the statutory test as leading to any result different from that which would flow from an application of the common law presumption."
Pearce cites, in support of that proposition, the High Court decision in Carr v Finance Corporation of Australia Ltd (No 2) [1982] HCA 43; (1982) 150 CLR 139, at 152.
In Robertson v City of Nunawading [1973] VR 819, at 827, the Full Court of the Supreme Court of Victoria held, referring to s 7(2) of the Acts Interpretation Act 1958 (Vic) which was in similar terms to s 30(1) of the Interpretation Act:
"There may be some areas in which the limits of the common law principle and those of this statutory provision are not the same. The case where an amending statute imposes an entirely new obligation may be one covered by the common law principle and not by the statutory provision. But, for present purposes, the quality of the 'right' required for the purpose of the statutory provision can be tested in the same way as a right for the purpose of applying the common law principle".
See also R v Papanicolaou (No 4) [2021] NSWSC 1698 at [38], where Wright J held:
"38 … The principles to be applied in construing [the relevant provisions which had been amended] include the general rule of the common law that a statute changing the law ought not, unless the intention appears with reasonable certainty, to be understood as applying to facts or events that have already occurred in such a way as to confer or impose or otherwise affect rights or liabilities which the law had defined by reference to the past events: Maxwell v Murphy (1957) 96 CLR 261 at 267 (Dixon CJ); [1957] HCA 7; Rodway v The Queen (1990) 169 CLR 515 at 519 (Mason CJ, Dawson, Toohey, Gaudron and McHugh JJ); [1990] HCA 19. Section 30 of the Interpretation Act, …, is a statutory provision to essentially the same effect."
In my view it is clear that the enactment of regulation 13A does not affect any right, privilege, obligation or liability acquired or accrued under the Fair Trading Act or Regulation.
The past events giving rise to the liability on the part of Rise Products were not affected by the limit on the jurisdiction of the Tribunal imposed by s 79S or by the enactment of a regulation increasing that limit. Those past events have, as I have determined, given rise to a right of Actol to reimbursement and a liability to reimburse Actol on the part of Rise Products. Adapting the words of Dixon CJ, "the law appointing or regulating the manner in which [those rights and liabilities] are to be enforced … by judicial remedy" is affected by the enactment of regulation 13A, but the rights and liabilities themselves are not.
In this context, the statement of Mellish LJ quoted by Dixon CJ in Maxwell v Murphy is apt. Rise Products had no vested interest in the limit imposed upon the capacity of the Tribunal to make orders in respect of a consumer claim, nor any right to complain if, during the litigation, that capacity is changed.
Rise Products submitted that it "might have conducted the case and any negotiation of settlement differently had it been aware of [the] change in exposure" arising from the enactment of regulation 13A.
Rise Products did not particularise any way in which it claimed it "might" have acted differently. I do not consider that knowledge that the limit of jurisdiction was $100,000 rather than $40,000 would have affected any decision made by Rise Products in relation to the substantive conduct of the proceedings. Any decisions made by Rise Products in relation to settlement offers seem to me to be relevant only to the consideration of questions of costs, where they may be brought into consideration, and the impact of the increase in jurisdiction taken into account.
In any event, the question whether potential injustice would result from the application of the increased limit on jurisdiction to existing cases, must be answered in general, and not by reference to the specific circumstances of the instant case.
Once it is recognised that there is no vested right to have proceedings determined in the Tribunal subject to a particular limit on jurisdiction, it follows that there can be no injustice to a party which may find that the jurisdictional limit has increased during the pendency of the proceedings in the Tribunal.
Accordingly, I find that the limit of the Tribunal's jurisdiction in respect of the consumer claim brought by Actol against Rise Products is $100,000 and I will order Rise Products to pay Actol the full amount paid in respect of the RiseWall products not delivered, that is $50,650.60.
[16]
Costs
The parties sought to be heard with on the question of costs.
The amount claimed in the proceedings exceeds $30,000. Accordingly, rule 38 of the Civil and Administrative Tribunal Rules 2014 (NSW) is applicable and special circumstances are not necessary before I may make an order in relation to the costs of the proceedings.
Although Actol has succeeded in obtaining a judgment in its favour, it has succeeded in only one element of its claim and in a small proportion of the total amount claimed.
Presumptively, Gledswood would be entitled to an order for costs, as it has succeeded in full, but it was not legally represented at the hearing and may choose not to seek an order for costs.
I will make directions permitting any party to make an application for costs, accompanied by submissions which should not exceed five pages, within 14 days. Such application should include a detailed statement of the orders sought, including in relation to the allocation between Actol and Rise Products of any costs that may be awarded to Gledswood.
All parties will have 14 days to respond to submissions filed by other parties. Submissions in response should not exceed five pages. I will allow parties to file submissions strictly in reply within a further 14 days.
Submissions filed by any party should address the question whether the issue of costs can be determined on the basis of the written submissions and without a further hearing.
If no application is filed in accordance with my orders there will be no order as to costs.
[17]
ORDERS
My orders are:
In proceedings HB 20/35833
1. The first-named respondent, Rise Products Pty Ltd, is to pay the applicant, Actol Pty Ltd, the sum of $50,650.60 within 28 days of the date of publication of this decision.
2. The proceedings are otherwise dismissed.
In proceedings HB 21/30136
1. The proceedings are dismissed.
In both proceedings
1. Within 14 days of the date of publication of this decision, any party may file submissions, not exceeding five pages, and evidence in support, seeking an order in respect of the costs of the proceedings.
2. If any party files submissions in accordance with order 4, the other parties may file submissions in response, not exceeding five pages, and any evidence relied upon, within a further 14 days.
3. Submissions strictly in reply to submissions filed in accordance with order 5, not exceeding three pages, may be filed within a further 14 days.
4. Any submissions filed in accordance with orders 4 and 5 must address the question whether the issue of costs can be determined on the basis of written submissions and without a further hearing.
5. If no submissions are filed in accordance with order 4, there will be no order in relation to the costs of the proceedings.
[18]
I hereby certify that this is a true and accurate record of the reasons for decision of the Civil and Administrative Tribunal of New South Wales.
Registrar
[19]
Amendments
22 September 2023 - Formatting amendments.
DISCLAIMER - Every effort has been made to comply with suppression orders or statutory provisions prohibiting publication that may apply to this judgment or decision. The onus remains on any person using material in the judgment or decision to ensure that the intended use of that material does not breach any such order or provision. Further enquiries may be directed to the Registry of the Court or Tribunal in which it was generated.
Decision last updated: 22 September 2023
Legislation Cited (14)
Acts Interpretation Act 1958(Vic)
Fair Trading Amendment (Monetary Limit on Orders) Regulation 2022(NSW)
iction was applicable to proceedings already on foot at the time of the amendment
STATUTORY INTERPRETATION - Principle of legality - Retrospectivity - Interpretation Act 1987 (NSW), s 30 - Increase of jurisdiction of Tribunal with respect to consumer claims in existing proceedings does not affect any right, privilege, obligation or liability acquired, accrued or incurred under the pre-existing legislation
WORDS AND PHRASES - "consumer", "goods of a kind ordinarily acquired for the purpose of personal, domestic or household use or consumptions", "using [goods] up or transforming them … in the course of a process of production or manufacture"
Legislation Cited: Australian Consumer Law (NSW)
Acts Interpretation Act 1958 (Vic)
Building and Construction Industry Security of Payment Act 1999 (NSW)
Civil and Administrative Tribunal Act 2013 (NSW)
Civil and Administrative Tribunal Rules 2014 (NSW)
Competition and Consumer Act 2010 (Cth)
Corporations Act 2001 (Cth)
Design and Building Practitioners Act 2020 (NSW)
Fair Trading Act 1987 (NSW)
Fair Trading Amendment (Monetary Limit on Orders) Regulation 2022 (NSW)
Fair Trading Regulation 2019 (NSW)
Home Building Act 1989 (NSW)
Interpretation Act 1987 (NSW)
Trade Practices Act 1974 (Cth)
Cases Cited: 20*20 Pty Ltd v D&G Developments Pty Ltd [2009] WASC 343
Bunnings Group Limited v Laminex Group Limited [2006] FCA 682; 153 FCR 479
Carr v Finance Corporation of Australia Ltd (No 2) [1982] HCA 43; (1982) 150 CLR 139
County Securities Pty Ltd v Challenger Group Holdings Pty Ltd [2008] NSWCA 193
Gallagher v Masters Installation Pty Ltd [2017] NSWCATAP 117
Gaskell and Bourke v Northshore Homes Pty Ltd and Nazha [2021] NSWCATCD 33
John McDonald Building Services Pty Ltd v Gusa [2022] NSWCATAP 60
Laws v GWS Machinery Pty Ltd [2007] NSWSC 316
Maxwell v Murphy (1957) 96 CLR 261
Pollock v Hicks [2015] NSWCA 122
R v Papanicolaou (No 4) [2021] NSWSC 1698
Robertson v City of Nunawading [1973] VR 819
Theo Holdings Pty Ltd v Hockey; Australian Competition And Consumer Commission v Theo Holdings Pty Ltd [2000] FCA 665; (2000) 99 FCR 232
Wilson v Winnicott [2021] NSWCATAP 211
Woodward v Warwick Green Building Pty Ltd [2021] NSWCATAP 210
Texts Cited: D Pearce, Statutory Interpretation in Australia, Ninth Edition 2019
Category: Principal judgment
Parties: HB 20/35833
Actol Pty Ltd (Applicant)
Rise Products Pty Ltd (First Respondent)
Daniel Pszczonka (Second Respondent)
Benth Holdings Pty Ltd t/as Gledswood Projects (Fourth Respondent)